Loading...
HomeMy WebLinkAboutAnderson Architects Public Museum Renovation 2019 . 134Thi . , , '. � .Tr 4„ Oshkosh PROFESSIONAL SERVICES AGREEMENT THIS AGREEMENT, made on the n ril day of MA rdn , 2019, by and between the CITY of OSHKOSH, party of the first part, hereinafter referred to as CITY, and Engberg Anderson Architects located at 320 E. Buffalo St., Suite 500; Milwaukee, Wisconsin 53202, hereinafter referred to as the CONSULTANT. WITNESSETH: That the CITY and the CONSULTANT,for the consideration hereinafter named,enter into the following Agreement. COMPONENT PARTS OF THE AGREEMENT This Agreement consists of the following component parts, all of which are as fully a part of this Agreement as if herein set out verbatim, or if not attached, as if hereto attached: 1. This Instrument 2. Consultant's Professional Services Proposal dated January 25, 2019, and attached hereto. In the event that any provision in any of the above component parts of this Agreement conflicts with any provision in any other of the component parts,the provision in the component part first enumerated above shall govern over any other component part which follows it numerically except as may be otherwise specifically stated. CITY REPRESENTATIVE The CITY shall assign the following individual to manage this Agreement: Brad Larson, Director 920 236-5769 blarson@ci.oshkosh.wi.us City Hall,215 Church Avenue P.O.Box 1 130 Oshkosh,WI 54903-1 130 http://www.ci.oshkosh.wi.us , SCOPE OF WORK The CONSULTANT shall provide the services described in the CONSULTANT's attached Professional Services Proposal. CITY may make or approve changes within the general Scope of Services contained within the Professional Services Proposal and in this AGREEMENT. If such changes affect CONSULTANT's cost or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT. RECORDS AND INSTRUMENTS OF SERVICE The City acknowledges the CONSULTANT's reports, drawings, data, computer files, and other materials, documents prepared by the CONSULTANT as instruments of professional service. Nevertheless, the plans and specifications prepared under this Agreement shall become the property of the City upon completion of the work and payment in full of all monies due to the CONSULTANT. The City agrees, to the fullest extent permitted by law, that consultant does not warranty or guaranty its deliverables in the context of only reuse or modification of the instruments of service by the City or any person or entity for which the City is responsible. Any document related to this agreement, whether in electronic or paper form, is considered a public record and shall be provided to the City upon request. The CONSULTANT may provide the City with an explanation of why they believe any document should not be released to the public. The City shall make all final determinations regarding the release of any document related to this Agreement. TERM AND TERMINATION A. Term. This Agreement shall commence upon the date indicated above and shall terminate on December 31,2019, unless terminated earlier by one of the parties as provided below, except that CITY may extend this Agreement,upon written notice to CONSULTANT. B. Termination. 1. For Cause. If either party shall fail to fulfill in timely and proper manner any of the obligations under this Agreement,the other party shall have the right to terminate this Agreement by written notice. In this event,the CONSULTANT shall be entitled to compensation to the date of delivery of the Notice. 2.For Convenience. The CITY may terminate this Agreement at any time by giving written notice to the CONSULTANT no later than 30 calendar days before the termination date. TIME OF COMPLETION The CONSULTANT shall perform the services under this Agreement with reasonable diligence and expediency consistent with sound professional practices. The CITY agrees that the Page 2 of 7 CONSULTANT is not responsible for damages arising directly or indirectly from any delays for causes beyond the CONSULTANT's control. For the purposes of this Agreement, such causes include,but are not limited to,strikes or other labor disputes,severe weather disruptions or other natural disasters, or failure of performance by the CITY. If the delays resulting from any such causes increase the time required by the CONSULTANT to perform its services in an orderly and efficient manner, the CONSULTANT shall be entitled to an equitable adjustment in schedule. SUSPENSION,DELAY,OR INTERRUPTION OF WORK CITY may suspend, delay, or interrupt the Services of CONSULTANT for the convenience of CITY. In such event, CONSULTANT's contract price and schedule shall be equitably adjusted. ASSIGNMENT Neither party to this Agreement shall transfer, sublet or assign any rights under or interest in this Agreement (including, but not limited to, monies that are due or monies that may be due) without the prior written consent of the other party. INDEPENDENT CONTRACTOR CONSULTANT is an independent contractor and is not an employee of the CITY. COOPERATION IN LITIGATION AND AUDITS CONSULTANT shall fully and completely cooperate with the CITY, the City's insurer,the City's attorneys, the CITY's Auditors or other representative of the CITY (collectively, the "City" for purposes of this Article) in connection with (a) any internal or governmental investigation or administrative,regulatory, arbitral or judicial proceeding(collectively"Litigation")or internal or governmental Audit, with respect to matters relating to this Agreement;other than a third party proceeding in which CONSULTANT is a named party and CONSULTANT and the CITY have not entered into a mutually acceptable joint defense agreement. Such cooperation may include,but shall not be limited to, responding to requests for documents and/or other records, and making CONSULTANT's employees available to the CITY (or their respective insurers, attorneys or auditors) upon reasonable notice for: (i) interviews, factual investigations, and providing declarations or affidavits that provide truthful information in connection with any Litigation or Audit; (ii) appearing at the request of the CITY to give testimony without requiring service of a subpoena or other legal process;(iii)volunteering to the CITY all pertinent information related to any Litigation or Audit;and (iv)providing information and legal representations to auditors in a form and within a timeframe requested. CITY shall reimburse CONSULTANT for reasonable direct expenses incurred in connection with providing documents and records required under this paragraph and may require, at the CITY's Page 3 of 7 sole discretion,such expenses to be documented by receipts or other appropriate documentation. Reasonable direct expenses include costs, such as copying, postage and similar costs;but do not include wages,salaries,benefits and other employee compensation. CONSULTANT shall not be entitled to additional compensation for employee services provided under this paragraph. STANDARD OF CARE The standard of care applicable to CONSULTANT's Services will be the degree of skill and diligence normally employed by professional CONSULTANTs or consultants performing the same or similar Services at the time said services are performed.CONSULTANT will re-perform any services not meeting this standard without additional compensation. CITY RESPONSIBILITIES The CITY shall furnish, at the CONSULTANT's request, such information as is needed by the CONSULTANT to aid in the progress of the project, providing it is reasonably obtainable from CITY records. CONSULTANT may reasonably rely upon the accuracy, timeliness, and completeness of the information provided by CITY. To prevent any unreasonable delay in the CONSULTANT's work, the CITY will examine all reports and other documents and will make any authorizations necessary to proceed with work within a reasonable time period. PAYMENT A. The Agreement Sum. The CITY shall pay to the CONSULTANT for the performance of the Agreement the amount of $180,800 (Schematic Design and Design Development) in the Cost portion of the Consultant's Professional Services Proposal. B. Method of Payment. The CONSULTANT shall submit itemized monthly statements for services. The CITY shall pay the CONSULTANT within 30 calendar days after receipt of such statement. If any statement amount is disputed,the CITY may withhold payment of such amount and shall provide to CONSULTANT a statement as to the reason(s) for withholding payment. C. Additional Costs. Costs for additional services shall be negotiated and set forth in a written amendment to this Agreement executed by both parties prior to proceeding with the work covered under the subject amendment. Page 4 of 7 HOLD HARMLESS The CONSULTANT covenants and agrees to protect and hold the City of Oshkosh harmless against all actions, claims, and demands which may be to the proportionate extent caused by or result from the intentional or negligent acts of the CONSULTANT, its agents or assigns, its employees, or its SUBCONSULTANT related to the performance of this Agreement or be caused or result from any violation of any law or administrative regulation, and shall indemnify or refund to the CITY all sums including court costs,attorney fees,and punitive damages which the CITY may be obliged or adjudged to pay on any such claims or demands within thirty (30) days of the date of the CITY's written demand for indemnification or refund for those actions, claim, and demands caused by or resulting from intentional or negligent acts as specified in this paragraph. Subject to any limitations contained in Sec. 893.80 and any similar statute, of the Wisconsin Statutes, the CITY further agrees to hold CONSULTANT harmless from any and all liability, including claims, demands, losses, costs, damages, and expenses of every kind and description (including death), which may be to the proportionate extent caused by or result from the intentional or negligent acts of the CITY, its agents or assigns, its employees, or its SUBCONSULTANTS related to the performance of this Agreement or be caused or result from any violation of any law or administrative regulation, where such liability is founded upon or grows out of the acts or omission of any of the officers,employees or agents of the City of Oshkosh while acting within the scope of their employment. It is the intention of the parties to this Agreement that each party shall be solely responsible for its own actions and activities and the actions and activities of its own officers, employees and agents while acting within the scope of their employment INSURANCE The CONSULTANT agrees to abide by the attached City of Oshkosh Insurance Requirements for Professional Services. WHOLE AGREEMENT/AMENDMENT This document and any specified attachments contain all terms and conditions of the Agreement and any alteration thereto shall be invalid unless made in writing, signed by both parties and incorporated as an amendment to this Agreement. NO THIRD-PARTY BENEFICIARIES This AGREEMENT gives no rights or benefits to anyone other than CITY and CONSULTANT and has no third-party beneficiaries. Page 5 of 7 AGREEMENT NOT TO BE CONSTRUED AGAINST ANY PARTY This Agreement is the product of negotiation between the parties hereto and no term, covenant or provision herein or the failure to include a term, covenant or provision shall be construed against any party hereto solely on the basis that one party or the other drafted this Agreement or any term, covenant or condition contained herein. NO WAIVER Failure of either party to insist upon the strict performance of terms and provisions of this agreement, or any of them, shall not constitute or be construed as a waiver or relinquishment of that party's right to thereafter enforce such term or provision, and that term of the provisions shall continue in full force and effect. NON-DISCRIMINATION The Operator agrees not to discriminate in its operations under this Agreement on the basis of race,color, creed, age, and gender, or as otherwise prohibited by law. A breach of this covenant may be regarded as a material breach of this Agreement SEVERABILITY If any term, covenant, condition or provision of this agreement shall be invalid or enforceable, the remainder of this agreement shall not be affected thereby the remainder of the agreement shall be valid and enforceable to the fullest extent permitted by law. CHOICE OF LAW AND VENUE The laws of the State of Wisconsin shall govern the interpretation and construction of this Agreement. Winnebago County shall be the venue for all disputes arising under this Agreement. Page 6 of 7 IN WITNESS WHEREOF, the City of Oshkosh, Wisconsin,has caused this contract to be sealed with its corporate seal and to be subscribed to by its City Manager and City Clerk and countersigned by the Comptroller of said CITY, and CONSULTANT hereunto set its hand and seal the day and year first above written. In the Presence of: Name of CONSULTANT Company/Firm By: Pha�ve+�e. (Seal of CONSULTANT (Specify Title) if a Corporation.) CITY OF OSHKOSH By: Mark A. Rohloff, City Manager i ess) And: rtness) Pamela R. Ubrig, City lerk APPROVED: I hereby certify that the necessary provisions have been made to pay the liability which will accrue under this contract ity : ttomey J' City Comptroller Page 7 of 7 IrjEngberg Anderson ARCHITECTS January 25, 2019 AGREEMENT FOR ARCHITECTURAL DESIGN SERVICES OSHKOSH PUBLIC MUSEUM I RENOVATION & EXPANSION between and Oshkosh Public Museum Engberg Anderson, Inc. 1331 Algoma Boulevard 320 E. Buffalo St., Suite 500 Oshkosh,WI 54901 Milwaukee, WI 53212 Engberg Anderson Project No. 162604 Dear Brad, Engberg Anderson is pleased to submit this proposal for architectural design services. This proposal is based on our current understanding of the project. We ask that you review the scope, schedule and fee proposed and identify any concerns or questions in this regard. SCOPE OF BASIC SERVICES PROJECT UNDERSTANDING The Oshkosh Public Museum desires to expand its current facility to meet the long term needs of the institution. The intent is to create two additions to the existing building to improve the patron experience at the entrance of the building and to improve the flow of materials from the loading dock to each level of the museum. The additions will be designed to seamlessly integrate with the existing building. The design work will include civil engineering,architectural design, mechanical, electrical, plumbing and fire protection design, construction cost estimates, and presentation drawings for use in providing public information and fundraising. PROJECT PARAMETERS Schedule It is anticipated that the project will progress as follows: Phase 1-2017—Concept Design (Complete) Phase 2-2019—Schematic& Design Development Phase 3-2020—Construction Document Production Phase 4-2021 to 2022—Bidding and Construction Phase Services Budget The construction cost for the project is estimated at$7,750,000. 320 E Buffalo St, Suite 500 I Milwaukee, WI 53202 I (414) 944-9000 I www.engberganderson.com PV'l I LJVAU KEE MADISON TUCSON CHICAGO Reviews and Approvals After each phase of work, the design team will present a design package including a cost estimate for approval before beginning the next phase of design. Owner Supplied Information/Responsibilities The Museum will continue to be an active participant in the process. By virtue of its central role and the extensive work completed to date it is in a unique position to bring the various decision makers and stakeholders together. The purpose of this effort is to build understanding and consensus. The Museum is responsible to identify those individuals whose participation is needed to meet the local requirements for broad based consensus. The Museum will need to supply information during the project to support the design and construction efforts: • Site survey • Geotechnical report • Exhibit design drawings • Other information as needed to coordinate with the building or site design WORK PLAN &DELIVERABLES A detailed Work Plan is appended to this proposal and is the basis for the fee proposal in the next section. FEE PROPOSAL FEE Based on the current project understanding, we propose to complete the outlined services for a fee calculated as 8%of the cost of construction ($7,750,000 x 8%=$620,000), less the concept design fee of$18,800 and including expenses itemized later in the proposal. The fee breakdown is as follows: DESIGN FEE Breakdown Design Fee Expenses Total Schematic Design 10% 60,000 400 60,400 Design Development 20% 120,000 400 120,400 Construction Documents 36% 216,000 800 216,800 Bidding 6% 36,000 400 36,400 Contract Administration 28% 168,000 3,400 171,400 TOTAL $600,000 $5,400 $605,400 At a time when it is mutually agreeable to both parties,the fee can be converted from a percentage of construction to a lump sum fee, no later than the start of Construction Documents (Phase 3). As with all agreements, if the scope of the work or parameters under which the work is performed are modified,we reserve the right to review the fees related to these modifications and make mutually agreeable adjustments. REIMBURSABLE EXPENSES We propose to include reimbursables in the fees as calculated above. These amounts are based on the following assumptions; Page 2 I • REIMBURSABLE FEE BASES Mileage Printing Total Design Development Meetings 6 trips 660 140 800 Construction Documents Meetings 4 trips 440 360 800 Bidding Meetings 3 trips 330 70 400 Contract Administration Meetings 28 trips 3080 320 3,400 The printing costs above include printing of materials for meetings and one set of completed drawings and specifications at the end of each phase. All materials will be delivered to the client as PDF files for additional printing as needed by the client's vendors, including bid documents if required. PROGRESS PAYMENTS Invoices shall be submitted monthly and shall reflect the status of the work at the time of the invoice. Payments based on the invoices shall be made in accordance with established review and approval procedures. Invoices shall be submitted monthly and shall reflect the status of the work at the time of the invoice. Expense of professional liability insurance dedicated exclusively to this Project or the expense of additional insurance coverage or limits requested by the Owner in excess of that normally carried by the Architect. The Architect currently maintains the coverages identified in the insurance Coverages Exhibit. OTHER TERMS ADDITIONAL SERVICES No additional service will be undertaken without a defined scope and written authorization. Any Additional Service will be itemized and invoiced against a limit established and agreed to in writing by both parties. Any additional service shall be invoiced separately to allow tracking of project expenses. USE OF MATERIALS The Architect agrees to furnish, upon completion of this Agreement, upon termination and upon demand by the Library,copies of all basic notes and sketches, charts, computations,and any other data prepared or obtained by the Architect pursuant to this Agreement, and without restrictions or limitation as to the use relative to specific Projects covered under this Agreement. In such event,the Architect shall not be liable for the use of such documents by the Library or others. TERMINATION Both parties acknowledge each other's right to terminate this agreement with 15 days written notice and without cause. Upon such notification all product of the design effort completed to that point becomes the property of the Library and any fees earned to that point become due. ATTACHMENTS The following Exhibits are made part of this agreement: • Exhibit:Work Plans • Exhibit: Insurance Coverages Page 3