Loading...
HomeMy WebLinkAboutMaquire Iron, Inc� � CONSTRUCTION CONTRACT THIS AGREEMENT, made on the 13�h day of January, 2016, by and between the CITY OF OSHKOSH, party ofthe first part, hereinafter referred to as CITY, and MAGUIRE IRON, INC., PO BOX 1446, SIOUX FALLS, SD, 57101, party of the second part, hereinafter referred to as the CONTRACTOR, WITNESSETH: That the CITY and the CONTRACTOR, for the consideration hereinafter named, agree as follows: ARTICLE I. SCOPE OF WORK The CONTRACTOR hereby agrees to furnish all of the materials and all of the equipment and labor necessary, and to perform all of the work shown on the plans and described in the specifications for the project entitled or described as follows: Public Works Contract No. 16-10 for the southwest water tower interior painting, for the Public Works Department, pursuant to Resolution 16-OS adopted by the Common Council of the City of Oshkosh on the 12th day of January, 2016, all in accordance and in strictcompliancewith the CONTRACTOR's Proposal and the other Contract Documents referred to in ARTICLE V of this Contract. ARTICLE II. TIME OF COMPLETION The work to be performed under this contract shall be commenced and the work completed within the time limits specified in the Special Conditions and/or CONTRACTOR's proposal. ARTICLE III. PAYMENT (a) The Contract Sum. The CITY shall pay to the CONTRACTOR for the performance of the Contract the sum of Two Hundred - Twenty One Thousand - Seven Hundred - Ninety One Dollars and 00/100 ($221,790.00), adjusted by any changes as provided in the Specifications, orany changes hereafter mutually agreed upon in writing by the parties hereto, provided, however, in the event the Proposal and Contract Documents are on a"Unit Price" basis, the above mentioned figure is an estimated figure, and the CITY shall, in such cases, pay to the CONTRACTOR for the performance of the Contract the amounts determined for the total number of each of the units of work as set forth in the CONTRACTOR's proposal; the number of units therein contained is approximate only, and the final payment shall be made for the actual number of units that are incorporated in or made necessary by the �� work covered by the Contract. (b) Progress Payments. In the event the time necessary to complete this Contract is such that progress payments are required, they shall be made according to the provisions set forth in the Specifications. ARTICLE IV. CONTRACTOR TO HOLD CITY HARMLESS The CONTRACTOR covenants and agrees to protect and hold the CITY harmless against all actions, claims and demands of any kind or characterwhatsoeverwhich may in any way be caused by or result from the intentional or negligent acts of the CONTRACTOR, his agents or assigns, his employees or his subcontractors related however remotely to the performance of this Contrect or be caused or result from any violation of any law or administrative regulation, and shall indemnify or refund to the CITY all sums including court costs, attorney fees, and punitive damages which the CITY may be obliged or adjudged to pay on any such claims or demands within thirty (30) days of the date of the CITY's written demand for indemnification or refund. ARTICLE V. INSURANCE The Insurance required by the City of Oshkosh as specified in the CITY's specifications, including addenda, or plans, or instructions, or advertisements, shall be primarv coveraqe and that any insurance or self insurance maintained by the City of Oshkosh, its officers, council members, agents, employees or authorized volunteers will not contribute to a loss. All insurance shall be based upon the occurrence of an event, and not based on claims made. All insurance shall be in full force prior to commencing work and remain in force until the entirejob is completed and the length of time that is specifed, if any, in this Contract, the Specifications, whichever is longer. ARTICLE VI. COMPONENT PARTS OF THE CONTRACT This Contract consists of the following component parts, all of which are as fully a part of this contract as if herein set out verbatim, or if not attached, as if hereto attached: 1. This Instrument 2. The City's Plans and Specifications, including all Addenda's 3. City of Oshkosh Standard Specifications 4. Instructions to Bidders 5. Advertisement for Bids 6. Contractor's Proposal The Contract Documents are complementary; what is required by one is as binding as if required by all. Before undertaking each part of the work, the CONTRACTOR shall carefully study and compare the Contract Documents and check and verify all pertinent figures and measurements required therein. CONTRACTOR shall promptly report in writing to the Engineer any conflict, error, ambiguity or discrepancy which CONTRACTOR may discover and shall obtain written clarifcation from the Engineer before proceeding with any work affected thereby. ., � : In the event that any provision in any of the above component parts ofthis Contract conflicts with any provision in any other of the component parts, the provision in the component part first en umerated above shall govern over any other component part which follows it numerically except as may be otherwise specifically stated. IT IS HEREBY DECLARED, UNDERSTOOD AND AGREED that the word "CONTRACTOR" wherever used in this Contract means the party of the second part and its/his/their legal representatives, successors, and assigns. IN WITNESS WHEREOF, the City of Oshkosh, Wisconsin, has caused this contract to be sealed with its corporate seal and to be subscribed to by its City Manager and City Clerk and countersigned by the Comptroller of said City, and the party of the second part hereunto set its, his or their hand and seal the day and year first above written. In the Presence of: (Seal of Contractor if a Corporation.) � L Z G� (W(tness �/1 G� 21�. � 2. -�/�, itness) _••:• � � � k��iw'�/v-t_. ��I ,1 �X. ti�,i� CiE�/ A� o� CONTRACTO MAGUIRE IR , NC By: � PfeS�detid �e i le) By: F 2. ; ai / (Specify Title) CITY OF OSHKOSH By: /ya--�e�,C✓�- Ma A. Rohloff, City Manager �_� �� An . _ � Pamela R. Ubrig, Cit Clerk / I hereby certify that the necessary provisions have been made to pay the liability which will accrue under this contract 11��� ..a...� . .-, _-- Bond No. nossiia �� ��, GREAT AMERICAN INSURANCE COMPANY •suwxcecxwv �H�Q Performance Bond Any singular relerenceto CoMrac[or, Surery, Ownaror othar party shall be consitlereA plural whereapplicable. CONTRACTOR: (Name, legal status and address) Maguire Iron, Inc. PO Boz 1446 Sioux Falls, 5➢ 5"I101 OWNER: (Name, legal sfaNS and address) City of Oshkosh, wI PO Hox 1130 Oshkosh, WI 549�2-1130 SURETY: (Name, legal status and pnncipal place o/business) Great Amezican Insurance Company 3460 Washington nrive, Suice 208 Eagan, MN 55122 CONSTRUCTION CONTRAC7 Da�e: January 13, 2016 AfYiO�OC Two Hundred Twen[y One Thousand Seven Hundied Ninety and m/100 ($221,]90.00) Description: Southwest Water Tower Interior Pain[ing (Ndlll¢2/1tlIOC2hOlifpublic Works Contract No. 16-10 Oshkosh, wisconsin BOND Date: January zo, zoie (NOtearlierthan Construction ContracfDate) Amount Two Hundred Twenty One Thousand Seven Hundred Ninety and m/100 ($221,v90.00) Modifcations to �his Bond: � None ❑ See Section i6 CONTRACTORA RINCI SURETY Company: (comorareseap Company: � (cwpora��seap maquire xro GREAT AMERICA 3iVS itiL+ COMPANY � SlgnaWre: � SignaNre- — Name and Title. Name antl Title'. � Gene Sones, Sz., Psesi Kevin Kroeze, A[torney-In-Pact (Any atltlitional signafures appear on the last paqe of fbis Per7ormance Bond) (FORINFORMATIONONLY—Name,addressandtelephone) OWNER'SREPRESENTATIVE: AGENT or BROKER: (Architec( Engineer or otherparty) Boen & Associates, Inc. PO 0ox 89010 SiOUx Fdlls, 5� 5]109 Phone: 605-336-0425 T�e Company eaeculing Nis Eontl voucM1es that this tlocument coniorms to GAIC PerfA312 QO/10) OocumentAllR � 4010 Edition 1 The Contractor and Surety, joinlly antl severally, bind themselves, iheir heirs, execulors, administralors, successors and assigns to the Owner for Ihe performance of ihe Constmction Contract, which is incorporated herein byreference. 2 If the Contrac[or performs the Construction Contract the Surery and the Contrector shall have no obligation untler Ihis Bond, except when applicable to participate in a conference as pmvided in Section 3. 3 If there is no Owner Default untler lhe Constmction Contrec[, ihe Surety's obligation under Ihis Bond shall anse afler 3.1 �he Owner first provitles nolice to �he Contrector and lhe Surety that ihe Owner is consitlering declaring a Contractor DefaulL Such notice shall intlicate whether t�e Owner is reQUesting a conference among l�e Owner, Contracror and Surery to tliswss the ConlractoYS performance. If the Owner tloes not request a conference, lhe Surety may, within five (5) business days after receipt of the Owner's notice, requesl such a wnference. If the Surery timely requests a conference, the Owner shall attentl. Unless the Owner agrees olherv+ise, any conference requestetl under Ihis Sedion 3.1 shall be held within ten (10) business tlays of Ihe Surelys receipt of Ihe Owner's notice. If the Owner, the Contractor antl the Surety agree, the Contrector shall be allowed a reasonable time to perform ihe Constmction Contrac�, bul such an agreement shall wl waive the Owners right, if any, subsequently to dedare a Contractor Defaulf, 3.2 �he Owner declares a Contracror Default, lenninales lhe Construction Conireci and nolifies the Surety', antl 3.3 lhe Owner has agreed to pay Ihe Balance of the Contract Price in accordance with Ihe terms of lhe Constmccion Contrad to lhe Surery or to a contrac�or selec�ed lo peAorm lhe Constmction Contract. 4 FaiWre on lhe part of the Owner to comply with the notice �equiremenl in Section 3.1 shall not constitute a faiWre ro comply with a condition precedent to ihe Surety's obligations, or release lhe Surety fmm its oCligations, except lo the euten� lhe Surety demonstrates acfual prelutlice. 5 When the Owner has salisfied the wntli�ions of Section 3, the SureTi shall promplly and at Ihe Surely's expense lake one of ihe following ac�ions: 5.1 Arrange for the Contractar, with the consent of the Owner, to perform and complete lhe Consiruclion Contrect, 5.2 Undertake to perform and complete lhe Conslmction Contract itself, lhrough its agents or indepentlent wntreclors; 5.3 Obtain bitls or negolialed pmposals fmm qualified contractors acceptable lo Ihe Owner for a contract for performance antl completion of lhe Constmclion Contract, arrange for a contract to be prepared for execution by �he Owner and a conUactor selectetl with the Ownefs concurrence, to be seared wilh pertormance and paymenl bontls executetl by a qualifietl surery equivalent lo Ihe bontls issued on the Cons�ruclion Contrect, and pay to the Owner lhe amount of damages as described in Section 7 in excess of the Balance of lhe Contraci Price inwrred by the Owner as a reSNt of the Contractor DefaWf, or 5.4 Waive its right to perform and wmplete, arrange for completion, or obtain a new contractor antl with reasonable promptness under Ihe circumstances: .1 Aker imestigation, determine the amount for whic� it may be liable lo the Owner and, as soon as practicable afler the amowt is determined, make payment to the Owner, or .2 Deny liabiliry in whole or in part and nolify [he Owner, citing the reasons for denial. 6 If the Surery does not pmceed as provitled in Section 5 with reasonable prompiness, fhe Surery shall be deemed to be in default on Ihis Bond seven tlays aRer receipt of an adtlitional writlen notice fmm the Owner b the Surery demanding that the Surety pertorm its obligations under this Bond, and lhe Owner shall be enti0ed m enforce any remetly available lo lhe Owner. if the Surety proceeds as providetl in Section 5.4, and Ihe Owner refuses the payment or Ihe Surery has tlenied liability, in whole or in part, withoul further notice the Owner shall Ee entitletl to enforce any remetly available ro lhe Owner. 7 If [he Surety elects [o act under Section 5.1, 52 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater l�an lhose of Ihe Contractor under Ihe Conslmction Contrad, antl �he responsibilities of the Owner to lhe Surery shall not be greater than lhose of the Owner under lhe Consimction ContracL Subjecl lo the wmmitmenl by lhe Owner to pay ihe Balance of Ihe Contract Price, lhe Surety is obligated, withouf duplication, for 74 lhe responsibilities of the Coniraclor for wnection of defective work and completion of the Conslmction Con�rac��, 7.2 adtlitional legal, design professional and delay msts resulling from Ihe Contractors Default, and resulling Gom lhe actions or failure to act of the Surety untler Section 5', and 7.3 liquidaled tlamages, or if no liquidated damages are specifed in Ihe Constmction Conlract, acNal damages caused by delayed performance or non-performance of the Contraclor. 8 If the Surety elects to act under Section 5.1, 5.3 or 54, the Surety's liability is limited to lhe amount of Ihis Bond. 9 The Surety shall not be liable lo Ihe Owner or others for obligalions of the Contractor that are unrelated to the Constmction Conlract, and the Balance of the Contract Price shall nol be retlucetl or set oH on acwunt o( any such unrelated obligations. No right of adion shall accme on lhis Bontl to any person or entity other than the Owner or its heirs, exewmrs, atlministrators, successors and assigns 10 The Surety hereby waives notice of any change, induding changes of time, to the Constmction Contracl ot to relaletl subcontrac4s, pumhase ortlers and other obligations. t1 Any pmceeding, legal or equitable, under Ihis Bond may be instituted in any court of competent juristliction in the localion in which the work or part of the work is localed and shall be instituled within hvo years after a declaration of Contrector Default or within lwo years after lhe Contractor ceasetl working or within hvo years after the Surery refuses or fails to perfortn its obligations untler lhis Bond, whichever occurs firs�. If the provisions of this Paragraph are void or prohibited by law, lhe minimum period of limitation available lo sureties as a defense in ihe jurisdiction of the suit shall be applicable. T�e Company execulin9 �h�s �ontl vouches iM1at this documen[ contorms to American IrmliWle ot Architecb Document A�13 - I010 Etlition GAIC Pcr(AJ12 (10/10) 12 Notice to ihe Surery, the Owner or the Contracror shall be mailetl or tleliveretl to the atltlress shown on the page on which their signature appears. 73 When this Bond has been furnished to comply with a staWtory or other legal requiremenl in ihe location where ihe constmction was to be performed, any provision in �his Bond conflicting with said staturory or legal requirement shall be tleemetl tleleletl herehom antl provisions conforming to such staWtory or other legal requiremen� shall be deemed incorporaletl herein. When so fumished, Ihe intent is Ihat Ihis Bontl shall be constmed as a SfaNtory bond and not as a common law bond. 14 De£nitions 74.7 Balance of Ne Contrecl Price. The total amount payable by the Owner to Ihe Contrector under ihe Constmction Contract aker all pmper adjustmenis have been matle, including allowance to the Contrector of any amounts received or to be receivetl by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper paymen�s made to or on behalf of ihe Contraclor untler the ConsUUCtion Contrect. 14.2 Construction ContncL The agreement behveen the Owner and Conlractor itlentifetl on lhe cover page, including all Coniract Documenls antl changes matle lo ihe agreement and the Con(ract Documents. 14.3 Conlractor Default. Failure of ihe Contreclor, which has not been remetlietl or waiveQ to pertorm or otherwise lo comply with a material term of lhe Construction Contrac[. 14.4 Own¢r D¢faWt Failure o( the Owner, which has not been remedietl or waivetl, to pay the Coniractor as required under the Construction Coniract or to perform and complete or comply with ihe other material terms of the Constmction Contracl. 14.5 Coniracl Documenls. All the tlocumwls that comprise the agreement between the Owner antl Contractor. 15 If ihis Bond is issued for an agreement between a Contractor and subwntrecror, the term Contractor in this Bontl shall be tleemed to be Subcontractor antl the term Owner shall be deemed to be Contractor. 'I6 Modifications to this bond are as follows: (Space is provitledbelow /or atltlifional signatures of added parties, otherthan fhose appeanng on the coverpageJ CONTRACTORASPRINCIPAL SURETY Company: (COrporate Seal) Company: (COrporafe Seal) SignaNre: — Name and Title: Address: SignaNre: — Name and Title: Address'. T�e Company ezecuting rols bontl vouches thal this Oocument conbrms [o Ameriwn Instl[ute of ArcNtects Oocument AN Y- 3010 Etlition GAIC Perf A312 (IO/10) eond No.no99iin ���E � GREAT AMERICAN INSURANCE COMPANY IXSURNICFBMU� OHIO Payment Bond Any singular reference to Contrac[or, Surery, Owner or o[M1er party sM1all be consitleretl plurel where applicable. CONTRACTOR: (Name, Iegal5taN5 and adtlressf Maguiie Iron, Inc. PO Box 1446 SiOUx F3lls� 5� 59101 OWNER: (Name, legal status and adtlress) City of Oehkosh, Wisconsin PO Hox 1130 Oshkosh, WI 54902-1130 SURETY: (Name, legal sfatus and pnncipal place of business) Grea[ American Insuaance Company 3460 Washington Dsive, Sui[e 20B Eagan, MN 55122 CONSTRUCTION CONTRACT Datel January 13, 2016 Art10U0C Two Hund[ed Twenty One Thousand Seven Hundred Ninety and m/100 ($221,]90.00) Descriplion: Southwes[ Water Tower Interior Painting (NameantllOCationJpublic Works Contract No. 16-10 Oshkosh, Wisconsin BOND oate' January zo, zois (NOt eatlier than Constmction Confract Date) AmO�nC Two Hundred Twenty One Thousand Seven Hundred Ninety and no/100 ($221,090.00) Modifications to this Bond: � None ❑ See Sec[ion 18 CONTRACTOR AS RINC Company: (COPOrere Seap 1 Maguire Iron, I Signature: Name and Title�. � Gene Sones, Si., Pses�c}�nt SURETY Gompany (COrporete Seep GREAT AMERI I NCE COMPANY Signature. Name and Title: Kevin Ki'oeze, Attorney-In-Pac[ (Any addifional signafures appeai on the last page of this PeAOrmance Bond) (FORMFORMA710NONLY—Name,adtliessandtelephone) OWNER'SREPRESENTATIVE: AGENT or BROKER: (Architec( Engineerorotherparty) 9oen & Associates, Inc. PO Box 89010 Sioux Falls, SD 5"1109 Phone: 605-336-0425 TM1e Compeny executing tM1ic bontl vouches that this document conbrms to American InstlWle oi Archi[ecfs Document A312 - 3010 Etlltlon GNC Pym[ 4JII (IOAO) t The Conlractor and Surery, jointly and severally, bintl themselves, [heir heirs, executors, administrators, successors antl assigns to the Owner to pay for labor, materials and equipment furnishetl for use in Ihe performance of the Construction Coniract, which is inwrporeted herein by reference, subject to lhe fallawing lerms. 2❑ Ihe Contractor promptly makes payment of all sums tlue to Claiman�s, and defentls, indemnifies and holds harmless the Owner hom claims, tlemantls, liens or sui�s by any person or entiry seeking payment for labor. materials or equipment furnishetl for use in the performance of the Constmction Contrect, ihen the Surery and the Conirector shall have no obligation under this Band. 3 If there is no owner Default untler the Constmction Contrec�, ihe Surerys obligation ro the Owner untler ihis Bond shall arise afler the Owner has promptly notified lhe Contractor antl the Surery (at the address tlescribetl in Section �3) of claims, demantls, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment fumished for use in ihe performance of the ConstmIXion Coniract and �endered defense of such claims, demands, liens or suits to Ihe Con�ractor antl ihe Surery. 4 When the Owner has satisfied Ihe wntlitions in Section 3, ihe Surety shall promptly and at ihe Surery's expense tlefentl, indemniry and hold harmless the Owner against a duly tendered claim, tlemanQ lien or suit. 5 The Surety's obligalions to a Claimant under this Bontl shallarise atterihefollowing: 5.1 Claimants, who tlo not have a direct contractwith the ConVacbr, .� have fumishetl a written notice of non-payment to the Contrac[or, stating with substantial acaracy the amount claimed and Ihe name of the party ro whom �he materials were, or equipment was, fumished or supplied or for whom Ihe labor was done or per(ormed, within ninety (90) days after having last performed labor or last fumished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the atltlress described in Section �3). 5.2 Claimanls, who are employed by or have a tlirect conVar.t with ihe ConUactor, have sent a Claim to the Surety (at the address describetl in Section 13). 6 If a notic_ o( non-payment required by Section 5.1.� is given by lhe Owner to [he ConVactor, lhat is sufficient to satisf; a ClalmanPS obligation to fumish a written notice of non-payment under Sec�ion 5. i. i. 7 When a Claimant has satisfied the conGitions of Sections 5.1 or 52, whichever is applicable, the Surety shall pmmpHy and at Ihe Surety's ezpense take the following ac�ions' 7.7 Send an answer to the Claimant, wi�h a copy to lhe Owner, wi�hin sixty (60) days aRer receipt of the Claim, stating the amounts that are undisputed antl the basis for challenging any amounts that are dispu�ed; and 72 Pay or arrenge for payment o( any undisputed amounis. 7.3 The Surety's failure to discharge its obligalions under Section 7.1 or Section 72 shall not be tleemed to constitute a waiver of defenses Ihe Surety or Contrac�or may have o� acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reachetl agreement It, however, the Surety hils �o discharge its obligations under Section 7.1 or Seclion Z2, �he Surety shall intlemnify the Claimant (or ihe reasonable attorney's fees �he Claimant incurs thereaker to recover any sums found to be tlue ana owing ro the Claimant. 8 The Surety's total obligation shall not exceetl the amount of this Bond, plus ihe amount of reasonable attomey's fees pmvitletl untler Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surery. 9 Amounts owed by the Owner to Ihe Coniraclor under the Constmction Controct shall be used for the peAormance of the Constmction Contract antl to satisfy claims, if any, under any construction performance bontl. By the Contrac�or fumishing antl the Owner accep�ing Ihis Bontl, they agrea that all funds eamed by Ihe ConUacror in ihe performance oflhe Construction Coniract are dedicated to satisfy obligations of the Contractor and Surery under Ihis Bond, subjecl to the Owner's prioriry [o use the funtls for the completion of ihe work. 10 The Surery shall not be liable to the Owner, Claimants orothers Porobligations of Ihe Contractor ihat are unrelated to the Constmction Coniract. The Owner shall not be liable for the payment of any cos�s or expenses of any Claimant under ihis Bond, antl shall have untler this Bond no obligation to make paymenis tq or give notice on behalf of, Claimants or otheiwise have any obligations to Claimanis under this Bontl. 77 The Surety hereby waives notice of any change, including changes of time, to the Cons�mc�ion Coniract or to relatetl subcontracts, purchase orders and other obligations. 72 No suit or action shall be commenced by a Claimant unGer this Bontl olher than in a court of competent junsdiction in the state in which lhe projec[ Ihat is �he subject of the Constmc[ion Con�ract is locatetl or after the expiration of one year from the date (�) on which the Claimant sent a Claim to ihe Surety pursuant to Section 5.1 2 or 52, or (2) on which �he last labor or senice was pertormed by anyone or the last materials or equipment were furnished by anyone untler the Consimction Coniract, whichever of (1) ar (2) first ocwrs. If the provisions o( Ihis Paragraph are void or pmhibited by law, the minimum periotl of limitation available lo sureties as a de(ense in the jurisdiction olthe sui� shall be applicable. 13 Notice and Claims to the Surety, the Owner or Ihe Contrector shall be mailed or delivered to the atldress shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be suffcient compliance as of the tlate received. 14 When this Bond has been furnishetl ro comply wi�h a statutory ar other legal requirement in the location where the constmction was to be performed, any provision in this Bond wnflic�ing with saitl staWmry or legal requirement shall be deemed deleted here(rom antl provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, Me intent is Ihat this Bond shall be o�nstruetl as a staW�ory bontl and nol as a common law bontl. 75 Upon request by any person or entity appeanng to be a potential bene(ciary of ihis Bontl, the Coniractor and Owner shall promptly fumish a copy of Ihis Bond or shall permit a copy �o be made. TM1e Company exxuHng [hia bontl vouc�es that this tlocumenl conbrms ro American InstiN[e of Archi[ects Oocument A31 Y- 3010 Etlitlon GAIC Pymt A312 (10/10) 2 �6 D¢Flnitions i6A Claim. A written statement by the Claimant indutling at a minimum�. .1 the name of the Claimant; .p the name of �he persan (or whom ihe labor was done, or materials or equipment fumished; ,3 a wpy of ihe agreement or purchase ortler pursuant to which labor, materials or equipment was Pornishetl for use in lhe performance of the Construction Coniract .4 a brief tlescription of lhe labor, materials or equipment furnished', .5 the tlate on which Ihe Claimant last performed labor or las� fumished ma�erials or equipmen� for use in ihe performance of ihe Consimction Contract, .6 Ihe to�al amount earned by the Claimant for labor, materials or equipment fumished as of the dale of the Claim; 7 the total amount o( previous payments received by the Claimant, antl .8 the total amount due antl unpaid to the Claimant for labor, materials or equipment fumished as of the date of the Claim. 16.2 Claimant. An individual or en�ity having a direct contract wilh lhe Contractor or with a subcontracror of Ihe Contractorb fumish labor, materials or equipment for use in ihe performance of the Construction Contract. The term Claimant also inclutles any intlivitlual or entity t�at has nghHulry assertetl a ciaim under an applicable mechanic's lien or similar statute against the real pmperty upon which the Project is localetl. The intenl of this Bond shall be lo indutle without limi[ation in the terms "labor, materials or equipment" Ihat part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment usetl in the Consimction Coniract, architectural antl engineering services required (or pedormance of the work of the Contractor and the Contraclols subcontractors, antl all other items for which a mechanic's lien may be assehed in the jurisdiction where the labor, materials or equipment were (urnished. '16.3 Consimction Con4acL The agreement behveen the Owner antl Contractor itlentified on ihe cover page, including all Contract Dowmenls and all changes matle to the agreement antl the Conlract Documenis. '16.4 Owner D¢faWL FaiWre of Ihe Owner, which has not been remedied or waived, to pay the Contractor as requiretl untler ihe Consimction Contract or to perform and complete or compty with Ihe other ma�erial terms of the Constmction Contrect. 16.5 Contract Documents. All the documents Ihat wmprise ihe agreement between Ihe Owner and Contraclor. 77 I( this Bond is issuetl for an agreement belween a Contractor and subwn[ractor, the term Coniractor in ihis Bond shall be tleemetl to be SubwnVacror antl the term Owner shall be deemetl to be Contractor. 78 Modifcalions to this bond are as follows'. (Space is provitled below for adtlitional signatures o/ atltletl pariies, other than those appearing on the cover page ) CONTRACTORASPRINCIPAL SURETY COmp2ny. (COryoate Seal) Company: (Corporafe Seal) Signature: — Name antl Title: Atltlress'. Signature: Name and Title'. Address: TM1a Cempany executing Nia bontl voucM1as IM1at tM1ia tlocument con(orma to Ameticen Inn[RUIe oi Archllecb Document A312 - 2010 EEltlon GAIC Pyml A312 QO/10) GREAT AMERICAN INSURANCE COMPANY� AtlminislretiveOHiee: 301E4TMSTREET � CINCINNATI,OHI095202 � 573-389-5000 � FAX573-723-2740 The number of'persons au�hori>ed by this�werofattomeyismtmorctlmn FOUR No.O 16690 POW ER OF.4"fl'OHVEY KNOW'ALLMENeVTHESEPRESENI'S Iha�@cGRLATAMC.RICANINSURANCEWMPANY,awryurationmganizcdandexistingunder anA by rirtue ofNe laws of che Stam of Ohio, does heaFy nnmina�e, mnsciw�e end appoint the person or persons named below, each individually if more �han one is named, ics we and IawPol atmmey-imfed, for it and in its vume, placc and s�cad to execure on behalfof fie said Company, u surety, any and ell Mnds, undenakings end convacls of suret}sltip, or oNer writ�cn oblieations in Ne naNre �hereof. provided Ihat �hc liability uf Ne said Company on any mch Mnd, undertaking or convaz� nfsure[}shi0 exewred undenM1is auNoriry� shall no� exceed Ne limi� stemd bclow. V ame Address Limit of Power KEVIN KROEZE MICHAEL M. MAHAN qLL OF ALL SONDftABOWDEN VANCARMODV SIOUXFALLS, $100,000,000.00 SOUTH DAKOTA IhisPOwttofA�mmeyrevokeselipreviouspowe uedonbehalfofNeatwmey(s)-imfactnamedabove. IN W ITNESS WHEREOF IAeGREATAMERICAN INSURANCE COMPANV has ceused Nesepruen¢ m be signed �d anesred by fk apOroO��a�e otHcers a�d i�s cnrporale senl Aercw�o aBixe� lM1is �TH �y �f AUGUST 2015 . Attcs[ CREATAMERICAN INSl1RANCE WMPANY ✓� 1 - ��`.� L C. � ���,G � ��, a.�...o., ��n,ary �� ,��".,o��,s��,o, �,« �..,se�, STA]F.OF OHip, (%JUNTY OF f1AMICfON - ss: onvio c. arcrvw �an-ar� aos� Un �i� �TH dyy of AUGlIST , 2015 , bcfore me personelly aOPeared DAVID C. KITCHIN, m me knmm, being duly swom, deposes and sayx Nat he resides in Cincinnati, Ohiu, tLet he is a Divisional Senior Vice President of Ne Bond Division of Grcat Amencan Insurance ComO�Y. �e Company described in end which executed the eWve mstrumrnt; Na� he knows Ne seal of �he seid Company; lha� Ne seal afiixed �u �he said inswmcm is such w�porare.veal�, Wat i� was so at5xed by amhori�y uf his office w�cr �hc By-Laws ofsaid Company, end Nat M1e signed his name thercw by like autAOnq. ��c� 1 /� � , , ,. Thie Pm�erofAnnmcy is granted by anthorin ol'Ihe Pollowiog msolmions udop�eJ by the doard ofDirettoa ofGmat American Inmranoe Company by uvaiimous wrfueu woseo� dale� lune 9, 2008. RESOLVED_ Tha( the Dlvh�o.w/ President, the severa! �ivisia.ml Senlor i ece P.rsidenra. OPolsiow/ Vke Pruidenle md Dro(soml Aestrmnr Vlee Presidema, or nny one ofihem, be and hereby is au�horced jrom eime m nme, ro aypoint one or more Aimrneys-in-Fact m uecure on beMlfojthe Campa.ry urery mry a.da!( DoWr, unde.mkinRS ardconnacn ojsurerysh�p, or oeMr wrirren obl�gaeiaru m ehe nawe ihereoj� m preecnFre their reapearoe duiies and rhes.espenive llmin ofrheir owlrorlry; and m revoke mry auch appomtmem al a�ry eime. RESOLVED FURTHER Thai ihe Comparq� seal oM �he s�gwrure ofairy oJihe aJoresatd �rers oMany Seeretary or Aasiamnt Seraeeary ojiM Company moy be �ed by faa:rimile ro mry pav�er I�rornry m rerthmte o/eirher gNen Jm ihe eseeurmn o/any bond, undermkmg co�nacr ajamery.ehry, ro�her wri�ren obl�gation in Me m�lure thereoJ, such eignamse and eea( when eo vsed heing he.eby adopledGy �he Comparry as the oreglnaf siynanve ofsuch �cer and ehe origmo7 sed I�hr Compo.ry m be vnLd arcd bmdtng upon rhe Compam� wi�h ihe same jurcr and � c� os �hough manualty �eQ CER'fIFICATION i, STBPHEN C BERAHA, Assislam Seaetary offiaa� American Insurence Company, do hereby certify N& Ne foregoing Powrr nfAtlomey end the Resolutions of the BowJ of Direcmrs oflune 9, 2008 have no� been revoked and ere now in fWl force unJ effec[. Signeda�dsealedthis 20th dayof Januaiy .. . ��.� siozsnriosns 2016 . '��..�. �.� ACKNOWLEDGMENT OF PRINCIPAL (Individual) STATE OF COUNTY OF ss: On this day of . in the year . before me personally come(s) . t�own m me ro be the person(s) who (is) (are) describeA in and who executed the foregoing inswment and acknowledge(s) ro me that he/she executed the same. NOTARY PUBLIC ACI{NOWLEDGMENT OF PRINCIPAL (Partnership) STATE OF _ COUNTYOF On [his day of , in [he year , before me personally come(s) a member of[he co-parmership of known lo me ro be the person who is described in and who exewted the foregoing instrument, and acknowledges m me that he/she executed [he same as and for [he act and deed of [he said co-parmership. NOTARY PUBLIC ACKNOWLEDGMENT OF PRINCIPAL (Corporation) STATE OF South Dakota COUNTY OF Mircnehaha ss: On this 20i6 day of Januarv in the year 2016 before me personally come(s) Gene Jones. h. [o me known, who, being by me duly swom, deposes and says that he/she resides in Ihe City of Sio� Fa(Is. SD tha[ he/she is Ihe President of Moeuirelron. /nc. a corporation; [ha[ [he seal affixed ro Ihe said ire[rumen[ is such corporere seal; [hat i[ waz so affixed by the order of the Board of Directors of said mrporatioq and [hat he/she signed his/her name fiere[o by Iike order. My Commission Expires: n y/ 1 Iunei2,2019 ���.�V � ��/�%(L NOTARY PUBLIC ACKNOWLEDGMENT OF SURETY S'CA7'E OF Sou[h Dakam COUNTY OF MinnehaHa ss: On [his 20'b day of Jonuarv in the year 1016 before me personally come(s) Kwin Kroue Attomay(s)-in-Fac[ of Great American Insurance Comoanv with whom I am personally acquainted, and who, being by me duty swom, says that he/she reside(s) in Sioux Fa(!s SD [hat he/she is (are) the Attomey(s)-In-Fact of GreatAmerican Insuranre Comparrv the company described in and which execured Ihe within inswment; that he/she kriow(s) Ne corporete seal of such Company; and [hat the seal affixed [o [he within instrumen[ is such corporate seal and [ha[ i[ was affixed by order of Ihe Board of Direc[ors of said Company, and [ha[ he/she signed said instrumen[ as Attomey(s)-in-Fact ofthe said Company like ordec • MyCommissionExpires: � y1,JfLJ-LYi � ,�A�JV June 12, 2019 NOTARY PUBLIC '�`dRO� CERTIFICATE OF LIABILITY WSURANCE i�22�20° 6"' THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLV AND CONFERS NO RIGHTS UPON THE GERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELV OR NEGATIVELV AMEND, EXTEND OR ALTER THE COVERAGE AFFOR�EU BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A GONTRAGT BETWEEN THE ISSUING INSURER�S�, AUTHORI2ED REPRESENTATIVE OR PRODUCER, AND THE GERTIFICATE HOL�ER. IMPORTANT: If the certificate holtler is an A�DITIONFL INSUREO, [he policy�ies) mus[ be entloroetl. If SUBROGATION IS WAIVED, subject to lhe lerms antl conditions o/the poliry, certain policies may require an endersement A statemen[ on this certificala does not conter righ[s to [he certifica[e holtler in liev of such entlorsement(s . en000cea mr�rncr Linda Evans NAME' Hoen S Associates� Znc. vxoxs ,(605)336-0425 AKNO:(605)336-B1B] 307 W. 91st Street E."^�� .lindae@boenassociates.com PO BOX BBOSO INWRERSAFFO0.�INGCWEMGE NAILI{ Sioux Falls SD 57105 ixsuaean:United Fire S Casualt Com an 13021 ixsuxeo ixsuaeae:Travelers Pxo ert Casualt 5679 Maguire Iron, Inc. 6 Maguixe Tank� Inc. ixsuaenmZurich American Insurance Watertown Paint 6 Repair o£ South Dakota Inc irvsuxeRO�RLI Insurance Com an P� HOX 1496 INS�RERE: Sioux Falls SD 57101 ixsuaeer: COVERAGES CERTIFICATE NUM8ER:16/1] iaaster w/sR REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUEO TO THE INSUREO NHME� A90VE FOR THE POLICY PERIOD IN�ICATED. NOTlMTHSTAN�ING ANY REQOIREMENT, TERM OR CON�ITION OF ANY CONTRACT OR OTHER �OCUMENT WITH RESPECT TO WHICH THIS CERTIFlCATE MAV BE ISSUED OR MAV PERTAIN, THE INSURANCE AFFORDED BV THE POLICIES DESCRIBE� HEREIN IS SUBJECT TO ALL THE TERMS, EXC W SIONS AND CONDITIONS OF SUCH POLIGES. IIMITS SHOWN MAY HAVE BEEN REOUCEO BV PAID ClAIMS. INSR }ypEOFINSOMNCE pOLICYNOMBEP MM�oAYYY MMI�O�I'VYY IIMITS �m GENERALLIABILItt FACHOCCURRENCE 5 1�000�000 X COMMERCIPLGENERALLIP91LIiV pREMI ES�ESO�i�cv ence 5 ZOO�OOO A CIAIMSNJNE ❑X OCWR 64426099 /1/2016 /1/201] MEOE%P�Anyonepersan) 5 $�0�� X ContLdCival Llab InCl vER50NnLBAOVINJURV f 1,000,000 X XCU Incl GENERALAGGRECnTE f 2,000,000 GEN'LAGGFEGATELIMRAPPLIESPER'. PRO�UCT$-COMPIOPAGG 5 P�OOO�OOO POLICY X PA� LOC E POTOMOBRELIABILITY COMBINE�SINGLELIMIT 1 000 000 A X quvavro eooavirv�uar�aerpersm� a HLLOWNE� SCHEDUlEO 60<26094 /1/Y016 /1/2010 BO�ILYINJORY�PerecciEeni) 5 AUi05 h11i05 X HIRE�AUiO$ x q�OS�EO pBOP�ERN�PMPGE 5 �s unineureamotaislBlsliu'imn t 1 000 000 X UM6RELLAl1A6 X OCCUF FACHOCCVRPENCE 5 $i0�Di4�� B E%CESSOP6 CLAIMSMAOE AGGREGATE $ $�OOO�OOO oEO 'Y aEiENiIONf 10,00 Ue-15a95368-16 /1/2016 /1/20ll g Q WORMERSCOMPENSFTIOH X WCSiATU� OiW PNDEMPLOYEPS'IIABILITY �.�N ANYPROPRIEiORIPMiNERiE%ECIIiNEO N�p ELEALNPCCIOENT 4 1 OOO OOO OFFlCERIMEMBEP E%CW�E�) C9892936-05 /1/2016 /1/201] (ManEalorylnNH) E.L.�ISEPSE-EAEMPLOYE $ 1 000 000 nyai eeirnm �mer OESCPIPTIONOFOPEIiPTIONSCeIw ELDISFASE-POLICYLIMIi 5 1 000 000 D Buildexs Risk - Special ILM0903569 /1/2016 /1/2019 BuikinBSPlskperslmcWre 2�500�000 Cavses mcluding theft oae�nibia $2,500 �ESCPIPiION OF OPERPTION51 LOCA90NSNENICLES �Atlaa� ACOP0101� PCOl�lonal RemaA55[�e4ula� Ilmo�e ¢pace la requlnJ� PROJECT: Public Works Contxact No. 16-10� Southwest Water Tower Interior Painting� Oshkosh� Wisconsin City o£ Oshkosh, and its o££icare, council membere, agents, employees antl authorizetl volunteexa axa xdditional Insureds on tha genaral liability, and builders xisk when xequiratl by written contxact. SHOIILD ANY OF TNE ABOVE DESCRIBED POLICIES BE CANCELLE� BEFORE THE ESPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City Of OShk09h ACCOR�qNCEWRHTHEPOLICVPROVISIONS. Attn: City Clerk ?li Church Ave AIITHORIZEDREGRESENTBTNE eo Box 1130 oshkosh, wI 54903-1130 �� � Revin Kxoeze/LINOA AGORD 25 (2010105) O 1988-2010 ACORD CORPORATION. All rights reservei INS015�zoioos�.oi 7he ACOR� name antl logo are registered marks of ACOR� `�`°RO� CERTIFICATE OF LIABILITY INSURANCE i�22�20 6"' TNIS CERTIFIGATE IS ISSUEO AS A MATTER OF INFORMHTION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLUER. THIS CERTIFICATE DOES NOT AFFIRMATIVELV OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BV THE POLICIES BELOW. THIS CERTIFICpTE OF INSUI2ANCE OOES NOT CONSTITUTE A GONTRACT BETWEEN THE ISSUING INSIIRER�S�, AUTHORIZE� REPRESENTATIVE OR PRODIICER, ANO THE CERTIFICATE HOLDER. IMPORTANT: If [he certifiwte holtler is an ADDITIONAL INSUREO, the poliry�ies) mus[ be endorsed. It SUBROGATION IS WAIVEO, subject lo [he lerms antl contlitions of tlie policy, certain policies may require an entlorsement. A sWtemen[ on this certificale does mt con/er rights to lhe cerlifiwte holder in lieu of such endorsemen[(s�. P0.0�ULER �ONTAti L1I1[jd EV2R9 NAME. Hoen 6 Associates� Inc. vxoxe (605)336-0G25 F^x o.(605�336-BI64 307 W. 91st Straet Em^�� lindae@boenassociates.com PO BOX BBOLO MSUREPSAFFOHOINGLOVEqqGE NAICY Sioux Falls SD 57105 ixsureeaw United Fire 6 Casualt Com an 13021 ixsuaeo iusuaeae:Travelens Pro ert Casualt 56'/4 Maguire Iron� Inc. S Maguixe Tank, Inc. ixsuxeac:ZUrich American Insurance Watertown Paint & Repair of South Dakota Inc ixsursErso:RLI Insurance Com an PO BOX �.GAO INSUFERE: Sioux Falls SD 5'1101 iusuaear: COVERAGES CERTIFICATENUMBER:15/16 Mastax w/BR REVISIONNUMBER: THI515 TO CERTIFV THAT THE POLICIES OF INSORANGE LISTEO BELOW HAVE BEEN ISSUEO TO THE INSURED NAMEO ABOVE FOR THE POLICY PEftIOD IN�ICATEO. NOMATHSTAN�ING ANV REpUIREMENT, TERM OR CON�ITION OF FNY CONTRACT OR OTHER �OCIIMENT 1MTH RESPECT TO WHICH THIS CERTIFICATE MAY 8E ISSUED OR MAV PERTAIN, THE INSURANCE AFFORDEO BV THE POLICIES DESCRIBE� HEREIN IS SUBJECT TO ALL THE TERMS, EXC W SIONS ANO CON�ITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN RE�UCE� BV PAI� CLHIMS. INSR rypEOFIN50MNCE POLICYEFF POLICYE%G LiR POLICYNONBER MMIOOIYYYV MMI�OIYYYY LIMRS GENERALIIABILITY EpCHOCCVRRENCE $ S�OOO�OOO X WMMERCIALGENERALLIPBILIiY pqEMISE$ F.aoaurreree S SOO�OOO A CLAIMS�MAOE �X OCCUR 60426094 /1/2015 /1/2016 MEOE%G�Myoneperson) $ $�000 X mn[iac[ual Liab Incl pER50uu&aoVINJUaY $ 1,000,000 X %CU Ii�cl GENERALAGGREGAIE $ P�OOO�OOO GEMLAGGREG/iELIMRAPPLIESPER'. pROOlICiS-COMPNPAGG $ 2�000�000 FOLICV X PR� LOC S FIITOMOBILELIFBWTY Ea�BUN�ISINGLELIMR 1 000 000 A X pNyq�jd BO�ILVINJVRY�Pxp¢RM� $ PLLOWNEO $CHEPOLEO 60<2609< /1/2015 /1/2016 gO�ILYINJVRY�Paamtlanlf $ AUTOS AIfr05 X HIRE�AIROS X AUTOOVVNEO Pe�a¢itlenOAMAGE f �9 Vninsme]mola�islBlslillimi� � 1 QOQ ��0 X UM9RELfALIAB X OCCOR FACHOCCORflENCE $ S�OOO�OOO $ ETCESSLIA9 CIAIMSNA�E qGGREGNTE $ 5�000�000 DED X RETENTIONS 30�04 OP-15R95368-15 /1/2015 /1/2016 a Q WORNERSLOMYENSPiION X WCSTATU- OTM- ANOEMpLOYERS'IIPBILITY y�N ANYPROPRIRORIPPRiNERIE%KVTNE ELFACHACGOENi $ 1 OOO OOO OFFlCERIMEMBEF E%CIUDE@ � N�A �Man4abrylnNX) 4892936-OS �1/2015 /1/2016 EL�ISEASE-EAEMVLOYE S 1 ��0 �OQ � BCRIPTI NOFOVEMTIONSbelaw tLOISFASE�POOCYLIMIT S 1 000 000 D evildars Risk�- Special umv03569 /1/2015 /i/2o1s auuatr�saisxperswn�,e 2,500,000 Causes including the£t oea�a�bie $2.500 OESCRIViION OF OVEIiATIONSI LOCFiIONS I VENICLES �AXa[� ACOR0101� Ptldi�loml Rem+Ax $oM1eEUla� Ilmore spa<e Is reOUIrcJ� PROJECT: Public Works Contzact No. 16-10, Southvast Water Towez Interior Paintinq� Oshkosh� Wisconain City o£ Oshkosh, and ite o£ficars, council mesbers� aqenta� employaes and auGhorized voluntaers a Additional Insurads on Ghe general liability, and builders riek when xequired by wxitten contract e CERTIFICATE HOLDER CANCELLATION SHOIILD ANY OF THE ABOVE �ESCqIBED POLICIES BE CANCELLED BEFORE THE E%PIRATION OATE THEREOF, NOTICE WILL BE DELIVEREO IN ACCORDANCE W ITH THE POLICV PROVISIONS. City of Oshkoah Attn: City Clerk 215 Church Ave nulxowzeoaeeaeseNrnrrve PO Hox 1130 Oshkosh, WI 54903-1130 ��� � Kevin Rxoaee/LINDA ACORD 25 (2010/O5) OO 7988-2070 ACORD CORPORATION. All rights resenetl. insu[a�m�oos�m TheAGOBDnameantllogoareregisteredmarksofACORD Ra[ng Seevices Mome Ralin95 . n Recenl0.alinS P.9viH . n Seamli �or a Raling FatingsbyRegon . Fatin9Pmcess&�e9nitions . . ,weema�emse::r:aati�a. �. .c�aema.n'iaews� . + Financial Stren9N Raling 6ulde er eree� aan�y �mae �e aati�s cmae � Na:lo0al5mle RaGng Guitle • Caun�ry ftisM Informellon � MaM_I Seqmenl Oullmk ftating MetM1Oaolagy IntlustryResearcM1 .� IntlustryBMarFetWn�ers. � Contact an Anayst Comer esBNenb > � . pwartls BCRecogni[ions �ala5ubmission Wnte� ... Regularory lnformation . �Fiv t �d¢Rmig I e��eraco�camr�er,� 0 �,nma��ee=e-2n �... �A.M Best Ra�ng SerWCes Gontac:ln7xna5cr u ] Of 2 &a ��mi: a-,�� �, r. __ _— — Great American Insurance Company m 0.M.BUU:00]]ll NNCf.16691 FEINO]IDSOIIA OomtiliaryAtldrts As�netlN A r�"�"� . aw E. ro�nn S�t� ees. � CincinnaY.OH452@ ompenies "� MSUpXw u�nea s�a�es mama.e, ropm� s�pe��aeiiirym'. W¢b: �a e meeuM1eirongoinglnsumn¢ pbone:51Y369-5400 n obllgations. Fac 513-369-]fi00 � �� - � � �� BasetlonA.M.Beslsanelysis, 5 -A F'nacalGmuolnc'nNeAMBN[imataParenlantlltlenMieSNeWpmoS[en�ity ofNecoryoratesWCN�e.Viewalis[ot�M�(n wWeslnIDiss[meture. Ratin9: A*(SupatioQ Financial5lze %III (E125 Billlon W St 5 La[egory: 8illlon) ONlook � Slable q�p�_ AR�metl EHecYVeOe[a: Ma¢tilO,P��5 Inl6alRatlngDaU: SeplemEer30,f908 Lon9-Tertn: aa- Ou�ook; S�aWe Fction: Afli�med EMecGVe �ate: MamM1 30, 20t5 InitislRaGn9�a[e: Junei].2005 Isauetl by: AM. Best Com(any. Inc. Financial Amlynt MicM1ael W Russo m[ Vice Presitlent Jennder Mars�all, CP W, ARM ,�� �9ewA.M.BezPS �' m5btement 6 A R' nFna�alGm '�4 �''� p /� SubsEarre � M nzo,mis . w�o �N N.M.�Best �as pmvideE�2ting5 4 anelysis on �M1ls company aln ¢ 1908. IFlnanciel5Mn9a' 'iLOna-TnmissuerReEil :''..EHeCWa��n Ra�ing�. .'...EXeCfve0alB Ralinp ....�13I202015 Aa ��.'.,.3/30/2015 - ��� '...vzvzou n+ ��'vzvzma '�, ��'.,'L2]2013 A �'2/292013 � I � '1129204 A I3/29Q012 � �'� .�'..,y16/20fl N IP/1C/201t � I. a a !uiorzom ,_� sim?o�o �,.:..._.�—_ �... �.....,.. ... � . .. . .. .._____._._.._...,<...,....m,�cun.n��nres�oomvia.nnmoaianaanaM�viaauon.mnsoraeieaar i AMB.Y CompmY�'�me 005�99 GreatAmentanlnsurenaCOmpanies(5G) RepresenlsNeAM.BestCOnsoliEateGfinancialslorNePmpeM/Cesualty bus eaSN��islegalentlly. 081pCbGreatAmetlwnlnsuranaCOmpanyCAB kepr.senbNePmpertylCesualryfinancialsbrMeCanatla6ranc�of��i5 Iegalen0ry. 9C]6dGreafAmemm�lnsuranceCOmpany(5G8) ReprasenlsNePmPeM/CasualryfinancielsforNeSingaporcBnnchof 9 N (�. AMBpeEkReoort-IncWEes6ezfsFinancial50-enpMRatlnganUrationalealon8w�wmprebensiveanalylical �y�_.:� mmmen�ary,tletaileEbusinessoverviewanEkeylinancialtlate. ftepoN Redsion Oala 652015 (represenb ��e IaLSt signifitan[ change). . ' HistonralReponsareavallaEieln �ed Artlive �,� Uewatltlifional � antlorotluc6forllilscompany.