HomeMy WebLinkAbout31596 / 81-12\o�ember 5, 1981
�/ 12 RESOLUTION
PURPOSE: AUTHORIZE CONTRACT FOR ARCAITECTURAL SERVICES
FOR THE MENOMINEE PARK BEACH HOUSE
INITIATED BY: PARKS DEPARTMENT
, BE IT RESOLVED by the Common Council of the City of Oshkosh that the
proper City officials are hereby authorized and directed to enter into the
attached contract with Reinke, Hansche, Last, Inc. for the renovation of the
Menominee Park Beach House.
BE IT FURTAER RESOLVED that funds for this purpose shall be appro-
priated from Account 1i361-818, Park Improvement.
;
� � � ���(%/�L/`�"
- 12 -
�
�
�
f
THE AMERICAN INSTITUTE OF ARCHITECTS
�`!,1�9p'�/�
��: �f4i�
�; j�c e:;•: :E
, �a�� �i.
�; �ia,^'����_
i ����
AIA Document 6151
Abbreviated Form of Agreement Between
Owner and Architect
For Construction Projects of Limited Scope
1978 EDITION
� �,
. TH15 DOCUMENT HAS IMPOR7ANT LEGAL CONSEQUENCES; CONSULTATION WRH
AN ATTOftNEY IS ENCOURAGED WITH Rf5PEC7 TO ITS COMPLETION OR MODIfIfA710N
AGREEMENT
made as of the Ztventieth day of october in the year of Nineteen
Hundred and Eighty-One
BETWEEN the Owner:
and the Architect
City of Oshkosh
215 Church Avenue
Oshkosh, Wisconsin 54901
Reinke, Hansche, Last, Inc.
805 North Main Street
Oshicosh, Wisconsin 54901
For the foilowing Project:
(Includes detailed description ot Project location and scope.)
Bath House Restoration
Menominee Park
Oshkosh, Wisconsin
Project No. 3281
The Owner and the Architect agree as set forth below.
Copyrighl t9N, p t978 by The Amerion InstiN�e of Archire<IS, '1735 New York Avenue, N.W., Washington, D.C. 20006.
Reproduction o( the macerial herein or suhstantial quotacion af its provisions wi[hou[ permission of the AIA violatp
Ihe mpyright laws of the United Staes and will be subjecl lo legal prose<ution.
AIA DOCUMEM B757 ABBREVIATED OWNER-ARCHIiER AG2EEMENT • JUNE 1978 EDITION • AIAs
O 7978 • THE AMERIUN•INSTIiUTE OF ARCHITECTS, 7735 NEW YOftK AVENUE, N.W.. WASHINGTON, D.C. lOW6 B751-1978 �
_._._ ... . ... . ... .. . .. ..... . .. ..... . .. ... . .. . . .... ..... ... .... ..J
� Terms and Conditions of Agreement Between Owner and Architect
ARTICLE'I
ARCHITECT'S SERVICES
AND RESPONSIBILITIES
The ArchiiecCs Basic Services are as described un-
der the four Phases identified below and in Article
10, and unless otherwise provided in Article �0,
include normal structural, mechanical and electri-
cal engineering services.
7,� DESIGN PHASE
1.7.1 The Architect shall review with the Owner alterna-
tive approaches to design and construction of the Project.
1.1.2 Based on the mutually accepted program and Proj-
eci budget requirements, the Archi[ect shall prepare, for
approval by the Owner, Design Documents consisting of
drawings and other documents appropriate for the Proj-
ect, and shall submit ro Ihe Owner a Statement of Proba-
ble Construction Cost.
'i,y CONSTRUCf10N DOCUMENTS PHASE
7.2.1 Based on the approved Design Documents, [he Ar-
chitect shall prepare, for approval by the Owner, Con-
struction Documents consisting of Drawings and Specifi-
cations setting forth in detail the requirements for the
construction of the Project and shall advise the Owner
of any adjustments to previous Statements of Probable
Construction Cost.
1.2.2 The Architect shall assist the Owner in connection
with [he Owners responsibility for filing documents re-
quired for the approval of governmental authorities hav-
ing jurisdiction over the Projec[.
1.3 BIDDINC OR NEGOTIATION PHASE
'1.3.1 Unless provided in Article '10, the Architect, fol-
lowing the Owner's approval of the Construction Docu-
men[s and of the most recent Statement of Probable Con-
struction Cost, shall assist the Owner in obtaining bids or
negotiated proposals and in awarding co�tracts for con-
struction.
1.4 CONSTRUCTION PHAS�ADMINISTRATION OF THE
CONSTRUCTION CONTRACT
1.4.1 The Construction Phase will commence with the
award of the Contract for Construction and will terminate
when final payment to the Contractor is due, or in the
absence of a final Certificate for Payment or of such due
date, sixry days after the Date of Substantial Completion
of the Work, whichever occurs first.
'1.4.2 Unless otherwise provided in this Agreemen[ and
incorporated in the Contract Documents, [he Architect
shail provide administration of the Contract for Construc-
tion as set forth below and in the edition of AIA Docu-
ment A20�, General Conditions of the Contract for Con-
struction, current as of the date of this Agreement.
1.4.3 The Architect shall be a representative of the
Owner during the Construction Phase. Instructions to the
Contractor shall be forwarded through the Architect.
��°�O
1.4.4 The Architec[ shall visit [he si[e at intervals appro-
priate to the stage of wnstruction or as othenvise agreed
by the Architect in writing to become generally familiar
with the progress and quality of the Work and to deter-
mine in general if the Work is proceeding in accordance
with the Contract Documents. However, the Archited
shall not be required to make exhaustive or continuous
on-site inspections to check the quality or quantity of ihe
Work. On che basis of such on-site observations as an
architect, the Architect shali keep the Owner informed of
the progress and quality of the Work, and shall endeavor
to guard the Owner against defec[s and deficiencies in the
Work of the Contractor.
1.4.5 The Architect shall not have control or charge of
and shall no[ be responsible for construction means,
methods, techniques, sequences or procedures, or for
safety precautions and progrems in connection with the
Work, for the acts or omissions of the Contractor, Sub-
contractors or any o[her persons performing any of [he
Work, or for the failure of any of them to carry out the
Work in accordance with the Contract Documents.
1.4.6 The Architect shali at all times have access to the
Work wherever i[ is in preparation and progress.
1.4.7 The Architect shall determine the amounts owing
to the Contractor based on observations at the site and
on evaluations of the Contrectors Applications for Pay-
ment, and shall issue Certificates for Payment in such
amounts.
1.4.8 The issuance of a Certificate for Payment shall con-
s[itute a represen[ation by the Architect to the Owner,
based on the ArchitecYs observations at the site as pro-
vided in Subparagraph 1.4.4 and on the data comprising
the Contractor's Application for Payment, that, to the best
of the Architect's knowledge, information and belief, the
Work has progressed to the point indicated; the quality of
the Work is in accordance with the Contrac[ Documents
(subject to an evaluation of. the Work for conformance
with the Contrect Documen[s upon Substantial Comple-
tion, to Ihe results of any subsequent tests required by or
performed under the Contract Documents, [o minor
deviations from the Contract Documents correctable prior
to completion, and to any specific qualifications stated in
the Certificate for Payment); and that the Contractor is
en[itled to payment in the amount cer[ified. However, the
issuance of a Certifica[e for Paymen[ shall not be a reprr
sentation that the Architect has made any examination to
ascertain how and for whaf purpose the Contractor has
used the moneys paid on account of the Contract Sum.
1.4.9 The Architect shall be the interpreter of the r�
quirements of the Contract Documents and the judge of
the performance thereunder by both the Owner and
Contractor, and shall render written decisions on all
claims, disputes and other matters in question behveen
the Owner and the Contractoc In the capacity of inter-
pre[er and judge, the Architect shall endeavor to secure
faithful performance by both the Owner and the Con-
tractor, shall not show partialiry to either, and shall not be
AIA DOCUMENT B751 • ABBREVIATED OWNER-A0.CHITER AGREEMENT • 7UNE 1978 EDITION • AIA�
m 1978 � THE AMERIUN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE� N.W.� WASHINGTON, D.0 20004 6151-'I978 �L
liable for the result of any interpretation or decision
rendered in good faith in such capaciry.
7.4.70 The Architect shall have authority to rejec[ Work
which does not conform to the Con[ract Documen[s, and
wili have authority to require speciai inspection or testing
of the Work whenever, in the Architect's reasonable opin-
ion, it is necessary or advisabie for the implementation of
the intent of the Contract Documents.
1.4.17 The Architect shall review and approve or take
other appropriate action upon the Contractor's submittais
such as Shop Drawings, Product Data and Samples, but
only for conformance with the design concept of the
Work and with the informa[ion given in the Contract
Documents. Such action shail be taken with reasonable
promptness so as [o cause no delay. The Archi[ec['s ap-
proval of a specific item shali not indicate approval of an
assembly of whichthe item is a component.
1.4.12 The Architect shall prepare Change Orders for the
Ownels approval and execu[ion, and shall have authority
to order minor changes in the Work not involving an
adjustment in the Contract Sum or an extension of the
Contract Time.
'f.4.13 The Architect shall conduct inspections to deter-
mine the Dates of Substantial Completion and final com-
pletion, and shall issue a final Certificate for Payment.
1.4.74 The extent of the duties, responsibilities and limita-
tions of authority of the Architect as the Owner's repre-
sentative during construction shall not be modified or ex-
tended without written consent of the Owner, the Con-
tracror and the Architect
�_5 ADDITIONAL SERVICES
1.i.1 Additional Services shall be provided if authorized
or confirmed in writing by the Owner or if included in
Article 10, and they shall be paid for by the Owner as
provided in this Agreement.
7.5.2 ff the Owner and the Architec[ agree that moie
extensive representation at the site than is described in
Paragraph �.4 shall be provided, s�ch additional project
representation shall be provided and paid for as set forth
in Article "10.
1.6 TIME
1.6.1 The Architect shall perform services as expediti-
ously as is consisten[ with professional skill and care and
the orderly progress of the Work.
ARTICLE 2
THE OWNER'S RESPONSIBILITIES
The following services and responsibilities, and
any others so indicated in Article 10, shall be un-
dertaken by the Owner.
2.1 The Owner shall provide full information including
a program, which shall set forth the Owner's design
objectives, constraints and criteria.
2.2 The Owner shall furnish a legal description and a
certifiied land survey of the site and the services of soil
engineers or other consultants when such services are
deemed necessary by the Architect.
2.3 The Owner shall furnish structural, mechanical,
chemical and other laboratory tests, inspections and re-
�/�O
ports as required by law or the Contrect Documents.
2.4 The Owner shall furnish all legal, accounting and
insurance counseling services as may be necessary at any
time for the Project, including such auditing services as
the Owner may require to verify [he Contmctor's Applica-
tions for Paymen[ or to ascertain how or for what pur-
poses the Contractor uses the moneys paid by the Owner.
2S The services, information, surveys and reports re-
quired by Paragraphs 2.2 through Z.4 inclusive shall 6e
furnished at the Ownels expense, and the Architect shall
be entitled to rely upon the accuracy and completeness
thereof.
2.6 If the Owner observes or othenvise becomes aware
of any fault or defect in the Project or nonconformance
with the ConVact Documents, prompt writ[en no[ice
thereof shali be given by the Owner to the Architect
2.7 The Owner shall furnish required information and
shall render approvals and decisions as expeditiously az
necer>ary for the orderly progress of the ArchitecPs serv-
ices and of the Work.
ARTICLE 3
CONSTRUCTION COST
3,� DEFINITION
3.1.1 The Construction Cost shall be the total cost or
estimated cost to the Owner of all elements of the Project
designed or specified by the Architect.
3.1.2 The Construction Cost shall indude at wrren[ mar-
ket rates, including a reasonable allowance for overhead
and profit, the cost of labor and materials furnished by
the Owner and any equipment which has been designed,
specified, selected or specially provided for by the Archi-
tect.
3.1.3 Construction Cos[ does not include the compensa-
tion of the Architect and the ArchitecYs consultants, the
cost of the land, rights-of-way, or other costs which are
the responsibility of [he Owner as provided in Ar[icle 2.
3.2 RESPONSIBILITY FOR CONSTRURION COST
3.2.'I It is recognized that neither [he Architect nor the
Owner has control over the cost of labor, materials or
equipment, over the Contrector's methods of determining
bid prices, or over competitive bidding, market or nego-
iiating conditions. Accordingly, the Architect cannot and
does not warrant or represent that bids or negotiated
prices will no[ vary from any Statement of Probable Con-
struction Cost or other cost estimate or evaluation pre-
pared by [he Architec[.
3.2.2 No fixed limit of Construction Cost shall be esub-
lished as a condition of this Agreement by the furnishing,
proposal or establishmen[ of a Projec[ budget, unless such
fixed limit has been agreed upon in writing and signed by
the parties hereto. If such a fixed limit has been estab-
lished, the Architect shall be permitted to include con-
tingencies for design, bidding and price escalation, to de-
termine what materials, equipment, component systems
and types of construc[ion are to be induded in the Con-
trac[ Documents, to make reasonable adjustments in the
scope of the Project and ro indude in the Contract Doc-
uments Alternate Bids to adj�st the Construction Cosi to
the fixed limit. Any such fixed limit shali be increased in
3 B751-1978 AIA DOCUMENT B751 • ABBREVIATED OWNER-ARCHITER AGREEMENT • JU�E 1978 EDITION • AIA•
O 1978 • THE AMEftIGN INSTITUTE OF ARCMITERS, 7735 NEW YORK AVENUE, N.W., 1YASHINGTON, D.0 30006
l�
(�
the amount of any increase in the Contract Sum ocwrring
after exewtion of the Contract for Construction.
3.2.3 Any Project budget or fixed limit of Construc[ion
Cost shall be adjusted to reflect any change in the general
level of prices in the construc[ion industry between the
date of submission of Ihe Construction Documents to the
Owner and the date on which proposals are sought.
3.2.4 If a fixed limit of Construction Cost (adjusted as
provided in Subparagraph 3.2.3) is exceeded by the low-
est bona fide bid or negotiated proposal, the Owner shall
('1) give written approval of an increase in such fixed limit,
(Z) authorize rebidding or renegotiating of the Project
within a reasonable time, (3) if the Project is abandoned,
terminate in accordance wi[h Paragraph 7.2, or (4) coop-
erate in revising the Projxt scope and quality as required
to reduce the Construction Cost. In the case of (4), pro-
vided a fixed limit of Construction Cost has been estab-
lished as a condition of this Agreement, the Architect,
without additional charge, shall modify the Drawings and
Specifications as necessary [o comply with the fixed limi[.
The providing of such service shall be the limit of the
Architect's responsibility arising from the establishment of
such fixed limit, and having done so, the Architect shall
be entitled to compensation for all services performed, in
accordance with this Agreement, whether or no[ the Con-
struction Phase is commenced.
ARTICLE 4
PAYMENTS TO THE ARCHITECT
4.1 An initial paymen[ as set forth in Paragraph 9.1 is
the minimum paymen[ under this Agreement,
4.2 Subsequent payments for Basic Services shall be
made monthly and shall be in proportion to services per-
formed within each Phase.
43 When compensation is based on a percentage of
Construction Cost, and any portions of the Project are
deleted or otherwise not constructed, compensation for
such portions of [he Project shall be payable to the extent
services are performed on such portions, in accordance
with the schedule set forth in Subparagreph 9.21, based
on (1) the lowest bona fide bid or negotiated proposal, or
(2) if no such bid or proposal is received, the most recent
SWtemen[ of Probable Construction Cost.
4.4 Reimbursable Expenses indude actual expenditures
made by the Architect in the interest of the Project for.
.1-ex�ensre��raas�ortatisa-arxi.l'wiwg-axpeaso�.in
cormectiotrwiNrovt-oFtewrrkaveF,-aathc�ti�ed-by
ttre-C3oaner,
.2 lon gdistartce�cemm�x� eatiot»,
3 fees paid for securing approvai of authorities hav-
ing jurisdic[ion over the Project,
.4 reproductions,
S pesi'agrared-�+andlirtg-ef-�ewengfar+d-Speeefier
tiertr,
.6 renderings and models requested by the Owner,
J expense of overfime work requiring higher than
regular rates, if authorized by the Owner,
.8 expense of any additional insurance coverage or
limits, including professional liability insurance,
requested by the Owner in excess of that normally
. v
carried by the Architect and the ArchitecYs con-
sultants.
4.5 Payments on account of [he Archi[ect's Additional
Services and for Reimbursable Expenses as defined in
Paragraph 4.4 shali be made monthly upon presentation
of the Architect's statement of services rendered or ex-
penses incurred.
4.6 No deductions shall be made from the Architect's
tompensation on account of sums withheld from pay-
ments to contractors.
4.7 If the Project is suspended or abandoned in whole
or in part for more than three months, the Architect shall
be compensated for all services performed prior to receipt
of writ[en no[ice from the Owner of such suspension or
abandonment, together with Reimbursable bcpenses then
due and all Termination Expenses as defined in Paragraph
7.4. If the Project is resumed after being suspended for
more than three months, the ArchitecYs compensation
shall be equitably adjusted.
ARTICLE 5
OWNERSHIP AND USE OF DOCUMENTS
5.1 Drawings and Specifications as instruments of serv-
ice are and sha�i remain the property of the Architect
whether the Project for which they are made is executed
or not. The Owner shall be permitted to reWin copies, in-
cluding reproducible copies, of Drawings and Specifira-
tions for information and reference in connection with
the Owner's use and occupancy of the Project. The Draw-
ings and Specifications shall not be used by the Owner on
other projects, for additions to this Project, or for com-
pletion of this Project by others provided the Architect is
not in default under this Agreement, except by agreemen[
in writing and with appropriate compensa[ion [o [he
Architect.
5.2 Submission or distribution to meet o�cial regula-
tory requirements or for other purposes in connection
with the Project is not to be construed as publication in
derogation of the Arthitect's rights.
ARTICLE 6
ARBITRATION
6.7 All claims, disputes and other matters in question
behveen the parties to this Agreement, arising out of or
relating to this Agreement or the breach thereof, shall be
decided by arbitration in accordance with the Construc-
tion Industry Arbitration Rules of the American Arbitra-
tion Association then obtaining unless the parties mutu-
ally agree otherwise. No arbitration, arising out of or re-
lating to this Agreement, shall include, by consolidation,
joinder or in any other manner, any additional person
not a party to [his Agreement excep[ by written consen[
containing a specific reference to this Agreement and
signed by the Architect, the Owner, and any other person
sought to be joined. Any consent to arbitration involving
an additional person or persons shall not constitute mn-
sent to arbitretion of any dispute not described therein.
This Agreement to arbitrate and any agreement to arbi-
trate with an additional person or persons duly tonsented
to by the parties to this Agreement shall be specifically
enforceable under the p�evailing ar6itration law.
AIA DOCUMENT 8751 ABBREVIATED OWNER-ARCHITECT ACREEMENT jUNE 19]8 E�ITION AIAO
O 79]8 • THE AMENIGN INST�TUTE OF ARCHITECTS,'1735 NEW YORK AVENUE•N.W., WASHINGTON� D.C. 2000G 6151-'1976 �}
,
6.2 In no event shall the demand for arbiiration be
made af[er the da[e when institution of legal or equitable
proceedings based on such claim, dispute or other matter
in question would be barred by the applicable sWtute of
limitations.
6.3 The award rendered by the arbitrators shail be
final, and judgment may be entered upon it in accordance
with applicable law in any court having jurisdiction
thereof.
ARTICLE 7
TERMINATION Of AGREEMENT
7.1 This Agreement may be terminated by ei[her party
upon seven days' written notice should the other party
fail substantiaily to perform in accordance with its terms
through no fault of the party initiating the termination.
7.2 This Agreement may be terminated by the Owner
upon at leas[ seven days' written notice to the Architect
in the event that the Project is permanently abandoned.
7.3 In the event of termination not the fault of the
Architect, the Architect shall be compensated for all
services performed to termination date, together with Re-
imbursable Expenses then due and all Termination Ex-
penses as defined in Paragraph 7.4.
7.4 Termination Expenses include expenses directly at-
tributable to termi�ation for which the Architect is noi
otherwise compensated, plvsan-amoaM-compvtedas�-
�erc�enf, aeof-thetetel-eamperrsef+aireamedtetF�etime
vf �erminatiort; as foFtows
.l -30� pef cmtif temnrmt iom�o¢a�ning-the-Design
-Phasr,-or- '
� ��
.2 'H�percenrif-tennirretiaeroeean�uring-the-6en-
strtxfien�Doetl menls�hese;ex
.3 Spercent-#-tcwnin�aEieROCeurs��+ing-any-w!>sr
ryuenE�ase.
ARTICLE 8
MISCELL4NEOU5 PROVIS10N5
8.1 This Agreement shall be governed by the law of
the principal place of business of the Architect
8.2 As between the parties to this Agreement: as to atl
acts or failures ro act by either parry to this Agreemeny
any applicable sWtute of limitations shall commence to
run and any alleged cause of action shali be deemed to
have accrued in any and all events not later than the
relevant Date of Substantial Completion of the Work, and
as to any acts or failures to act occurring after the relevant
Date of Substantial Completion, not later than the date of
issuance of the final Certificate for Payment.
8.3 The Owner and the Architect, respectively, bind
Ihemselves, their partners, successors, assigns and legal
representatives to the other party to this Agreement and
to the partners, successors, assigns and legal representa-
tives of such party with respect to all covenants of this
Agreement. Neither the Owner nor the Architect shall
assign, subiet or transfer any interest in this Agreement
without the written consent of the other.
8.4 This Agreement represents the entire and inte-
grated agreement between the Owner and the Architecl
and supersedes all prior negotiations, representations or
agreements, either written or oral. This Agreement may be
amended only by written instrument signed by both
Owner and Architect.
AIA DOCUMENT 6151 • ABBREVIATED OWNER-ARCHITECT ACREEMENT • �UNE 7978 EDITION • AIA�
S B'IS�-'I9%S p t9]8 • THE AMERiUN INSTITUTE OF ARCHITERS, 1735 NEW YORK AVENUE, N.W., W/SHINGTON, D.G 20006
�
���
ARTICLE 9
BA515 OF COMPENSATION
The Owner shall compensate the Architect for the Services provided, in accordance with Article 4, Payments to the
Architect, and the other Terms and Conditions of this Agreement, as follows:
9.7 AN INITIAL PAYMENT OF . NONE dollars (S 1
shall be made upon execution of this Agreement and credited to the Owner's account as follows:
9.2 BASICCOMPENSATION
9.2.'I FOR BASIC SERVICES, as described in Paragraphs 1.1 through 1.4 or identified as such in Article 10, Basic Com-
pensation shall be computed as follows:
(Herc insert 6uif ol compentation, i�rcluding fiaed amountr, multiples or percenbgez, and idenlify Phsses w which particula� methodi ol coor
Ptlltili0ll iPP�Y. Il IIKGfSif)'.) .
Fixed Fee . . . . . . . . . . . . . . . . . . . $5,800.00
9.2.2 Where compensation is based on a Stipulated Sum or Percentage of Constructio� Cosi, paymenGS for Basic Seo-
vices shall be made as provided in Subparagraph 4.2 so that Basic Compensation for each Phase shall equal the
foliowing percentages of the total Compensation payable: � �
9.3
9.4
9S
(Indude any additionil phuv u appropriateJ
Design Phase:
Construction Documenu Phase:
Bidding or Negotiation Phase:
Construction Phase:
Twenty-Five
Fifty
Twenty-Five
percent ( 2�/0)
percent W yo)
percent( %)
percent (ZS%)
FOR ADDITIONAt SERVICES provided under Paragraph 1.5 or identified as such in Article 10, compensation
shall be computed as folfows:
(Here intert buis ol compensatlon, including rates and/o� multlples ol Direct Personnel Erpense fo� Principafs, mnsultants and employees. ideo-
tily specific rypes ol crosulfinb in Artide 10, !f requiredJ
2.5 Times Direct Personnel Expense. �
Payments due the Architect and unpaid under this Agreement shall bear interest from the date payment is due
at the rate entered below, or in the absence thereof, at the legal rate prevailing at the principal place of busi-
ness of the Architect.
(Herc fnsvt any nte of (nterest agreed uponJ
After ninety days, 12$ per anmun.
(USmry laws and requirements under the fedenl Truth in Lending Atq similar slate and local consumer oedit laws and other reguhtions at Ne
Ownds and ArchitecCS principal plaas o/ 6usiness, the Ixalion ol rhe Project and elsewhwe may aHect the wlidiry al this prwision. Speci�c
legal advice shou/d 6e obhined wiN respect to deletion, modiFiation, or ofher requirements tu�h u written disdosures or waiverr.)
The Owner and the Architect agree in accordance with the Terms and Conditions of this Agreement that:
9.5.� IF THE SCOPE of [he Project or of the ArchitecYs Services is changed ma[erially, the amounts of compensation
shall be equitably adjusted.
9.5.2 IF THE SERVICES covered by this Agreement have not been completed witfiin twenty-four (?.4 ) months
of the date hereof, through no fault of the Architect, the amounts of compensation, rates and multiples set
forth herein shali be equitably adjusted.
AIA DOCUMEM 6151 • ABBREVIATED OWNER-ARCHITECT AGREEMENT • JUNE 1918 EDITION • AIA�
m 1978 • THE AMERIUN INSTITUTE OF ARCHITECTS� 1735 NEW YORK AVENUE, N.W., WASHINGTON� O.C. 20006 g�S�-i9iH (,
� r7
ARTICLE 10
OTHER CONDITIONS OR SERVICES
(Describe any services not induded above which are to be performed by the Architect or Owner. State whether ser-
vices to be provided 6y the Architect aie Basic Services or Additional Services.)
7his Agreement entered into as of the day and year first written above.
OWNER
csT�� eF osxicosx
INC.
AIA DOCUMENT B751 • ABBREVIATED OWNER-ARCHRER ACREEFtENT • JUNE t978 ED�TION • AUs
% BiS�-�9iS m 1978 • THE AMENIUN INSTITUTE Oi ARGHITECTS, 1]35 NEW YORK AVENUE, N.W., WASHINGTON, D.C. ]0006
�
�
�
REINKE • HANSCHE • LAST • INC •�ICI II�I�C�S
gp5 NORTH MAIN STiiEET • OSHKOSH, WISCONSIN 54901 • TELEPHONE 616 231-6930
��/�O
October 16, 1981
Mr. Boyd Kramer, Pa=ks Director
City of Oshkosh
215 Church St,
Oshkosh, WI 54901
RE: MENOPd2NEB PARK
BATH AOUSE RESTORATION
Dear Mr.-Kramer:
Thank you for the opportunity to be of service once again, and provide
our architectural services for the Parks Department. £nclosed please
£ind two (2) copies oE our StandaYd Agreement for Architectural Services
for the Renovation and Restoration of the Menominee Park Bath House.
This contract is being proposed for a lump sun fee with printing of .
documents either provided by the City of Oshkosh, or comgleted by our
office as an additional reimbursable expense.
We would like to start this project immediately, so quotations can be
received and construction started before freeze-up. Please let me
know when we can start.
One copy o£ the contract is for yo�r files and the second copy is
for our files.
If you have any questions relative to the contracts, please feel free
to contact me.
Ve Tr y Yours,
v` V�-_/ �
ONALD D. HANSCHE
RDH/dcb
Enc.
LEONARD H. REINKE fAIA RONALD D. HANSCHE A�A GEORGE w. LAST PE
fi'
N
r�-I
� N
N
1
U
m
��
c� �
N N
G�+ � N
� �
�ro}.�x
O +� U
r�
� +.��
� U X
°��a
ti
m
N
� �
P+ �
O
,d ..
6 b
N
o •�
H �
Fa
�
U
O
�
r-�
�
�
�
�;
�
2
�x
� U
, U