Loading...
HomeMy WebLinkAbout2015 Section 5339 Capital assistance Grant�A +M 2015 SECTION 5339 CAPITAL ASSISTANCE GRANT AGREEMENT BETWEEN THE STATE OF WISCONSIN, DEPARTMENT OF TRANSPORTATION AND THE CITY OF OSHKOSH This Grant Agreement is made by and between the State of Wisconsin, Department of Transportation, hereinafter referred to as "Department" and the City of Oshkosh, hereinafter referred to as "Recipient." PRELIMINARY STATEMENT The Department is authorized by sections 85.20 (3) (d) and 85.23, Wisconsin Statutes, to administer the Federal Small Urban and Bus and Bus Facilities Program authorized under 49 U.S.C. § 5339. The purpose of this program is to promote the general public good by providing financial assistance to surface public transportation systems operating in areas other than urbanized areas. The Recipient has requested funds to assist in financing capital purchases under this program. The Department agrees to provide financial assistance with program monies made available under 49 U.S.C. § 5339 in accordance with the terms and conditions of this Grant Agreement. The Project is financed with appropriations for transit capital assistance for the Bus and Bus Facilities Program authorized by 49 U.S.C. § 5339 (CFDA 20.526). In consideration of the reciprocal promises expressed in this Grant Agreement, the Department and the Recipient mutually agree as follows: Article I: Payment by the Department A. Payment under the terms of this Grant Agreement is based on 49 U.S.C. §5339, as amended, and the Wisconsin Administrative Code, Chapter TRANS 6. B. The Department agrees to pay the Recipient $360,000.00, or 80 % of the purchase price, whichever is less of the items specified in Attachment A, Project Budget. Project Budget Quantities are limited to the number shown in the quantity column in Attachment A. C. The Department shall make payment to the Recipient upon receipt of invoices prepared by the manufacturer or dealer showing the actual costs of purchased equipment or in the case of a construction project, upon receipt of invoices in accordance with the payment schedule as specified in the construction contract. Progress payments on capital equipment would be made only at the discretion of the Department and in compliance with all applicable federal requirements. D. If the Department's audit establishes that payment to the Recipient under the terms of this Grant Agreement has exceeded the allowable maximum as defined in Article I.B., the Recipient shall refund to the Department upon demand a sum sufficient to reduce the .^ payment to comply with Article I.B of this Grant Agreement and with Chapter TRANS 6.03, Wisconsin Administrative Code. E. Consistent with Articles I.B and notwithstanding other provisions of this Grant Agreement, the Department may reduce the payments otherwise due under paragraph B of this article. The Department under this paragraph may reduce those payments only by an amount equal to any overpayments made to Recipient under this Grant Agreement or under any prior capital assistance Grant Agreement. The Department may determine the amount of any such overpayment by conducting an audit under Article III. If the Department finds an overpayment, the Department may set off that overpayment against the amount payable to Recipient under paragraph B of this article until the amount payable under paragraph B of this article equals the overpayment. Article II: Responsibility of Recipient A. The purchase of all equipment and facilities financed pursuant to this Grant Agreement shall be undertaken by the Recipient and shall be in accordance with applicable state and federal laws and regulations. The Master Agreement between the State of Wisconsin and the Federal Transit Administration (FTA) contains all required clauses that should be included in agreement between the State of Wisconsin and the Recipient and said Master Agreement is therefore included in this agreement by reference. (An online version can be fOUridathttp://www.fta.dot.gov/documents/21-Master.pdf.) Projectequipment, facilities, and construction projects shall be purchased or constructed in accordance with the appropriate procedures as specified in the Wisconsin Department of Transportation Procurement Manual online at http://www.dot.wisconsin. gov/localgov/docs/procurement.pdf B. The Recipient shall complete all projects included in this Grant Agreement witlzin a period of two (2) years from the date of execution. If the Recipient fails to complete a given project(s) within the two (2) year period, the Department shall take necessary actions to withdraw any remaining uncommitted funds in the Grant Agreement at that time. The uncommitted funds may be reassigned to other subrecipients or surrendered to the federal government. C. Title to project equipment and rolling stock shall be in the name of a public body, subject to the restrictions on use and disposition of the project equipment and rolling stock set forth herein. The title holder shall ensure that the Department is listed as a secured party when application for title/registration is originally filed. Copies of form MV-1, Application for Title/Registration, must be filed with the Bureau of Transit and Local Roads before reimbursement of the federal share of the cost for any rolling stock is processed for payment. D. The Recipient may not execute any transfer of title, lease, lien, pledge, mortgage, encumbrance, contract, grant anticipation note, alienation, or other obligation that in any way affects the federal interest in any project real property or equipment. Nor may the Recipient obligate itself, in any other manner, to any third party with respect to project real property or equipment, unless such transfer of title, lease, lien, pledge, mortgage, encumbrance, contract, grant anticipation note, alienation, or other obligation is expressly authorized in writing by the Department; nor may the Recipient, by any act or omission, adversely affect the federal interest or impair the Recipient's continuing control over the use of project real property or equipment. E. The Recipient agrees that the project equipment and rolling stock shall only be used for the provision of transportation service to the general public and rolling stock shall be clearly marked for public use. The Recipient shall keep satisfactory records with regard to the use of the equipment and rolling stock and submit to the Department upon request such information as may be required to assure compliance with this section. Project equipment and rolling stock shall be operated only within the transit service area described in the capital and operating grant applications that are made part of this Grant Agreement by reference for the duration of its useful life. If during the useful life, the project equipment and rolling is withdrawn from transportation service, the Recipient shall immediately notify the Department and request disposition instructions. F. The Recipient shall develop a written maintenance plan in accordance with Department requirements and shall perform preventive maintenance on the equipment, facilities, and rolling stock purchased with FTA funds, including accessibility equipment, at a level no less than the manufacturer's recommended specifications. Adequate records of preventive maintenance on each piece of equipment, rolling stock, and facilities shall be maintained by the Recipient. The equipment, facilities, and rolling stock shall be properly maintained at all times. The Department shall have the right to conduct periodic inspections and reviews for the purpose of confirming that proper maintenance policies and procedures are being followed. G. The Recipient shall make available the equipment and rolling stock including maintenance and/or usage records to the Department upon demand for the purpose of an annual verification or other inspections deemed necessary by the Department. H. The Recipient shall immediately notify the Department in all cases where project equipment or rolling stock is used in a manner substantially different from that described in the application. The Recipient shall obtain prior written concurrence from the Department for any proposed sale of equipment or rolling stock, title transfer, or lease to another agency. I. The Recipient shall maintain in an amount and form satisfactory to the Department such insurance or self-insurance (including property, personal injury and collision coverage) as will be adequate to cover the current value of project equipment and rolling stock throughout the period of required use. The Department reserves the right to require the Recipient to restore equipment and rolling stock or pay for damages to the equipment and rolling stock as a result of abuse or misuse of such equipment and rolling stock with the Recipient's knowledge and consent. Article III: Records and Audits A. The Recipient shall have a single, organization-wide, financial and compliance audit performed by a qualified independerit auditor if required to do so under federal law and regulations. See federal Office of Management and Budget (OMB) Super Circular 2 CFR 200. B. This audit shall be performed in accordance with OMB Super Circular 2 CFR 200 and state single audit guidelines issued by the Wisconsin Department of Administration (DOA). C. The Recipient agrees to maintain appropriate accounts and records relating to this transportation project. Such accounts and records will be made available upon request to the Department for inspection and audit purposes. D. The Recipient shall permit the Department, The Comptroller General of the United States, and The Secretary of the United States Department of Transportation, or their authorized representatives, access to inspect: (1) all vehicles, facilities, and equipment purchased by the Recipient as part of the project; (2) all transportation services rendered by the Recipient by the use of such vehicles, facilities, and equipment; and (3) all relevant project data and records. The Recipient shall also permit the above-named agencies to audit the books, records, documents, and accounts of the Recipient pertaining to the project. Article IV: Labor Protection The Recipient agrees that it will comply with the terms and conditions of the Special Section 5333(b) Warranty for Application (formerly known as Section 13(c)) to the Small Urban and Rural Program as promulgated by the U.S. Department of Labor. The Recipient further agrees that it will assume all legal and financial responsibility relative to compliance with the terms and conditions of the Warranty. Article V: Prohibited Interests A. No member of or delegate to the Congress of the United States shall be admitted to any share or part of this Grant Agreement, or to any beneiit arising there from. B. No member, officer, or employee of the Department or of the Recipient during his or her tenure or for one year thereafter shall have any personally benefiting interest, direct or indirect, in this Grant Agreement or the proceeds thereof. Article VI: Applicable Law This Grant Agreement is governed under the laws of the United States, State of Wisconsin and Menominee Tribal Law. In the event any conflict in these laws may arise relating to the obligations tulder this Grant Agreement, the affected parties shall meet and resolve the conflict with tlie intent of each fulfilling the terms of this Grant Agreement. The Recipient shall at all times comply with 4 and observe all federal and state laws, local laws, ordinances, and regulations which are in effect during the period of this Grant Agreement and which in any manner affect the work or its conduct. Article VII: Safety Requirements All materials, equipment, and supplies acquired through this Grant Agreement by the Recipient, must comply fully with all safety requirements as set forth in law or rule by the State of Wisconsin and all applicable Occupational Safety and Health Administration Standards. Article VIII: Dispute Resolution Any claim, counterclaim or dispute arising out of or relating to this Grant Agreement may, by mutual consent, be resolved by the parties as they may mutually agree by any form of alternative dispute resolution process. Article IX Privacy Act The recipient agrees to comply with, and assures the compliance of its employees with, the information restrictions and other applicable requirements of the Privacy Act of 1974, 5 U.S.C. § 552a. Among other things, the recipient agrees to obtain the express consent of the federal government before the recipient or its employees operate a system of records on behalf of the federal government. The recipient understands that the requirements of the Privacy Act, including the civil and criminal penalties for violation of that Act, apply to those individuals involved, and that failure to comply with the terms of the Privacy Act may result in termination of the underlying contract. The recipient also agrees to include these requirements in each subcontract to administer any system of records on behalf of the federal government financed in whole or in part with federal assistance provided by FTA. Article X: Noti�cation of Federal Participation The recipient must include the following notification language of federal participation in all its requests for proposals, solicitations, contracts, press releases, brochures, web site, or other publications, etc. funded under this grant: "This project is expected to have 80% of funding provided by the Federal Transit Administration under 49 USC §5339 (CFDA 20.526)." Article XI: Department Approval of Contracts and Procurements The Department shall be in receipt of all draft procurements for services mentioned as part of this Grant Agreement, as well as any contracts between the Recipient and any vendor that is slated to receive funds under this Grant Agreement. The Department shall review such draft contracts and determine their conformance with the provisions of this Graut Agreernent. Upon authorization by the Department, the Recipient and the Transit System may execute such contracts. Article XII: Termination A. The Department may terminate this Grant Agreement at any time that the Secretary determines that the Recipient or their subcontractor has failed to perform in the manner called for in the contract or has failed to fulfill contract obligations. Failure of the Recipient or their subcontractor to comply with the terms and conditions of its grant application and/or the provisions of this Grant Agreement shall be considered cause for termination. B. The Recipient may terminate this Grant Agreement if so directed by their appropriate governing body for whatever reason such request to terminate is made. C. Both parties agree that notice of intent to terminate the Grant Agreement shall be made in writing through "return-receipt certified mail," at least 30 calendar days prior to the proposed termination date. D. Upon termination of this Grant Agreement under the provisions of paragraphs A, B or C of this Article, the Recipient agrees to dispose of the project facilities, equipment, and/or rolling stock, in accordance with Wisconsin Department of Transportation instructions. Article XIII: Attachments and Appendices All attachments and appendices to this Grant Agreement are incorporated herein by annexation. The Recipient agrees to comply with the standard federal contract clauses listed in Appendix I. Witness the execution of this Grant Agreement by the parties hereto in the manner most appropriate to each. STATE OF WISCONSIN DEPARTMENT OF SPORTATION By: Aileen Switzer, A ministrator Division of Transportation Investment Management Date: �� ���'� 6 CITY OF OSHKOSH By: SEE ATTACHED PAGE Title: Date: IN WITNESS THEREOF, the parties hereto have caused this Agreement to be executed by their respective proper officers and affixed their corporate seals hereto as of the day and year first above written. CITY OF OSHKOSH �� MA K A ROHLOFF CITY MANAGER _ � _, i �, '; �;�.�� �� � . - ;�%�� PAMELA R. UBRIG CITY CLERK APPROVED BY: �YN�V�. LOF�Iy� CITY ATTORNEY I hereby certify that the necessary provisions have been made to pay the liability which will accrue under this contract. �'�(��;� Ct A T� � ON TRENA LARSON FINANCE DIRECTOR Appendix I Federally Required Contract Clauses Required by the Federal Transit Administration Fly America Requirements Applicability — all contracts involving transportation of persons or property, by air between the U.S. and/or places outside the U.S. These requirements do not apply to micro-purchases ($3,000 or less, except for construction contracts over $2,000). Contractor shall comply with 49 USC 40118 (the "Fly America" Act) in accordance with General Services Administration regulations 41 CFR 301-10, stating that recipients and subrecipients of Federal funds and their contractors are required to use US Flag air carriers for US Government-financed international air travel and transportation of their personal effects or property, to the extent such service is available, unless travel by foreign air carrier is a matter of necessity, as defined by the Fly America Act. Contractor shall submit, if a foreign air carrier was used, an appropriate certification or memorandum adequately explaining why service by a US flag air carrier was not available or why it was necessary to use a foreign air carrier and shall, in any event, provide a certificate of compliance with the Fly America requirements. Contractor shall include the requirements of this section in all subcontracts that may involve international air transportation. Charter Bus Requirements These requirements do not apply to micro-purchases ($3,000 or less, except for construction contracts over $2,000). Contractor shall comply with 49 USC 5323(d) and (g) and 49 CFR 604, which state that recipients and subrecipients of FTA assistance may provide charter service for transportation projects that uses equipment or facilities acquired with Federal assistance authorized under the Federal transit laws (except as permitted by 49 CFR 604.2), or under 23 U.S.C. 133 or 142, only in compliance with those laws and FTA regulations, "Charter Service," 49 CFR part 604, the terms and conditions of which are incorporated herein by reference. School Bus Requirements These requirements do not apply to micro-purchases ($3,000 or less, except for construction contracts over $2,000). Pursuant to 69 USC 5323(f) and 49 CFR 605, recipients and subrecipients of FTA assistance shall not engage in school bus operations exclusively for transportation of students and school personnel in competition with private school bus operators unless qualified under specified exemptions. When operating exclusive school bus service under an allowable exemption, recipients and subrecipients shall not use federally funded equipment, vehicles or facilities. Energy Conservation All Contracts except micro-purchases ($3,000 or less, except for construction contracts over $2,000) Contractor shall comply with mandatory standards and policies relating to energy efficiency, stated in the state energy conservation plan issued in compliance with the Energy Policy & Conservation Act. Clean Water All Contracts and Subcontracts over $100,000 Contractor shall comply with all applicable standards, orders or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 USC 1251 et seq. Contractor shall report each violation to the recipient and understands and agrees that the recipient shall, in turn, report each violation as required to FTA and the appropriate EPA Regional Office. Contractor shall include these requirements in each subcontract exceeding $100,000 financed in whole or in part with FTA assistance. Lobbying Construction/Architectural and Engineering/Acquisition of Rolling Stock/Professional Service Contract/Operational Service Contract/Turnkey contracts over $100,000 Byrd Anti-Lobbying Amendment, 31 U.S.C. 1352, as amended by the Lobbying Disclosure Act of 1995, P.L. 104-65 [to be codified at 2 U.S.C. § 1601, et seq.] - Contractors who apply or bid for an award of $100,000 or more shall file the certification required by 49 CFR part 20, "New Restrictions on Lobbying." Each tier certifies to the tier above that it will not and has not used Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352. Each tier shall also disclose the name of any registrant under the Lobbying Disclosure Act of 1995 who has made lobbying contacts on its behalf with non- Federal funds with respect to that Federal contract, grant or award covered by 31 U.S.C. 1352. Such disclosures are forwarded from tier to tier up to the recipient. Access to Records and Reports Applicability — As shown below. These requirements do not apply to micro-purchases ($3,000 or less, except for construction contracts over $2,000) The following access to records requirements apply to this Contract: 1. Where the purchaser is not a State but a local government and is an FTA recipient or a subgrantee of FTA recipient in accordance with 49 CFR 18.36(i), contractor shall provide the purchaser, the FTA, the US Comptroller General or their authorized representatives access to any books, documents, papers and contractor records which are pertinent to this contract for the purposes of making audits, examinations, excerpts and transcriptions. Contractor shall also, pursuant to 49 CFR 633.17, provide authorized FTA representatives, including any PMO contractor, access to contractor's records and construction sites pertaining to a capital project, defined at 49 USC 5302(a)1, which is receiving FTA assistance through the programs described at 49 USC 5307, 5309 or 5311. 2. Where the purchaser is a State and is an FTA recipient or a subgrantee of FTA recipient in accordance with 49 CFR 633.17, contractor shall provide the purchaser, authorized FTA representatives, including any PMO Contractor, access to contractor's records and construction sites pertaining to a capital project, defined at 49 USC 5302(a)1, which receives FTA assistance through the programs described at 49 USC 5307, 5309 or 5311. By definition, a capital project excludes contracts of less than the simplified acquisition threshold currently set at $100,000. 3. Where the purchaser enters into a negotiated contract for other than a small purchase or under the simplified acquisition threshold and is an institution of higher education, a hospital or other non-profit organization and is an FTA recipient or a subgrantee of FTA recipient in accordance with 49 CFR 19.48, contractor shall provide the purchaser, the FTA, the US Comptroller General or their authorized representatives, access to any books, documents, papers and record of the contractor which are directly pertinent to this contract for the purposes of making audits, examinations, excerpts and transcriptions. 4. Where a purchaser which is an FTA recipient or a subgrantee of FTA recipient in accordance with 49 USC 5325(a) enters into a contract for a capital project or improvement (defined at 49 USC 5302(a)1) through other than competitive bidding, contractor shall make available records related to the contract to the purchaser, the Secretary of USDOT and the US Comptroller General or any authorized officer or employee of any of them for the purposes of conducting an audit and inspection. 5. Contractor shall permit any of the foregoing parties to reproduce by any means whatsoever or to copy excerpts and transcriptions as reasonably needed. 6. Contractor shall maintain all books, records, accounts and reports required under this contract for a period of not less than three (3) years after the date of termination or expiration of this contract, except in the event of litigation or settlement of claims arising from the performance of this contract, in which case contractor agrees to maintain same until the recipient, FTA Administrator, US Comptroller General, or any of their authorized representatives, have disposed of all such litigation, appeals, claims or exceptions related thereto. Re: 49 CFR 18.39(i)(11). FTA does not require the inclusion of these requirements in subcontracts. Federal Changes All Contracts except micro-purchases ($3,000 or less, except for construction contracts over $2,000) Contractor shall comply with all applicable FTA regulations, policies, procedures and directives, including without limitation those listed directly or by reference in the Master Agreement between the purchaser and FTA, as they may be amended or promulgated from time to time during the term of the contract. Contractor's failure to comply shall constitute a material breach of the contract. Clean Air 1) Contractor shall comply with all applicable standards, orders or regulations pursuant to the Clean Air Act, 42 USC 7401 et seq. Contractor shall report each violation to the recipient and understands and agrees that the recipient will, in turn, report each violation as required to FTA and the appropriate EPA Regional Office. 2) Contractor shall include these requirements in each subcontract exceeding $100,000 financed in whole or in part with FTA assistance. Recycled Products All contracts for items designated by the EPA, when the purchaser or contractor procures $10,000 or more of one of these items during the current or previous fiscal year using Federal funds. The contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in Subpart B of 40 CFR Part 247. Contract Work Hours & Safety Standards Act Applicability — Contracts over $100,000 (1) Overtime requirements - No contractor or subcontractor contracting for any part of the contract work which may require or involve the employment of laborers or mechanics shall require or permit any such laborer or mechanic in any workweek in which he or she is employed on such work to work in excess of 40 hours in such workweek unless such laborer or mechanic receives compensation at a rate not less than one and one-half times the basic rate of pay for all hours worked in excess of 40 hours in such workweek. (2) Violation; liability for unpaid wages; liquidated damages - In the event of any violation of the clause set forth in para. (1) of this section, contractor and any subcontractor responsible therefore shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in para. (1) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of 40 hours without payment of the overtime wages required by the clause set forth in para. (1) of this section. (3) Withholding for unpaid wages and liquidated damages - the recipient shall upon its own action or upon written request of USDOL withhold or cause to be withheid, from any moneys payable on account of work performed by contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours & Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in para. (2) of this section. (4) Subcontracts - Contractor or subcontractor shall insert in any subcontracts the clauses set forth in this section and also a clause requiring the subcontractors to include these clauses in any lower tier subcontracts. Prime contractor shall be responsible for compliance by any subcontractor or lower tier subcontractor with the clauses set forth in this section. No Government Obligation to Third Parties Applicability — All contracts except micro-purchases ($3,000 or less, except for construction contracts over $2,000) (1) The recipient and contractor acknowledge and agree that, notwithstanding any concurrence by the US Government in or approval of the solicitation or award of the underlying contract, absent the express written consent by the US Government, the US Government is not a party to this contract and shall not be subject to any obligations or liabilities to the recipient, the contractor, or any other party (whether or not a party to that contract) pertaining to any matter resulting from the underlying contract. (2) Contractor agrees to include the above clause in each subcontract financed in whole or in part with FTA assistance. It is further agreed that the clause shall not be modified, except to identify the subcontractor who will be subject to its provisions. Program Fraud and False or Fraudulent Statements or Related Acts Applicability — All contracts except micro-purchases ($3,000 or less, except for construction contracts over $2,000) (1) Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of 1986, as amended, 31 USC 3801 et seq. and USDOT regulations, "Program Fraud Civil Remedies," 49 CFR 31, app�y to its actions pertaining to this project. Upon execution of the underlying contract, contractor certifies or affirms the truthfulness and accuracy of any statement it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or FTA assisted project for which this contract work is being performed. In addition to other penalties that may be applicable, contractor further acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submittal, or certification, the US Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act (1986) on contractor to the extent the US Government deems appropriate. (2) If contractor makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submittal, or certification to the US Government under a contract connected with a project that is financed in whole or in part with FTA assistance under the authority of 49 USC 5307, the Government reserves the right to impose the penalties of 18 USC 1001 and 49 USC 5307(n)(1) on contractor, to the extent the US Government deems appropriate. (3) Contractor shall include the above two clauses in each subcontract financed in whole or in part with FTA assistance. The clauses shall not be modified, except to identify the subcontractor who will be subject to the provisions. 10 Termination Applicability — All Contracts over $10,000, except contracts with nonprofit organizations and institutions of higher learning, where the threshold is $100,000 a. Termination for Convenience (Generai Provision) the recipient may terminate this contract, in whole or in part, at any time by written notice to contractor when it is in the recipient's best interest. Contractor shall be paid its costs, including contract close-out costs, and profit on work performed up to the time of termination. Contractor shall promptly submit its termination claim to the recipient. If contractor is in possession of any of the recipient's property, contractor shall account for same, and dispose of it as the recipient directs. b. Termination for Default [Breach or Cause] (General Provision) If contractor does not de�iver items in accordance with the contract delivery schedule, or, if the contract is for services, and contractor fails to perform in the manner called for in the contract, or if contractor fails to comply with any other provisions of the contract, the recipient may terminate this contract for default. Termination shall be effected by.serving a notice of termination to contractor setting forth the manner in which contractor is in default. Contractor shall only be paid the contract price for supplies delivered and accepted, or for services performed in accordance with the manner of performance set forth in the contract. If it is later determined by the recipient that contractor had an excusable reason for not performing, such as a strike, fire, or flood, events which are not the fault of or are beyond the control of contractor, the recipient, after setting up a new delivery or performance schedule, may allow contractor to continue work, or treat the termination as a termination for convenience. c. Opportunity to Cure (General Provision) the recipient in its sole discretion may, in the case of a termination for breach or default, allow contractor an appropriately short period of time in which to cure the defect. In such case, the notice of termination shall state the time period in which cure is permitted and other appropriate conditions If contractor fails to remedy to the recipient's satisfaction the breach or default or any of the terms, covenants, or conditions of this Contract within ten (10) days after receipt by contractor or written notice from the recipient setting forth the nature of said breach or default, the recipient shall have the right to terminate the Contract without any further obligation to contractor. Any such termination for default shall not in any way operate to preclude the recipient from also pursuing all available remedies against contractor and its sureties for said breach or default. d. Waiver of Remedies for any Breach In the event that the recipient elects to waive its remedies for any breach by contractor of any covenant, term or condition of this Contract, such waiver by the recipient shall not limit its remedies for any succeeding breach of that or of any other term, covenant, or condition of this Contract. e. Termination for Convenience (Professional or Transit Service Contracts) the recipient, by written notice, may terminate this contract, in whole or in part, when it is in the recipient's interest. If the contract is terminated, the recipient shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination. f. Termination for Default (Supplies and Service) If contractor fails to deliver supplies or to perform the services within the time specified in this contract or any extension or if the contractor fails to comply with any other provisions of this contract, the recipient may terminate this contract for default. The recipient shall terminate by delivering to contractor a notice of termination specifying the nature of default. Contractor shall only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner or performance set forth in this contract. If, after termination for failure to fulfill contract obligations, it is determined that contractor was not in default, the rights and obligations of the parties shall be the same as if termination had been issued for the recipienYs convenience. g. Termination for Default (Transportation Services) If contractor fails to pick up the commodities or to perform the services, including delivery services, within the time specified in this contract or any extension or 11 if contractor fails to comply with any other provisions of this contract, the recipient may terminate this contract for default. The recipient shall terminate by delivering to contractor a notice of termination specifying the nature of default. Contractor shall only be paid the contract price for services performed in accordance with the manner of performance set forth in this contract. If this contract is terminated while contractor has possession of the recipient goods, contractor shall, as directed by the recipient, protect and preserve the goods until surrendered to the recipient or its agent. Contractor and the recipient shall agree on payment for the preservation and protection of goods. Failure to agree on an amount shall be resolved under the Dispute clause. If, after termination for failure to fulfill contract obligations, it is determined that contractor was not in default, the rights and obligations of the parties shall be the same as if termination had been issued for the recipient's convenience. h. Termination for Default (Construction) if contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified, or any extension, or fails to complete the work within this time, or if contractor fails to comply with any other provisions of this contract, the recipient may terminate this contract for default. the recipient shall terminate by delivering to contractor a notice of termination specifying the nature of default. In this event, the recipient may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. Contractor and its sureties shall be liable for any damage to the recipient resulting from contractor's refusal or failure to complete the work within specified time, whether or not contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the recipient in completing the work. Contractor's right to proceed shall not be terminated nor shall contractor be charged with damages under this clause if: 1. Delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of contractor. Examples of such causes include: acts of God, acts of the recipient, acts of another contractor in the performance of a contract with the recipient, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. Contractor, within 10 days from the beginning of any delay, notifies the recipient in writing of the causes of delay. If in the recipienYs judgment, delay is excusable, the time for completing the work shall be extended. The recipient's judgment shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. If, after termination of contractor's right to proceed, it is determined that contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if termination had been issued for the recipienYs convenience. i. Termination for Convenience or Default (Architect & Engineering) the recipient may terminate this contract in whole or in part, for the recipient's convenience or because of contractor's failure to fulfill contract obligations. The recipient shall terminate by delivering to contractor a notice of termination specifying the . nature, extent, and effective date of termination. Upon receipt of the notice, contractor shall (1) immediately discontinue all services affected (unless the notice directs otherwise), and (2) deliver to the recipient all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process. If termination is for the recipient's convenience, it shall make an equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services. If termination is for contractor's failure to fulfill contract obligations, the recipient may complete the work by contact or otherwise and contractor shall be liable for any additional cost incurred by the recipient. If, after termination for failure to fulfill contract obligations, it is determined that contractor was not in default, the rights and obligations of the parties shall be the same as if termination had been issued for the recipient's convenience. j. Termination for Convenience or Default (Cost-Type Contracts) the recipient may terminate this contract, or any portion of it, by serving a notice or termination on contractor. The notice shall state whether termination is for convenience of the recipient or for default of contractor. If termination is for default, the notice shall 12 state the manner in which contractor has failed to perform the requirements of the contract. Contractor shall account for any property in its possession paid for from funds received from the recipient, or property supplied to contractor by the recipient. If termination is for default, the recipient may fix the fee, if the contract provides for a fee, to be paid to contractor in proportion to the value, if any, of work performed up to the time of termination. Contractor shall promptly submit its termination claim to the recipient and the parties shall negotiate the termination settlement to be paid to contractor. If termination is for the recipienYs convenience, contractor shall be paid its contract close- out costs, and a fee, if the contract provided for payment of a fee, in proportion to the work performed up to the time of termination. If, after serving a notice of termination for default, the recipient determines that contractor has an excusable reason for not performing, such as strike, fire, flood, events which are not the fault of and are beyond the control of contractor, the recipient, after setting up a new work schedule, may allow contractor to continue work, or treat the termination as a termination for convenience. Government Wide Debarment and Suspension (Non Procurement) Applicability — Contracts over $25,000 This contract is a covered transaction for purposes of 49 CFR Part 29. As such, the contractor is required to verify that none of the contractors, its principals, as defined at 49 CFR 29.995, or affiliates, as defined at 49 CFR 29.905, are excluded or disqualified as defined at 49 CFR 29.940 and 29.945. The contractor is required to comply with 49 CFR 29, Subpart C and must include the requirement to comply with 49 CFR 29, Subpart C in any lower tier covered transaction it enters into. By signing and submitting its bid or proposal, the bidder or proposer certifies as follows: The certification in this clause is a material representation of fact relied upon by the recipient. If it is later determined that the bidder or proposer knowingly rendered an erroneous certification, in addition to remedies available to the recipient, the Federal Government may pursue available remedies, including but not limited to suspension and/or debarment. The bidder or proposer agrees to comply with the requirements of 49 CFR 29, Subpart C while this offer is valid and throughout the period of any contract that may arise from this offer. The bidder or proposer further agrees to include a provision requiring such compliance in its lower tier covered transactions. Contracts Involving Federal Privacy Act Requirements When a grantee maintains files on drug and alcohol enforcement activities for FTA, and those files are organized so that information could be retrieved by personal identifier, the Privacy Act requirements apply to all contracts except micro-purchases ($3,000 or less, except for construction contracts over $2,000) The following requirements apply to the Contractor and its employees that administer any system of records on behalf of the Federal Government under any contract: (1) The Contractor agrees to comply with, and assures the compliance of its employees with, the information restrictions and other applicable requirements of the Privacy Act of 1974, 5 U.S.C. § 552a. Among other things, the Contractor agrees to obtain the express consent of the Federal Government before the Contractor or its employees operate a system of records on behalf of the Federal Government. The Contractor understands that the requirements of the Privacy Act, including the civil and criminal penalties for violation of that Act, apply to those individuals involved, and that failure to comply with the terms of the Privacy Act may result in termination of the underlying contract. (2) The Contractor also agrees to include these requirements in each subcontract to administer any system of records on behalf of the Federal Government financed in whole or in part with Federal assistance provided by FTA. Civil Rights Requirements All contracts except micro-purchases ($3,000 or less, except for construction contracts over $2,000) The following requirements apply to the underlying contract: The Recipient understands and agrees that it must comply with applicable Federal civil rights laws and regulations, and follow applicable Federal guidance, except as the Federal Government determines otherwise in writing. Specifically: 13 ,' a. Nondiscrimination in Federal Public Transportation Programs. The Recipient agrees to, and assures that each Third Party Participant will, comply with Federal transit law, 49 U.S.C. § 5332 (FTA's "Nondiscrimination" statute): (1) FTA's "Nondiscrimination" statute prohibits discrimination on the basis of: (a) Race, (b) Color, (c) Religion, (d) National origin, (e) Sex, (f) Disability, or (g) Age, and (2) The FTA "Nondiscrimination" statute's prohibition against discrimination includes: (a) Exclusion from participation, (b) Denial of program benefits, or (c) Discrimination, including discrimination in employment or business opportunity, b. Nondiscrimination — Title VI of the Civil Rights Act. The Recipient agrees to, and assures that each Third Party Participant will: (1) Prohibit discrimination based on: (a) Race, (b) Color, or (c) National origin, (2) Comply with: (a) Title VI of the Civil Rights Act of 1964, as amended, 42 U.S.C. § 2000d et seq., (b) U.S. DOT regulations, "Nondiscrimination in Federally-Assisted Programs of the Department of Transportation — Effectuation of Title VI of the Civil Rights Act of 1964," 49 C.F.R. part 21, and (c) Federal transit law, specifically 49 U.S.C. § 5332, as stated in the preceding section a, and (3) Except as FTA determines otherwise in writing, follow: (a) The most recent edition of FTA Circular 4702.1, "Title VI and Title VI-Dependent Guidelines for Federal Transit Administration Recipients," to the extent consistent with applicable Federal laws, regulations, and guidance. (b) U.S. DOJ, "Guidelines for the enforcement of Title VI, Civil Rights Act of 1964," 28 C.F.R. § 50.3, and (c) Other applicable Federal guidance that may be issued, c. Equal Employment Opportunity. (1) Federal Requirements and Guidance. The Recipient agrees to, and assures that each Third Party Participant will, prohibit discrimination on the basis of race, color, religion, sex, or national origin, and: (a) Comply with Title VII of the Civil Rights Act of 1964, as amended, 42 U.S.C. § 2000e et seq., (b) Facilitate compliance with Executive Order No. 11246, "Equal Employment Opportunity," as amended by Executive Order No. 11375, "Amending Executive Order No. 11246, Relating to Equal Employment Opportunity," 42 U.S.C. § 2000e note, (c) Comply with Federal transit law, specifically 49 U.S.C. § 5332, as stated in section a, and (d) Comply with other applicable EEO laws and regulations, as provided in Federal guidance, including laws and regulations prohibiting discrimination on the basis of disability, except as the Federal Government determines otherwise in writing, (2) General. The Recipient agrees to: (a) Ensure that applicants for employment are employed and employees are treated during employment without discrimination on the basis of their: 1 Race, 2 Color, 3 Religion, 4 Sex, 5 Disability, 6 Age, or 7 National origin, (b) Take affirmative action that includes, but is not limited to: 1 Recruitment advertising, 2 Recruitment, 3 Employment, 4 Rates of pay, 5 Other forms of compensation, 6 Selection for training, including apprenticeship, 7 Upgrading, 8 Transfers, 9 Demotions, 10 Layoffs, and 11 Terminations, and (3) Equal Employment Opportunity Requirements for Construction Activities. In addition to the foregoing, when undertaking "construction" as recognized by the U.S. Department of Labor (U.S. DOL), the Recipient agrees to comply, and assures the compliance of each Third Party Participant, with: (a) U.S. DOL regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor," 41 C.F.R. chapter 60, and (b) Executive Order No. 11246, "Equal Employment Opportunity," as amended by Executive Order No. 11375, "Amending Executive Order No. 11246, Relating to Equal Employment Opportunity," 42 U.S.C. § 2000e note, d. Disadvantaged Business Enterprise. To the extent authorized by applicable Federal law, the Recipient agrees to facilitate, and assures that each Third Party Participant will facilitate, participation by small business concerns owned and controlled by socially and economically disadvantaged individuals, also referred to as "Disadvantaged Business Enterprises" (DBEs), in the Project as follows: (1) Requirements. The Recipient agrees to comply with: (a) Section 1101(b) of MAP-21, 23 U.S.C. § 101 note, (b) U.S. DOT regulations, "Participation by Disadvantaged Business Enterprises in Department of Transportation Financial Assistance Programs," 49 C.F.R. part 26, and (c) Federal transit law, specifically 49 U.S.C. § 5332, as stated in section a, (2) Assurance. As required by 49 C.F.R. § 26.13(a), the Recipient provides assurance that: The Recipient shall not discriminate on the basis of race, color, national origin, or sex in the award and performance of any DOT-assisted contract or in the administration of its DBE program or the requirements of 49 C.F.R. part 26. The Recipient shall take all 14 ♦` necessary and reasonable steps under 49 C.F.R. part 26 to ensure nondiscrimination in the award and administration of DOT-assisted contracts. The RecipienYs DBE program, as required by 49 C.F.R. part 26 and as approved by DOT, is incorporated by reference in this agreement. Implementation of this program is a legal obligation and failure to carry out its terms shall be treated as a violation of this agreement. Upon notification to the Recipient of its failure to carry out its approved program, the Department may impose sanctions as provided for under 49 C.F.R. part 26 and may, in appropriate cases, refer the matter for enforcement under 18 U.S.C. § 1001 and/or the Program Fraud Civil Remedies Act of 1986, 31 U.S.C. § 3801 et seq., e. Nondiscrimination on the Basis of Sex. The Recipient agrees to comply with Federal prohibitions against discrimination on the basis of sex, including: (1) Title IX of the Education Amendments of 1972, as amended, 20 U.S.C. § 1681 et seq., (2) U.S. DOT regulations, "Nondiscrimination on the Basis of Sex in Education Programs or Activities Receiving Federal Financial Assistance," 49 C.F.R. part 25, and (3) Federal transit law, specifically 49 U.S.C. § 5332, as stated in section a, f. Nondiscrimination on the Basis of Age. The Recipient agrees to comply with Federal prohibitions against discrimination on the basis of age, including: (1) The Age Discrimination in Employment Act (ADEA), 29 U.S.C. §§ 621 — 634, which prohibits discrimination on the basis of age, (2) U.S. Equal Employment Opportunity Commission (U.S. EEOC) regulations, "Age Discrimination in Employment Act," 29 C.F.R. part 1625, which implements the ADEA, (3) The Age Discrimination Act of 1975, as amended, 42 U.S.C. § 6101 et seq., which prohibits discrimination against individuals on the basis of age in the administration of programs or activities receiving Federal funds, (4) U.S. Health and Human Services regulations, "Nondiscrimination on the Basis of Age in Programs or Activities Receiving Federal Financial Assistance," 45 C.F.R. part 90, which implements the Age Discrimination Act of 1975, and (5) Federal transit law, specifically 49 U.S.C. § 5332, as stated in section a, g. Nondiscrimination on the Basis of Disability. The Recipient agrees to comply with the following Federal prohibitions pertaining to discrimination against seniors or individuals with disabilities: (1) Federal laws, including: (a) Section 504 of the Rehabilitation Act of 1973, as amended, 29 U.S.C. § 794, which prohibits discrimination on the basis of disability in the administration of federally funded programs or activities, (b) The Americans with Disabilities Act of 1990 (ADA), as amended, 42 U.S.C. § 12101 et seq., which requires that accessible facilities and services be made available to individuals with disabilities, (c) The Architectural Barriers Act of 1968, as amended, 42 U.S.C. § 4151 et seq., which requires that buildings and public accommodations be accessible to individuals with disabilities, (d) Federal transit law, specifically 49 U.S.C. § 5332, which now includes disability as a prohibited basis for discrimination, and (e) Other applicable laws and amendments pertaining to access for elderly individuals or individuals with disabilities, (2) Federal regulations, including: (a) U.S. DOT regulations, "Transportation Services for Individuals with Disabilities (ADA)," 49 C.F.R. part 37, (b) U.S. DOT regulations, "Nondiscrimination on the Basis of Disability in Programs and Activities Receiving or Benefiting from Federal Financial Assistance," 49 C.F.R. part 27, (c) U.S. DOT regulations, "Transportation for individuals with Disabilities: Passenger Vessels," 49 C.F.R. part 39, (d) Joint U.S. Architectural and Transportation Barriers Compliance Board (U.S. ATBCB) and U.S. DOT regulations, "Americans With Disabilities (ADA) Accessibility Specifications for Transportation Vehicles," 36 C.F.R. part 1192 and 49 C.F.R. part 38, (e) U.S. DOJ regulations, "Nondiscrimination on the Basis of Disability in State and Local Government Services," 28 C.F.R. part 35, (f) U.S. DOJ regulations, "Nondiscrimination on the Basis of Disability by Public Accommodations and in Commercial Facilities," 28 C.F.R. part 36, (g) U.S. EEOC, "Regulations to Implement the Equal Employment Provisions of the Americans with Disabilities Act," 29 C.F.R. part 1630, (h) U.S. Federal Communications Commission regulations, "Telecommunications Relay Services and Related Customer Premises Equipment for Persons with Disabilities," 47 C.F.R. part 64, Subpart F, (i) U.S. ATBCB regulations, "Electronic and Information Technology Accessibility Standards," 36 C.F.R. part 1194, and Q) FTA regulations, "Transportation for Elderly and Handicapped Persons," 49 C.F.R. part 609, and (3) Other applicable Federal civil rights and nondiscrimination guidance, h. Drug or Alcohol Abuse - Confidentiality and Other Civil Rights Protections. The Recipient agrees to comply with the confidentiality and civil rights protections of: (1) The Drug Abuse Office and Treatment Act of 1972, as amended, 21 U.S.C. § 1101 et seq., (2) The Comprehensive Alcohol Abuse and Alcoholism 15 � Prevention, Treatment and Rehabilitation Act of 1970, as amended, 42 U.S.C. § 4541 et seq., and (3) The Public Health Service Act, as amended, 42 U.S.C. §§ 290dd — 290dd-2, i. Access to Services for People with Limited English Proficiency. Except as the Federal Government determines otherwise in writing, the Recipient agrees to promote accessibility of public transportation services to people whose understanding of English is limited by following: 1) Executive Order No. 13166, "Improving Access to Services for Persons with Limited English Proficiency," August 11, 2000, 42 U.S.C. § 2000d-1 note, and (2) U.S. DOT Notice, "DOT Policy Guidance Concerning Recipients' Responsibilities to Limited English Proficiency (LEP) Persons," 70 Fed. Reg. 74087, December 14, 2005, j. Environmental Justice. Except as the Federal Government determines otherwise in writing, the Recipient agrees to promote environmental justice by following: (1) Executive Order No. 12898, "Federal Actions to Address Environmental Justice in Minority Populations and Low-Income Populations," February 11, 1994, 42 U.S.C. § 4321 note, as well as facilitating compliance with that Executive Order, and (2) DOT Order 5610.2, "Department of Transportation Actions To Address Environmental Justice in Minority Populations and Low-Income Populations," 62 Fed. Reg. 18377, April 15, 1997, and (3) The most recent and applicable edition of FTA Circular 4703.1, "Environmental Justice Policy Guidance for Federal Transit Administration Recipients," August 15, 2012, to the extent consistent with applicable Federal laws, regulations, and guidance, and k. Other Nondiscrimination Laws. Except as the Federal Government determines otherwise in writing, the Recipient agrees to: (1) Comply with other applicable Federal nondiscrimination laws and regulations, and (2) Follow Federal guidance prohibiting discrimination. I. Contractor shall include these requirements in each subcontract financed in whole or in part with FTA assistance, modified only if necessary to identify the affected parties. Breaches and Dispute Resolution All contracts over $100,000 Disputes arising in the performance of this contract which are not resolved by agreement of the parties shall be decided in writing by the recipient's authorized representative. This decision shall be finai and conclusive unless within ten (10) days from the date of receipt of its copy, contractor mails or otherwise furnishes a written appeal to the recipienYs CEO. In connection with such appeal, contractor shall be afforded an opportunity to be heard and to offer evidence in support of its position. The decision of the recipient's CEO shall be binding upon contractor and contractor shall abide by the decision. Performance During Dispute - Unless otherwise directed by the recipient, contractor shall continue performance under this contract while matters in dispute are being resolved. Claims for Damages - Should either party to the contract suffer injury or damage to person or property because of any act or omission of the party or of any of his employees, agents or others for whose acts he is legally liable, a claim for damages therefore shall be made in writing to such other party within ten days after the first observance of such injury or damage. Remedies - Unless this contract provides otherwise, all claims, counterclaims, disputes and other matters in question between the recipient and contractor arising out of or relating to this agreement or its breach will be decided by arbitration if the parties mutually agree, or in a court of competent jurisdiction within the residing State. Rights and Remedies - Duties and obligations imposed by the contract documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law. No action or failure to act by the recipient or contractor shall constitute a waiver of any right or duty afforded any of them under the contract, nor shall any such action or failure to act constitute an approval of or acquiescence in any breach thereunder, except as may be specifically agreed in writing. 16 R Transit Employee Protective Provisions Contracts for transit operations except micro-purchases ($3,000 or less, except for construction contracts over $2,000) (1) Contractor shall comply with applicable transit employee protective requirements as follows: (a) Transit Employee Protective Requirements for Projects Authorized by 49 USC 5311 in Nonurbanized Areas - If the contract involves transit operations financed in whole or in part with FTA assistance authorized by 49 USC 5311, the contractor shall comply with the terms and conditions of the Special Warranty for the Nonurbanized Area Program that is most current, and any alternative comparable arrangement specified by U.S. DOL for application to the project, in accordance with U.S. DOL guidelines, "Section 5333(b), Federal Transit Law," 29 C.F.R. Part 215, and any revision thereto. [New amendments to U.S. DOL guidelines, "Section 5333(b), Federal Transit Law," 29 C.F.R. Part 215, were published at 73 Fed. Reg. 47046 et. Seq., August 13, 2008.J (2) Contractor shall also include any applicable requirements in each subcontract involving transit operations financed in whole or in part with FTA assistance. Disadvantaged Business Enterprise Contracts over $3,000 awarded on the basis of a bid or proposal offering to use DBEs a. This contract is subject to the requirements of Title 49, Code of Federal Regulations, Part 26, Participation by Disadvantaged Business Enterprises in Department of Transportation Financial Assistance Programs. The national goal for participation of Disadvantaged Business Enterprises (DBE) is 10%. The recipienYs overall goal for DBE participation is listed elsewhere. If a separate contract goal for DBE participation has been established for this procurement, it is listed elsewhere. b. The contractor shall not discriminate on the basis of race, color, religion, national origin or sex in the performance of this contract. The contractor shall carry out applicable requirements of 49 CFR Part 26 in the award and administration of this contract. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or such other remedy as the municicpal corporation deems appropriate. Each subcontract the contractor signs with a subcontractor must include the assurance in this paragraph (see 49 CFR 26.13(b)). c. If a separate contract goal has been established, Bidders/offerors are required to document sufficient DBE participation to meet these goals or, alternatively, document adequate good faith efforts to do so, as provided for in 49 CFR 26.53. � d. If no separate contract goal has been established, the successful bidder/offeror will be required to report its DBE participation obtained through race-neutral means throughout the period of performance. e. The contractor is required to pay its subcontractors performing work related to this contract for satisfactory perFormance of that work no later than 10 calendar days after the contractor's receipt of payment for that work from the recipient. In addition, the contractor may not hold retainage from its subcontractors or must return any retainage payments to those subcontractors within 10 calendar days after the subcontractor's work related to this contract is satisfactorily completed or must return any retainage payments to those subcontractors within 10 calendar days after incremental acceptance of the subcontractor's work by the recipient and contractor's receipt of the partial retainage payment related to the subcontractor's work. f. The contractor must promptly notify the recipient whenever a DBE subcontractor performing work related to this contract is terminated or fails to complete its work, and must make good faith efforts to engage another DBE subcontractor to perform at least the same amount of work. The contractor may not terminate any DBE subcontractor and perform that work through its own forces or those of an affiliate without prior written consent of the recipient. 17 �i � Incorporation of Federal Transit Administration (FTA) Terms All contracts except micro-purchase ($3,000 or less, except for construction contracts over $2,000). The preceding provisions include, in part, certain Standard Terms & Conditions required by USDOT, whether or not expressly stated in the preceding contract provisions. All USDOT-required contractual provisions, as stated in FTA Circular 4220.1 F, are hereby incorporated by reference. Anything to the contrary herein notwithstanding, all FTA mandated terms shall be deemed to control in the event of a conflict with other provisions contained in this Agreement. The contractor shall not perform any act, fail to perform any act, or refuse to comply with any request that would cause the recipient to be in violation of FTA terms and conditions. Drug and Alcohol Abuse and Testing Operational service contracts except micro-purchases ($3,000 or less, except for construction contracts over $2,000) The Contractor agrees to comply with the following Federal substance abuse regulations: a. Drug-Free Workplace. U.S. DOT regulations, "Drug-Free Workplace Requirements (Grants), " 49 C.F.R. Part 32, that implements the Drug-Free Workplace Act of 1988, 41 U.S.C. §§ 701 et seq. b. Alcohol Misuse and Prohibited Drug Use. FTA Regulations, "Prevention of Alcohol Misuse and Prohibited Drug Use in Transit Operations," 49 CFR Part 655, to the extent applicable. Other Federal Requirements The following requirements are not federal clauses. Full and Open Competition In accordance with 49 U.S.C. § 5325(a) all procurement transactions shall be conducted in a manner that provides full and open competition. Prohibition Against Exclusionary or Discriminatory Specifications Apart from inconsistent requirements imposed by Federal statute or regulations, the contractor shall comply with the requirements of 49 USC 5323(h)(2) by refraining from using any FTA assistance to support procurements using exclusionary or discriminatory specifications. Conformance with ITS National Architecture Contractor shall conform, to the extent applicable, to the National Intelligent Transportation Standards architecture as required by SAFETEA-LU Section 5307(c), 23 U.S.C. Section 512 and as amended by MAP- 21 23 U.S.C. § 517(d), note and follow the provisions of FTA Notice, "FTA National Architecture Policy on Transit Projects," 66 Fed. Reg.1455 etseq., January 8, 2001, and any other implementing directives FTA may issue at a later date, except to the extent FTA determines otherwise in writing. Access Requirements for Persons with Disabilities Contractor shall comply with 49 USC 5301(d), stating Federal policy that the elderly and persons with disabilities have the same rights as other persons to use mass transportation services and facilities and that special efforts shall be made in planning and designing those services and facilities to implement that policy. Contractor shall also comply with all applicable requirements of Sec. 504 of the Rehabilitation Act (1973), as amended, 29 USC 794, which prohibits discrimination on the basis of handicaps, and the Americans with Disabilities Act of 1990 (ADA), as amended, 42 USC 12101 et seq., which requires that accessible facilities and services be made available to persons with disabilities, including any subsequent amendments thereto. Notification of Federal Participation To the extent required by law, in the announcement of any third party contract award for goods and services (including construction services) having an aggregate value of $500,000 or more, contractor shall specify the amount of Federal assistance to be used in financing that acquisition of goods and services and to express that amount of Federal assistance as a percentage of the total cost of the third party contract. 18 � Interest of Members or Delegates to Congress No members of, or delegates to, the US Congress shall be admitted to any share or part of this contract nor to any benefit arising therefrom. Ineligible Contractors and Subcontractors Any name appearing upon the Comptroller General's list of ineligible contractors for federally-assisted contracts shall be ineligible to act as a subcontractor for contractor pursuant to this contract. If contractor is on the Comptroller General's list of ineligible contractors for federally financed or assisted construction, the recipient shall cancel, terminate or suspend this contract. Other Contract Requirements To the extent not inconsistent with the foregoing Federal requirements, this contract shall also include those provisions attached hereto, and shall comply with the recipient's Procurement Guidelines, available upon request from the recipient. Compliance with Federal Regulations Any contract entered pursuant to this solicitation shall contain the following provisions: All USDOT-required contractual provisions, as set forth in FTA Circular 4220.1 F, are incorporated by reference. Anything to the contrary herein notwithstanding, FTA mandated terms shall control in the event of a conflict with other provisions contained in this Agreement. Contractor shall not perform any act, fail to perform any act, or refuse to comply with any grantee request that would cause the recipient to be in violation of FTA terms and conditions. Contractor shall comply with all applicable FTA regulations, policies, procedures and directives, including, without limitation, those listed directly or incorporated by reference in the Master Agreement between the recipient and FTA, as may be amended or promulgated from time to time during the term of this contract. Contractor's failure to so comply shall constitute a material breach of this contract. Real Property Any contract entered into shall contain the following provisions: Contractor shall at all times comply with all applicable statutes and USDOT regulations, policies, procedures and directives governing the acquisition, use and disposal of real property, including, but not limited to, 29 CFR 18.31, 49 CFR 24 Subpart B, FTA Circular 5010.1 D, and FTA Master Agreement, as they may be amended or promulgated during the term of this contract. Contractor's failure to so comply shall constitute a material breach of this contract. Access to Services for Persons with Limited English Proficiency To the extent applicable and except to the extent that FTA determines otherwise in writing, the Recipient agrees to comply with the policies of Executive Order No. 13166, "fmproving Access to Services for Persons with Limited English Proficiency," 42 U.S.C. § 2000d 1 note, and with the provisions of U.S. DOT Notice, "DOT Guidance to Recipients on Special Language Services to Limited English Proficient (LEP) Beneficiaries," 70 Fed. Reg. 74087, December 14, 2005. Environmental Justice The Recipient agrees to comply with the policies of Executive Order No. 12898, "Federal Actions to Address Environmental Justice in Minority Populations and Low Income Populations," 42 U.S.C. § 4321 note, except to the extent that the Federal Government determines otherwise in writing. Environmental Protections Compliance is required with any applicable Federal laws imposing environmental and resource conservation requirements for the project. Some, but not all, of the major Federal laws that may affect the project include: the National Environmental Policy Act of 1969; the Clean Air Act; the Resource Conservation and Recovery Act; the comprehensive Environmental response, Compensation and Liability Act; as well as environmental provisions with Title 23 U.S.C., and 49 U.C. chapter 53. The U.S. EPA, FHWA and other federal agencies may issue other federal regulations and directives that may affect the project. Compliance is required with any applicable Federal laws and regulations in effect now or that become effective in the future. 19 ,�. .�. Geographic Information and Related Spatial Data Any project activities involving spatial data or geographic information systems activities financed with Federal assistance are required to be consistent with the National Spatial Data Infrastructure promulgated by the Federal Geographic Data Committee, except to the extent that FTA determines otherwise in writing. Federal Single Audit Requirements for State Administered Federally Aid Funded Projects Only Non Federal entities that expend $500,000 or more in a year in Federal awards from all sources are required to comply with the Federal Single Audit Act provisions contained in U.S. Office of Management and Budget (OMB) Circular No. A 133, Audits of States, Local Governments, and Non Profit Organizations. Non Federal entities that expend Federal awards from a single source may provide a program specific audit, as defined in the Circular. Non Federal entities that expend less than $500,000 in a year in Federal awards from all sources are exempt from Federal audit requirements for that year, except as noted in '3052.215(a), but records must be available for review or audit by appropriate officials of the Federal and State agencies. Catalog of Federal Domestic Assistance (CFDA) Identification Number The municipal project sponsor is required to identify in its accounts all Federal awards received and expended, and the Federal programs under which they were received. Federal program and award identification shall include, as applicable, the CFDA title and number, award number and year, name of the Federal agency, and name of the pass through entity. CFDA number for the Federal Transportation Administration A Recipient covered by the Single Audit Act Amendments of 1996 and OMB Circular A-133, "Audits of States, Local Governments, and Non-Profit Organizations," agrees to separately identify the expenditures for Federal awards under the Recovery Act on the Schedule of Expenditures of Federal Awards (SEFA) and the Data Collection Form (SF-SAC) required by OMB Circular A-133. The Recipient agrees to accomplish this by identifying expenditures for Federal awards made under Recovery Act separately on the SEFA, and as separate rows under Item 9 of Part III on the SF-SAC by CFDA number, and inclusion of the prefix "ARRA" in identifying the name of the Federal program on the SEFA and as the first characters in Item 9d of Part III on the SF-SAC. 20 �' Attachment A Section 5339 Bus and Bus Facilities Capital Grant Grant Number WI-34-X013 City of Oshkosh Non-ADA Qtv ALI Item Description Unit Price Total Price 1 11.12.02 Revenue Rolling Stock - Purchase/Replacement - $450,000.00 $450,000.00 Bus STD 35 ft. - Diesei Total Federal Share $360,000.00 Total Local Share $90,000.00 Total Cost $450,000.00