Loading...
HomeMy WebLinkAboutMiller & Associates Playground Design & Installation South ParkPROFESSIONAL SERVICES AGREEMENT PLAYGROUND DESIGN AND INSTALLATION FOR SOUTH PARK THIS AGREEMENT, made on the 23 day of MARCH, 2018, by and between the CITY of OSHKOSH, hereinafter referred to as CITY, and MILLER & ASSOCIATES — Sauk Prairie Inc., PO BOX 154 PRAIRIE DU SAC, WI 53578 hereinafter referred to as the CONSULTANT. WITNESSETH: That the CITY and the CONSULTANT, for the consideration hereinafter named, enter into the following Agreement. COMPONENT PARTS OF THE AGREEMENT This Agreement consists of the following component parts, all of which are as fully a part of this Agreement as if herein set out verbatim, or if not attached, as if hereto attached: 1. This Instrument 2. Consultant's Professional Services Proposal dated FEBRUARY 23, 2018 In the event that any provision in any of the above component parts of this Agreement conflicts with any provision in any other of the component parts, the provision in the component part first enumerated above shall govern over any other component part which follows it numerically except as may be otherwise specifically stated. CITY REPRESENTATIVE The CITY shall assign the following individual to manage this Agreement: Ray Maurer, City of Oshkosh Parks Director SCOPE OF WORK The CONSULTANT shall provide the services described in the CONSULTANT's attached Professional Services Proposal. CITY may make or approve changes within the general Scope of Services contained within the Professional Services Proposal and in this AGREEMENT. If such changes affect CONSULTANT's cost or time required for performance of the services, an equitable adjustment will be made through an amendment to this AGREEMENT. City Hall, 215 Church Avenue P.O. Box 1 130 Oshkosh, WI 54903-1130 http://www.ci.oshkosh.wi.us RECORDS AND INSTRUMENTS OF SERVICE All reports, drawings, software, data, computer files, and other materials, documents and instruments prepared by the CONSULTANT as instruments of service shall remain the property of the CITY. Any document related to this agreement, whether in electronic or paper form, is considered a public record and shall be provided to the City upon request. The contractor may provide the City with an explanation of why they believe any document should not be released to the public. The City shall make all final determinations regarding the existence or release of any document related to this agreement. TERM AND TERMINATION A. Term. This Agreement shall commence upon the date indicated above and shall terminate on MAY 25,2018, unless terminated earlier by one of the parties as provided below. B. Termination. 1. For Cause. If either party shall fail to fulfill in timely and proper manner any of the obligations under this Agreement, the other party shall have the right to terminate this Agreement by written notice. In this event, the CONSULTANT shall be entitled to compensation to the date of delivery of the Notice. 2. For Convenience. The CITY may terminate this Agreement at any time by giving written notice to the CONSULTANT no later than 30 calendar days before the termination date. TIME OF COMPLETION The CONSULTANT shall perform the services under this Agreement with reasonable diligence and expediency consistent with sound professional practices. The CITY agrees that the CONSULTANT is not responsible for damages arising directly or indirectly from any delays for causes beyond the CONSULTANT's control. For the purposes of this Agreement, such causes include, but are not limited to, strikes or other labor disputes, severe weather disruptions or other natural disasters, or failure of performance by the CITY. If the delays resulting from any such causes increase the time required by the CONSULTANT to perform its services in an orderly and efficient manner, the CONSULTANT shall be entitled to an equitable adjustment in schedule. SUSPENSION, DELAY, OR INTERRUPTION OF WORK CITY may suspend, delay, or interrupt the Services of CONSULTANT for the convenience of CITY. In such event, CONSULTANT's contract price and schedule shall be equitably adjusted. ASSIGNMENT Contractor shall not have the right to assign this Agreement without the written prior consent of the City. INDEPENDENT CONTRACTOR CONSULTANT is an independent contractor and is not an employee of the CITY. COOPERATION IN LITIGATION AND AUDITS Contractor shall fully and completely cooperate with the City, the City's insurer, the City's attorneys, the City's Auditors or other representative of the City (collectively, the "City" for purposes of this Article) in connection with (a) any internal or governmental investigation or administrative, regulatory, arbitral or judicial proceeding (collectively "Litigation") or internal or governmental Audit, with respect to matters relating to this Agreement; other than a third party proceeding in which Contractor is a named party and Contractor and the City have not entered into a mutually acceptable joint defense agreement. Such cooperation may include, but shall not be limited to, responding to requests for documents and/or other records, and making Contractor's employees available to the City (or their respective insurers, attorneys or auditors) upon reasonable notice for: (i) interviews, factual investigations, and providing declarations or affidavits that provide truthful information in connection with any Litigation or Audit; (ii) appearing at the request of the City to give testimony without requiring service of a subpoena or other legal process; (iii) volunteering to the City all pertinent information related to any Litigation or Audit; and (iv) providing information and legal representations to auditors in a form and within a timeframe requested. City shall reimburse Contractor for reasonable direct expenses incurred in connection with providing documents and records required under this paragraph and may require, at the City's sole discretion, such expenses to be documented by receipts or other appropriate documentation. Reasonable direct expenses include costs, such as copying, postage and similar costs; but do not include wages, salaries, benefits and other employee compensation. Contractor shall not be entitled to additional compensation for employee services provided under this paragraph. STANDARD OF CARE The standard of care applicable to CONSULTANT's Services will be the degree of skill and diligence normally employed by professional CONSULTANTs or consultants performing the same or similar Services at the time said services are performed. CONSULTANT will re -perform any services not meeting this standard without additional compensation. CITY RESPONSIBILITIES The CITY shall furnish, at the CONSULTANT's request, such information as is needed by the _CONSULTANT to aid in the progress of the project, providing it is reasonably obtainable from City records. CONSULTANT may reasonably rely upon the accuracy, timeliness, and completeness of the information provided by CITY. To prevent any unreasonable delay in the CONSULTANT's work, the CITY will examine all reports and other documents and will make any authorizations necessary to proceed with work within a reasonable time period. PAYMENT A. The Agreement Sum. The CITY shall pay to the CONSULTANT for the performance of the Agreement the amount as outlined in the Cost portion of the Consultant's Professional Services Proposal ($137,140.00). B. Method of Payment. The CONSULTANT shall submit itemized monthly statements for services. The CITY shall pay the CONSULTANT within 30 calendar days after receipt of such statement. If any statement amount is disputed, the CITY may withhold payment of such amount and shall provide to CONSULTANT a statement as to the reason(s) for withholding payment. C. Additional Costs. Costs for additional services shall be negotiated and set forth in a written amendment to this Agreement executed by both parties prior to proceeding with the work covered under the subject amendment. HOLD HARMLESS The CONSULTANT covenants and agrees to protect and hold the City of Oshkosh harmless against all actions, claims, and demands which may be to the proportionate extent caused by or result from the intentional or negligent acts of the CONSULTANT, its agents or assigns, its employees, or its subcontractors related to the performance of this Agreement or be caused or result from any violation of any law or administrative regulation, and shall indemnify or refund to the CITY all sums including court costs, attorney fees, and punitive damages which the CITY may be obliged or adjudged to pay on any such claims or demands within thirty (30) days of the date of the CITY's written demand for indemnification or refund for those actions, claim, and demands caused by or resulting from intentional or negligent acts as specified in this paragraph. Subject to any limitations contained in Sec. 893.80 and any similar statute, of the Wisconsin Statutes, the City further agrees to hold CONTRACTOR harmless from any and all liability, including claims, demands, losses, costs, damages, and expenses of every kind and description (including death), which may be to the proportionate extent caused by or result from the intentional or negligent acts of the CITY, its agents or assigns, its employees, or its subcontractors related to the performance of this Agreement or be caused or result from any violation of any law or administrative regulation, where such liability is founded upon or grows out of the acts or omission of any of the officers, employees or agents of the City of Oshkosh while acting within the scope of their employment. It is the intention of the parties to this Agreement that each party shall be solely responsible for its own actions and activities and the actions and activities of its own officers, employees and agents while acting within the scope of their employment INSURANCE The CONSULTANT agrees to abide by the attached City of Oshkosh Insurance Requirements for Professional Services. WHOLE AGREEMENT / AMENDMENT This document and any specified attachments contain all terms and conditions of the Agreement and any alteration thereto shall be invalid unless made in writing, signed by both parties and incorporated as an amendment to this Agreement. NO THIRD -PARTY BENEFICIARIES This AGREEMENT gives no rights or benefits to anyone other than CITY and CONSULTANT and has no third -party beneficiaries. AGREEMENT NOT TO BE CONSTRUED AGAINST ANY PARTY This Agreement is the product of negotiation between the parties hereto and no term, covenant or provision herein or the failure to include a term, covenant or provision shall be construed against any party hereto solely on the basis that one party or the other drafted this Agreement or any term, covenant or condition contained herein. NO WAIVER Failure of either party to insist upon the strict performance of terms and provisions of this agreement, or any of them, shall not constitute or be construed as a waiver or relinquishment of that party's right to thereafter enforce such term or provision, and that term of the provisions shall continue in full force and effect. NON-DISCRIMINATION The Operator agrees not to discriminate in its operations under this Agreement on the basis of race, color, creed, age, and gender, or as otherwise prohibited by law. A breach of this covenant may be regarded as a material breach of this Agreement SEVERABILITY If any term, covenant, condition or provision of this agreement shall be invalid or enforceable, the remainder of this agreement shall not be affected thereby the remainder of the agreement shall be valid and enforceable to the fullest extent permitted by law. CHOICE OF LAW AND VENUE The laws of the State of Wisconsin shall govern the interpretation and construction of this Agreement. Winnebago County shall be the venue for all disputes arising under this Agreement. IN WITNESS WHEREOF, the City of Oshkosh, Wisconsin, has caused this contract to be sealed with its corporate seal and to be subscribed to by its City Manager and City Clerk and countersigned by the Comptroller of said City, and CONSULTANT hereunto set its hand and seal the day and year first above written. In the Presence of: (Seal of Contractor if a Corporation.) APPROVED: 01111 .1, � EXI ow �a 1i , CONTRACTOR Name of Company/Firm : Miller & Associates - Sauk Prairie, Inc. B Steven Barritt President (Specify Title) CITY OF OSHKOSH By: Mark A. Rohloff, City Manager An Pamela R. Ubrig, City Clerk I hereby certify that the necessary provisions have been made to pay the liability which will accrue under this contract City Comptroller GRANITE RE, INC. GENERAL POWER OF ATTORNEY Know all Men by these Presents: That GRANITE RE, INC., a corporation organized and existing under the laws of the State of OKLAHOMA and having its principal office at the City of OKLAHOMA CITY in the State of OKLAHOMA does hereby constitute and appoint: MICHAEL J. DOUGLAS; CHRIS STEINAGEL; CHRISTOPHER M. KEMP; KARLA HEFFRON; ROBERT DOWNEY; CONNIE SMITH its true and lawful Attorney-in-Fact(s) for the following purposes, to wit: To sign its name as surety to, and to execute, seal and acknowledge any and all bonds, and to respectively do and perform any and all acts and things set forth in the resolution of the Board of Directors of the said GRANITE RE, INC. a certified copy of which is hereto annexed and made a part of this Power of Attorney; and the said GRANITE RE, INC. through us, its Board of Directors, hereby ratifies and confirms all and whatsoever the said: MICHAEL J. DOUGLAS; CHRIS STEINAGEL; CHRISTOPHER M. KEMP; KARLA HEFFRON; ROBERT DOWNEY; CONNIE SMITH may lawfully do in the premises by virtue of these presents. In Witness Whereof, the said GRANITE RE, INC. has caused this instrument to be sealed with its corporate seal, duly attested by the signatures of its President and Secretary/Treasurer, this 1411' day of June, 2017. \T E RE„ y✓ v ooevoW f ryC,` Kenneth D. Whittingron, President STATE OF OKLAHOMA ) s E_a i SS: COUNTY OF OKLAHOMA ) Kyle . McDonald, Treasurer On this 14" day of June, 2017, before me personally came Kenneth D. Whittington, President of the GRANITE RE, INC. Company and Kyle P. McDonald, Secretary/Treasurer of said Company, with both of whom I am personally acquainted, who being by me severally duly sworn, said, that they, the said Kenneth D. Whittington and Kyle P. McDonald were respectively the President and the Secretary/Treasurer of GRANITE RE, INC., the corporation described in and which executed the foregoing Power of Attorney; that they each knew the seal of said corporation; that the seal affixed to said Power of Attorney was such corporate seal, that it was so fixed by order of the Board of Directors of said corporation, and that they signed their name thereto by like order as President and Secretary/Treasurer, respectively, of the Company. "� Go k R My Commission Expires:=...w..= August 8, 2021 �, Commission #: 01013257°FSK' Notal Public GRANITE RE, INC. Certificate THE UNDERSIGNED, being the duly elected and acting Secretary/Treasurer of Granite Re, Inc., an Oklahoma Corporation, HEREBY CERTIFIES that the following resolution is a true and correct excerpt from the July 15, 1987, minutes of the meeting of the Board of Directors of Granite Re, Inc. and that said Power of Attorney has not been revoked and is now in full force and effect. "RESOLVED, that the President, any Vice President, the Secretary, and any Assistant Vice President shall each have authority to appoint individuals as attorneys -in -fact or under other appropriate titles with authority to execute on behalf of the company fidelity and surety bonds and other documents of similar character issued by the Company in the course of its business. On any instrument making or evidencing such appointment, the signatures may be affixed by facsimile. On any instrument conferring such authority or on any bond or undertaking of the Company, the seal, or a facsimile thereof, may be impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not be necessary to the validity of any such instrument or undertaking." IN WITNESS WH E F, the ndersigned h s subscribed this Certificate and affixed the corporate seal of the Corporation this day of 20jXpPN1TERE, N s E A L Kyle P. McDonald, Secretary/Treasurer G R0800-1 CONTRACTOR: Name, legal status and address) MILLER & ASSOCIATES-SAUK PRAIRIE, INC. P.O. Box 154 Prairie du Sac, WI 53578 OWNER: (Name, legal status and address) City Of Oshkosh 215 Church Ave Oshkosh, WI 54903 WAIA Document A31OTM-2010 SURETY: (Name, legal status and principal place of business) Granite Re, Inc. 14001 Quailbrook Dr Oklahoma City, OK 73134 BOND AMOUNT: Five Percent of the Bid Amount (5.00% of Bid Amount) PROJECT: (Name, location or address, and Project number, if any) Proposal for Modular Playground Equipment Design and Install - South Park; Project No. RFP -020218.0.2018 Bid Bond No. GR12634 This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. The Contractor and Surety are bound to the Owner in the amount set forth above, for the payment of which the Contractor and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, as provided herein. The conditions of this Bond are such that if the Owner accepts the bid of the Contractor within the time specified in the bid documents, or within such time period as may be agreed to by the Owner and Contractor, and the Contractor either (1) enters into a contract with the Owner in accordance with the terms of such bid, and gives such bond or bonds as may be specified in the bidding or Contract Documents, with a surety admitted in the jurisdiction of the Project and otherwise acceptable to the Owner, for the faithful performance of such Contract and for the prompt payment of labor and material furnished in the prosecution thereof; or (2) pays to the Owner the difference, not to exceed the amount of this Bond, between the amount specified in said bid and such larger amount for which the Owner may in good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. The Surety hereby waives any notice of an agreement between the Owner and Contractor to extend the time in which the Owner may accept the bid. Waiver of notice by the Surety shall not apply to any extension exceeding sixty (60) days in the aggregate beyond the time for acceptance of bids specified in the bid documents, and the Owner and Contractor shall obtain the Surety's consent for an extension beyond sixty (60) days. If this Bond is issued in connection with a subcontractor's bid to a Contractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. When this Bond has been furnished to comply with a statutory or other legal requirement in the location of the Project, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. and sealed this 16th day of February, 2018 (Witness) Karla K. Heffron K PRAIRIE. INC, (Principal) r) ,f (seal) = (Tit ) I (Su ty) /c _ (Seal) (Title)Connie Smith, Attorney -in -Fad AIA Document A330'"— 2010. C pyright ©1963, 1970 and 2010 by The American Institute of Architects. All rights reserved. WARNING: This AIA6 Document is protected by opyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. Purchasers are permitted o reproduce ten copies of this document when completed, i o repo copyng vio a Ions or AIA Lontractocumen s, a -mai The American Institute of Architects' legal counsel, copyright0aia ora. Milo