The URL can be used to link to this page

Home My WebLink About6479-Building/Electric (03/04/2002)' � INSPECTION SERVICES DIVISION ROOM 205 CITY OF OSHKOSH � t � DEPARTMENT OF COMMUNITY DEVELOPMENT 215 CHURCH AVE OSHKOSH CORRECTION NOTICE PO Box 1130 ON THE WATER OSHKOSH WI 54903-1130 Issue Date 3/4/02 Compliance Date 4!3/02 Compliance Yes Address 1522 JACKSON ST Name Address City State Zip Code SeRt to �wner ' LORUAMANIRGINI TAWAWILI 1522 JACKSON ST OSHKOSH WI 54901 -2942 Required for Occupancy � Occupancy Single Family Int duction — Following a complaint and an inspection, and investigation the violations listed below were noted.Letter sent 1/13/04-request or update and written sched for correction. Item# 1 Code MUN 7-31 Compliance Not Checked Compliance Date 03/31/2004 ----__ _- --- _ Description here is no record of a rough inspection being requested for the addition prior to the framming being concealed AT THE TIME FINAL INSPECTION WAS MADE IT IS NOT POSSIBLE TO ASSURE COMPLIANCE WITH THE CODE IN AREAS WHERE 4/20/04 ORK IS CONCEALED! Provide a detail of how the posts were secured to the beam supporting the Last oof.@@@@INSPECTION ON 3/31/04 Unable to determine connection details as work has been covered-due to time that Updated as past unabfe to identify violations remaining -- _ _. _ ____- Item# 2 Code Comm 21.04 Compliance Yes Comptiance Date 03/31/2004 IMMEDIATELY Description he handrails on the strairs do not meet graspability requirements. The dimension and configuration of the handrails are equired to meet the requirements of Comm 21.04@@@@O.K. at inspection made 3/31/04 4/20/04 Last Updated Item# 3 Code Comm 21.04 Compliance Yes Compliance Date 03/31/2004 IMMEDIATELY Description he risers on the stairs are not equal. The code allows a maximum of 3/16"in variation through out the entire stair. 4/20/04 Last Updated Item# 4 Code Comm 21.24 Compliance Yes Compliance Date 03/31/2004 IMMEDIATELY Description he exterior wall area below the door is required to be covered with a permanent weather resistant finish material-Currently here is only exposed untreated wood. 4/20/04 Last Updated Item# 5 Code MUN 25-76(c) Compliance Not Checked Compliance Date 04/03/2002 IMMEDIATELY Description Uniform house number(address)are required to be posted-No house numbers have been installed after the home was sided � These numbers are availale from the engineering dept on 3rd floor at City Hall. 4/20/04 Last Updated Item# 6 Code Comm 22.28 Compliance Yes Complia�ce Date 03/31l2004 IMMEDIATEIY Description he penetrafions of utlities(cables, pipes,etc)through the siding are required to be properly sealed.@@ � 4/20/04 Last Updated i 6479 Page 1 of 3 INSPECTION SERVICES DIVISION ROOM 205 CITY OF OSHKOSH � DEPARTMENT OF COMMUNITY DEVELOPMENT 215 CHURCH AVE � 1 OSHKOSH CORRECTION NOTICE PO Box 1130 ON THE WATER OSHKOSH WI 54903-1130 Issue Date 3/4/02 Compliance Date 4/3/02 Compliance Yes Address 1522 JACKSON ST Name Address City State Zip Code Sent to ✓ Owner �I LORUAMA/VIRGINI TAWAWILI 1522 JACKSON ST OSHKOSH WI 54901 -2942 Required for Occupency_� Occupancy Single Family Intr�duction Following a complaint and an inspection,and investigation the violations listed below were noted.Letter sent 1/13/04-request ' or update and written sched for correction. Item# 7 Code Nec 110 Compliance Yes Compliance Date 03/31/2004 IMMEDIATELY Description he electrical service is not properly secured to the building. 4/20/04 Last Updated ' --_ - Item# g Code NEC 370 Compliance Yes Compliance Date 03/31/2004 IMMEDIATELY Description here is no electrical box installed behind the newley installed light fixtures. 4/20/04 Last Updated 6479 Page 2 of 3 �1 INSPECTION SERVICES DIVISION ROOM 205 CITY OF OSHKOSH �� DEPARTMENT OF COMMUNITY DEVELOPMENT 215 CHURCH AVE OSHKOSH CORRECTION NOTICE PO Box 1130 ON THE WATER OSHKOSH WI 54903-1130 Issue Date 3/4/02 Compliance Date 4/3/02 Compliance Yes Address 1522 JACKSON ST Name Address City State Zip Code Sent to ✓ Owner LORUAMANIRGINI TAWAWILI 1522 JACKSON ST OSHKOSH WI 54901 -2942 Required for Occupancy Occupancy Single Family � Intr�duction - ��- ° --- --- . Following a complaint and an inspection, and investigation the violations listed below were noted.Letter sent 1/13/04-request or update and written sched for correction. Item# 9 Code NEC 110 Compiiance Yes Compliance Date 03/31/2004 IMMEDIATELY Description here is no connector where the cable enfers the Air conditioner disconnect@@ ' 4/20/04 Last Updated - � Summarv Please make the required corrections and arrange for a reinspection within the next 30 days. If you have any questions I can e reached at(920)236-5051.ALL ELECTRICAL VIOLATIONS ARE REQUIRED TO BE CORRECTED BY A LICENSED ELECTRICIAN!CORRECTION NOTICE FILE CLOSED-DOCUMENTS RELATED TO SUCH, INCLUDING COURT INFO INCLUDED IN THIS PACKET PLACED IN PROPERTY FILE. Violations must be corrected and approved within 30 days unless otherwise noted. Call for reinspections prior to concealment and/or occupancy. Upon completing the corrections,the owner/contractor/agent must sign and date at the bottom of this notice and return it to the Inspection Services Division by the Compliance Date of 4/3/02 Office hours for obtaining permits are Monday through Friday 7:30-8:30 a.m.and 12:30-1:30 p.m.or by appointment.To schedule inspections please call the Inspection Request line at 236-5128 noting the address,permit number(when applicable),and the nature of what needs to be inspected. Signature Date Inspected by: Brian Noe 236-5051 bnoe@ci.oshkosh.wi.us I hereby certify the violations listed on this report have been corrected in compliance with the applicable codes. Print Name Company Signature Date Also Sent to: ✓ B�dg PAT WONG WINDOW AND SIDING 2020 N BIRCHWOOD AVE APPLETON WI 54914 -0 Elec � __ ._ ___. _- --- HVAC ` —__ _- ------ _ - - — Plbg _ _ __ Designer - -_ ___--- — ✓ Other Arrow Elelctric _ 0 -0000 Inspector _ 6479 Page 3 of 3 Building Permit Work Card Job Address 1522 JACKSON ST Permit Number 0087096 Create Date 6/28/01 Owner LORUAMA/VIRGINIA TAWAWILI Contractor PAT WONG WINDOW AND SIDING Category 141 -Exterior Remodeling � Type � Building � Sign � Canopy � Fence 0 Raze �I Plan Zoning Class of Const: Size Value $22,000.00 Unfinished/Basement 0 Sq. FinishedlLiving 0 Sq.Ft. Garage 0 Sq.Ft. Ft. Rooms 0 Bedrooms 0 Baths 0 Projection '� �---- a , Stories Height 0 Ft. Canopies 0 Signs 0 Foundation � Poured Concrete � Floating Slab � Pier 0 Other � Concrete Block � Post 0 Treated Wood Occupany Permit Not Required Flood Plain Height Permit Not Required Park Dedication Not Required #Dwelling Units 0 #Structures 0 - -- — -- Use/Nature ��SFR/TEAR OFF ROOF ON HOUSE AND GARAGE AND RE-ROOF, REPLACE VINYL SIDING ON of Work HOUSE AND GARAGE,WINDOWS,ONE DOOR,5 SUN TUBES INSTALL NEW GUTTERS AND �DOWNSPOUTS *EIV FORM SIGNED BY ARROW ELECTRIC*' I _._---_— ` HVAC Contr Plumbing Contr Electric Contr Inspections ` Date 1/25/04 Type Final Inspector Brian Noe not approved - -- - -_ __ - -- -- .__ See additional note under permit#88517 I i I Date/Time requested: 4/20/04 03:21 PM Notice Type: Phone Number: Access: r - — __ __. _- ___ Ready Date/Time: 4/20/04 03:21 PM Requested By: � Reinspect Fee � Fee Waived ❑ Reinspect Fee Paid --------------------------------------------------------------------------------------------- Date 3/31/04 Type Reinspect Inspector Brian Noe approved see additional notes under permit#88517 I I � ' I I _J DatelTime requested: 4/20/04 03:21 PM Notice Type: Phone Number: Access: _- - _ ---._� Ready Date/Time: 4/20/04 03:21 PM Requested By: � Reinspect Fee � Fee Waived ❑ Reinspect Fee Paid --------------------------------------------------------------------------------------------- �12� �oz. - ��.�-t.'Y� R r'C,t 0,1�`P �o�'`-1 ,�� _ ,f b� Uf�N 1��. �: on �..n^ � _ }�� c�� '� �t�h5 i-+ fd��0�1 �'Zp�M _ _ ��7 0�G `�"b CG C� \�C`�.0 � ��( - ��..1c-v,D � b ��(�_ �ST �}��f C _ -- ��J� �`o _ C.�Y��^�y C.�R� __ _ ___ _ _ _ _ __ _ _ __ _ ._ _ ___ _ _ _ SENT BY: ; 9207452299; JUN-11 -02 2:37PM; PAGE 2/2 " !'I Secon d Look - Home Inspections A Division of Schwanke Inc. • P.O.BOX 27'31 -OSHKOSN,Wl 5�903•(920)745-2288•FAX:(920)745-2299 �OGpLLY OWNED AND OPERATED Virginia Tawawili 1522 Jackson St, Oshkosh, WI 54901 Re; 1 S22 Jackson St. Oshkosh June 11,2002 Virginia: 'Today on June 11, 20�2,I inspected the attic:and roof systetn for the abave property and the following are my finclings: The roof shows soft spongy areas suTrou�din�,tlie chitz�ncy with the chimney showing settlement into thi5 soft roof area,which has caused the liner and masonry cap to separate ,° is esent between the chimney cap!chimney �nd t�om the nnasonrY chimney. A 1 �ap Pf the flue is loose snd cap could fa11 of�:'I'he shcathing and chimney should have been corrected before xoofing.Uneven shingling tows were alsu present_ Itt the attic,a ridge vent was installed incorrectly with o oyg�l"on�e �u�d 4of the : ventilation opening present, "1'his venCilQiion is only exp ridge board systEm. A ridge vent is improper insta�llation on a h�tpthre�afters im1 Frop�rly� ridge boatd present. W�en ridge vent was insta.��o�e�d el ven� Only a sheet meta] and felt paper presently covers `/'of the opening 8 pi�e w�s used to cover previaus roof vent holes at�d this is spongy c�nd op��t Attic possibility of being da�aSed. No pro�er soffit ve�iting or soffit chutes are pre ventilation is extremely inadequ�te. Regarding the list of city code compliance corrections, none uf pa�t 1 has bee�n �mp�eted. At►electti�ian has completed pages 2 &3 Res ctf ll S brcutt � ent chwanke President Wisco nsin State Gereified Home Inspeator•Member ot Housing Inspection Foundetion•Registered Home lnspecior(RHl) For Official Use STATE OF WISCONSIN, CIRCUIT COURT, COUNTY Case Caption Subpoena and PQ-� �f��9 �'��da W � �;d,;,� us Certificate of Appearance ' ��uarrlq., �'C�wacc�i �i +P� c�( Case No,.�floa S �- Oc�oc7 S� • The State of Wisconsin to (Witness Name and Address): Service Information �r(q n �Q e Date Served Time Served Fee Charged �/ �'�'l a �ooi. 7;3a �!M $ l�. 3 �S�c�0� i3(�� d��9 �'�5��L�..r,Y Manne of Service Witness Fee � Personal Enclosed ❑ SUbStItUtB: $ Serving Agency Serve51 Qy(Slgnature) �/ � j � �� You are re uired to a ear and ive evidence: APPEARANCE INFORMATION Date Time Location(Include Room Number) �ett�. M �, o�.C9C9Z, ID:c9D ffM ��c},►�e�-► 5e� �ert„ e�ur�' �'vvh�ssioi,e.. Presiding Official Cd�r+h�u s e r2 v�.-v� 3 �j g y�1 S T0.C<<So ti STi—e�T Ka ve n S� i �v�'� �v u v� �D YY��'S5l o r�er (9 k Ko h , w 1 sz(d o 1 On Behalf Of Type of Proceeding U�r �n' a� � Lni2 �t � �l� S�, c(��w, (-��ar �n � You are further required to bring with you the following: A'�''� �c��,.n e n`fs � PJo.o Ia s ��c . a.s rnay b e n �e ��ed �,i,- t�v u�- �-5�.'wi o n y r e��l►-d�� -l�� P�Per�-Y et f l S z � Jc��l�Cson �f-►-t�f^ l.cJl ..SZf4o � ❑ This is a third-party subpoena. Unless all parties agree otherwise, do not provide any requested items before the date and time of the above proceeding. Failure to appear may result in punishment for contempt, which may include monetary penalties, imprisonment and other sanctions. If ou ave an uestions about this sub ena, lease contact: Issuin Of icial Nam or Print) By: � Title Telephone Number � Address Signature �l5 J Date For Court Use Onl Witness Information Witness Certificate of A earance Telephone Number Date Witness Appeared Mileage Address Corredion Signature of Witness GF-126,11/99 Subpoena and Certificate ot Appearance §§805.07,885.02 and 885.03,Wisconsin Statutes This form shall not be modified.It may be supplemented with additional material. 5 May 8, 2002 State of Wisconsin Pat Wong Window& Siding vs. Loruama and Virginia Tawawili Case No. 2002SC000058 Court Official Karen Seifert, Court Commissioner CIRCUIT COURT WINNEBAGO COUNTY STATE OF WISCONSIN Summary Statement Re: Sm. Claim I am here because I believe the plaintiff has not completed the home improvement contract. I ha.ve already paid $26,818 for a new roof, siding, replacement windows, solar tubes, and a new front porch. I have withheld $3,286.13 until the plaintiff ha.s completed the rest of the contract; corrected the 9 building code violations; and, reedited the complaints about the work conforming to the standard of trade in workmanship, which he received during the court ordered mediation session. Since that mediation session I have not heard one iota from Mr. Wong. My complaints are governed by the Wisconsin Administrative Code, Agriculture, Trade and Consumer Protection (ATCP) 110 regarding Home Improvement Practices .The plaintiff has a copy of those complaints and I've given you a copy a well. I have subpoenaed Brian Noe, Oshkosh Building Inspector who will corroborate the fact that Mr. Wong has not answered the 9 violations included in my complaint. I will offe�ibits, which will also show that the work that has been completed is already, begun defective. I believe I was enticed to signing a very vague contract by many verbal promises ` made by the plaintiff and he has defaulted in the stand measure of practice in workmanship. Under ATCP 110.02(2)[g] he has failed to perform certain functions. For example, the photos show that the solar tubes have not been installed correctly and leak. I believe the integrity of a sealed roof has been put at risk because the tubes were installed ` more than a month after the roof was completed. The front door handle has not been installed properly and has come loose several times. The deadbolt lock does not secure because it, or the door was not installed and secured to the standard of the profession. I have purchased for Mr. Wong the required house numbers and the door bells (2) but he has made to attempt to contact me to fix these problems. My closing argument is to ask the court to consider the state statues that authorize payrnent for the damages that I have incurred, twice the amount of the pecuniary damages plus all court costs a maximum of$5,000 (small claims max.). Based on the amount of money($23,818) I have already paid, I ask the court to find the following misrepresentations and enticements. by direct and indirect implication by his verbal promised and behavior regarding the entire work,the problems and violations listed in detail below. I request the court to dismiss the plaintifPs claim and order a judgment of $5000 for my counter claim plus costs. I filed a counter-suit against Pat Wong Window& Siding because Mr. Wong demanded from me the balance of $3,286.13 (plus interest) after he forced his way into � my home, unannounced and uninvited, and then tried to intimidate me with threats to start ripping of the siding if I didn't pay up, or file a lien on me. It was late October, • 2001, and the verbal contract we made in April, 2001, had still not been completed. These are the items under contention: 1. "To sweeten the pot" some more, he agreed that instead of installing the "6`n„ solar tube through the roof that was already done, he would install a new range hood with outside vent (which I would purchase) at no additional cost. At the end he said that type of installation was structurally impossible to do, and has refused to follow through. Since the contract specified 6 solar tubes to be installed and only 5 were, I believe that arrangement would have been a fair trade-off. 2. At the beginning and throughout the work in progress, I kept asking for reassurance that the new eaves would not leak or create big icicles around the house. He promised that it would not happen and I would be very happen with the quality of the work. Photos attached speak for themselves; and those were taken in late February, 20002, when I realized I would need proof, even though the icicles pictures were not at their winter worst. When I called him in October to complain there were already drips from the seams, he did send over a man to make some adjustments. However, it did not remedy the ice build up in the winter. 3. I have no copy of the building plans that Mr. Wong submitted to the Building inspector, so I don't know if the finished job is what he told the inspector he would do. 4. I have no warranties for the materials and supplies, or services used for this home improvement job. Wisconsin State Administrative Codes described below, state that I have the right to expect copies of the warranties for the roofing materials, the siding, the 14 double hung replacement windows,the sofit, fascia, eaves, porch construction, labor, etc. 5. The contract was signed in Apri122; Mr. Wong promised he would begin my job the following Monday because he was just finishing up another house on East New Your Ave. in Oshkosh. As it happens I pass that sight each day on my way to work. The job was fmished within that ne� week as he said;however, only a dumpster(rented from Johnson's in Neenah) arrived in my driveway in May but the roofing work did not begin until June 8, 2001. There were frequent intervals of 2-3 weeks, between the times laborers came and went, leaving work unfinished. The dumpster was not removed until the end of August. 6. Mr. Wong wrongly states in his small claims complaint that the entire job was completed by August 30,200L However,there were still unresolved problems and work(i.e. range vent installation) in mid October. The following is an itemized account of the numerous violations of the Wisconsin Administrative Codes under Chapter 110: Home improvement Practices. This counter-claim if based on violations of Wisconsin Agriculture, trade & Consumer Protection (ATCP) law regarding Home Improvement Practices : Chapter ATCP 110. • We, the buyer, Virginia Tawawili and my husband Loruama Tawawili, to a home improvement contract for our residence at 1522 Jackson Street, Oshkosh entered into a "Home Improvement contract" with Pat Wong Widow& Siding which by definition (ATCP 110.02 [4] means "an oral or written agreement between a seller(Pat Wong) and an owner (V. &L. Tawawili). Part of my counter-complaint is in reference to one of the many verbal enticements Mr. Wong used to influence me to sign the written contract rather than choose the other contractor I had spoken with earlier that day. Mr. Wong indicated that he really wanted my job because he was trying to build name recognition in Oshkosh, and with the finishing of the Jackson Street construction he wanted to put out his company ' sign on our lawn because Jackson Street would be a busy thoroughfare and our home would really look sharp as people drove by. I have since come to learn that under Wisconsin Chapter ATCP110.02 [1] Prohibited trade practices, Mr. Wong lured me into thinking that his work would be like a"model" or"advertising job."In addition, Mr. Wong insisted upon showing me his papers proving that he was the only certified distributor of the brand of siding we were discussing. (Once the job was started, after a lengthy delay, Mr. Wong had no physical hand in the installation of the siding.) He insisted that I see the actual documentation which said he had the only certified right to buy and install that siding;this was "misrepresentation directly or by implication that products or materials to be used"ATCP110.02 (2) [b,f] and ATCP 110.02 (4) [b,c]."Misrepresent the status , authority or position of the sales representative.. which he represents." At this time, and repeatedly, Mr. Wong reassured me that he would personally be present to see to it that"the job would be done right." As the duration of the home improvement job became longer than the standard of practice for such work, I called Mr. Wong on three occasions to inquire why the eaves and downspouts had not yet been installed; since we were ha.ving so much rain that mother I wanted to be sure the roof was completed and secure against the weather. Mr. Wong each time he spoke about the matter I said the delay was due to the fact that the eaves and downspouts were backordered because there were specially made and that's why it was taking so long. This misrepresentation is a violation of ATCP 110.02 (3)[e,fJ. Two hours prior to my 6:00 PM meeting with Mr. Wong I interviewed another : contractor, John Calkins,ARMR, who made me a better price offer for the roofing job. I compared Mr. Wong's quote with the Mr. Calkin's quote. Mr. Wong said he really wanted the job so he would "sweeten the pot" for me by offering to "throw in the difference" in price between the fiberglass shingles with 30# felt that I originally wanted, ' but now for the same price as the asphalt shingles so we could finish the contract right away. He asked if it would be all right to make that a verbal agreement, because I could trust him, and it save time and extra paperwork which he had he already had filled out. TRUST being my hot button, I said OK. However, after the roof was finished, and I had an independent contractor examine the shingles, my suspicions were confirmed that the usual asphalt, not fiberglass shingles, had been used. I believe this is bait selling and is in violation of ATCP 110.02 (3) [a,b,d].I felt like I had been enticed and deceived. In addition, as our initial contract negotiations did not convince me to hire Mr. Wong, he volunteered to "sweeten the pot"again and"throw in" a decorative door and side panel • to dress up the finished new siding's appearance. Under ATCP 110.02(11)this was another violation. Another major violation is ATCPI 10.03 (1,2)regarding building permits. I refer : the details to Brian Noe, Oshkosh City Building inspector who will explain the nine(9) violations that come under this portion of the state code. Mr. Wong assured me he would take care of the necessa.ry building permits. However, not once nor ever, has there been any building or electrical permit issued from the City of Oshkosh placed in the usually designated location on our residence. Additionally, midpoint and final inspections have not been requested as are required by state law and city ordinances. In respect to ATCP 110.04 Warranties. (1) "A seller shall give a buyer a copy of every written warranty made with respect to labor, services, products or materials furnished in connection with home improvement. If the seller makes any oral warranty, the seller shall document that warranty in writing and give a copy to the buyer. The seller shall provide all warranty documents to the buyer at the time the buyer enters into a home improvement contract, except that a manufacturer's produce wananty may be provided when that product is installed. (2) If a seller warrants any labor, service...with the home improvement,the warranty shall be clear and specific and shall clearly specify all of the following: [a] Any warranty conditions or exclusions. [b] Any limitations on the scope or duration of the warranty. [c] The time period within which the seller will perform the seller's warranty obligations... (3)No seller may give any warranty which the seller does not intend to honor in full..." Throughout the entire home improvement period, from contract to the 2°d payrnent, Mr. Wong only verbally emphasized that he would guarantee the workmanship of the job and if there were ANY problems he would guarantee the cost of any labor that would be involved in making corrections. It was not until the 2"d payment tha.t I became aware that I was entitled to warranties for all the materials used on my home. In fact, I still do not know the name of the company that manufactured the replacement windows,the roof, or the siding, let alone have any copies of the warranties and specifications for installation, which may have a negative effect, should there be problems with the ma.terials. Mr. Wong failed to comply with ATCP 110.05 Home Improvement contract requirements (1,2 [a,b,d,fJ), which expressly describe the Wisconsin Administrative code for written contracts between seller and buyer. Another complaint that has not been addressed by Mr. Wong is in regard to the general contractor and subcontractor's under Pat Wong Window& Siding. On at least four separate phone calls with Mr. Wong I asked, even demanded, that I be given the names, addresses, and phone numbers of the men who worked on the roof. The solar tubes,the siding, and the new porch. Mr. Wong not only refused the give me those names, but sa.id he would not because these people had stolen equipment from him and . since one man was an alcoholic, he wanted to protect me from such"bad"character. On one telephone conversation Mr. Wong said he didn't want me to get misled by one of the workers because he (Wong ) was going to take him to court for his own reasons. Later, as � I persisted in another call, Wong said he would give me the man's name only after I had paid Pat Wong Window& Siding for the job. This violates ATCPl 10.05 (6)that states • that the name and address of a person other than the seller if he is to act as the general contractor. Finally, In violation of"ATCP 110.07 Contract cancellation; return of payments. (1) Condition warranting exercise of buyer's remedies. If, under a home improvement contract, a buyer pays a seller for any home improvement materials or services before the seller provides those materials or services to the buyer, the buyer may proceed under sub.(2)if any of the following occurs: (a)The seller fails to provide the materials or services by a deadline specified in the home improvement contract. (b) The seller fails to give notice of an impending delay as required (s) ATCP 110.02(7)[c],or fails to obtain the buyer's agreement to a new performance deadline (c) The buyer believes that the seller has failed to provide the materials in a timely manner, and the home improvement contract specifies no deadline for the seller to provide the materials or services. (2) Buyer's remedies: If conditions under sub(1) are met, he buyer may do all of the following: [a] Cancel the contract... [d] Demand a written accounting for all payments tha.t the buyer made to the seller. The written accounting shall detail how all the payments were used by the seller." r �� Q' '�/�'� ��l`� '�+� _ �'��/-��QJ�C �-�°� �-,��`�� .-- �►��r�� s�� ._ �.��.�a- _.. �� ._ - �,aS ►,�.� -.�� •.a�«�� .��y.,� _ . .�� ` 1 TO DATE � TIME ut-- � � �IS v�.� PM � FROM � �P J� PHONE( ) � � ; A OF CELL( ) � V �J �?.EC� Fwt( ) 'YZ6-�I�S"�. : N / z2— J� � E nn � E � . � S — . fr° .( ' EA � J � E � a � Z/ E-MAILADDRESS SiGNED pt{p��p� �� CEpT�URNED� SEE YOU�❑ AGAIN�❑ WAS IN � URGENT� s- jE ) f ♦ N • � E � � d � � City of Oshkosh � � Inspection Services Division 215 Church Avenue �.�KQ�H PO Box 1130 Oshkosh WI 54903-1130 � ON THE WATER Brian Noe o: J EFF From: (920)236-5051 bnoe@ci.oshkosh.wi.us �ce Hours 7:30 to 8:30 and 12:20 to 1:30 Fax: 1.{�,,(o- y 2-� Pages: �p � Phone• Date: 3— (p-b Z, Re: ��ZZ J P�C�.�SO�J C: ` � �� ❑ Urgent �'For Review �Please Comment ❑Please Repty ❑Please Recycle € � �-��s �. �, q t�� 2 A� 3 -�� '�- ; �� s�,� `?�o��- ��t r��p,��c.� ov�e � �,� . r�.s� r� 6�-,-- KrZ i� �"�� ,v r sT�o,.�� -� 1�'�L�' � � � fNSPECTION SERVICES DIVISION CITY OF OSHKOSH � � DEPARTMENT OF COMMUNITY DEVELOPMENT 215 CHURCH AVE OSHKOSH OSHKOSH WI 54901 ON THE WATER CORRECTION NOTICE Issue Date 3/4/02 Compliance Date 4/3/02 Compliance No Address 1522 JACKSON ST Inspected By Brian Nce 236-5051 Name Address City State Zip Code Sent to ✓ Owner LORUAMANIRGINI TAWAWILI 1522 JACKSON ST OSHKOSH WI 54901 -2942 ' ✓ Contractor PAT WONG WINDOW AND SIDING 2020 N BIRCHWOOD AVE APPLETON WI 54914 -0000 ✓ Other Arrow Elelctric _ 0 -0000 Inspector Required for Occupancy Occupancy Single Family Notice First Final Other Introduction ollowing a complaint and an inspection,and investigation the violations listed below were noted. Item# 1 Code MUN 7-31 Compliance No Compliance Date 04/03/2002 Description here is no record of a rough inspection being requested for the addition prior to the framming being concealed AT THE TIME FINAL INSPECTION WAS MADE IT IS NOT POSSIBLE TO ASSURE COMPLIANCE WITH THE CODE IN AREAS WHERE ORK IS CONCEALED! Provide a detail of how the posts were secured to the beam supporting the roof. Item# 2 Code Comm 21.04 Compliance No Compliance Date 04/03/2002 IMMEDIATELY � Description he handrails on the strairs do not meet graspability requirements. The dimension and configuration of the handrails are equired to meet the requirements of Comm 21.04@@@@ f r Item# 3 Code Comm 21.04 Compliance No Compliance Date 04l03/2002 IMMEDIATELY Description he risers on the stairs are not equal. The code allows a maximum of 3/16"in variation through out the entire stair. Item# 4 Code Comm 21.24 Compliance No Compliance Date 04/03/2002 IMMEDIATELY s Description he exterior wall area below the door is required to be covered with a permanent weather resistant finish material-Currently here is only exposed untreated wood. Item# 5 Code MUN 25-76(c) Compliance No Compliance Date 04/03/2002 IMMEDIATELY Description Uniform house number(address)are required to be posted-No house numbers haue been installed after the home was sided These numbers are availale from the engineering dept on 3rd floor at Ciry Hall. Page 1 of 3 ' � INSPECTION SERVICES DIVISION CITY OF OSHKOSH , � DEPARTMENT OF COMMUNITY DEVELOPMENT 215 CHURCH AVE OSHKOSH OSHKOSH WI 54901 ON THE WATER CORRECTION NOTICE Issue Date 3/4/02 Compliance Date 4/3/02 Compliance No Address 1522 JACKSON ST Inspected By Brian Noe 236-5051 Name Address City State Zip Code Sent to ✓ Owner LORUAMANIRGINI TAWAWILI 1522 JACKSON ST OSHKOSH WI 54901 -2942 ' ✓ Contractor PAT WONG WINDOW AND SIDING 2020 N BIRCHWOOD AVE APPLETON WI 54914 -0000 ✓ Other Arrow Elelctric 0 -0000 Inspector Required for Occupancy Occupancy Sing►e Family Notice First Finai Other Introduction Following a complaint and an inspection,and investigation the violations listed below were noted. Item# g Code Comm 22.28 Compliance No Compliance Date 04/03/2002 IMMEDIATELY Description he penetrations of utlities(cables, pipes,etc)through the siding are required to be properly sealed.@@ Item# 7 Code Nec 110 Compliance No Compliance Date 04/03/2002 IMMEDIATELY Description he electrical service is not properly secured to the building. Item# 8 Code NEC 370 Compliance No Compliance Date 04/03/2002 IMMEDIATELY Description here is no electrical box installed behind the newley installed light fixtures. Page 2 of 3 �'� INSPECTION SERVICES DIVISION CITY OF OSHKOSH � �� DEPARTMENT OF COMMUNITY DEVELOPMENT 215 CHURCH AVE OSHKOSH OSHKOSH WI 54901 ON THE WATER CORRECTION NOTICE Issue Date 3!4/02 Compliance Date 4/3/02 Compliance No Address 1522 JACKSON ST Inspected By Brian Nce 236-5051 Name Address City State Zip Code Sent to ✓ Owner LORUAMA/VIRGINI TAWAWILI 1522 JACKSON ST OSHKOSH WI 54901 -2942 ' ✓ Contractor PAT WONG WINDOW AND SIDING 2020 N BIRCHWOOD AVE APPLETON WI 54914 -0000 ✓ Other Arrow Elelctric _ 0 -0000 Inspector Required for Occupancy Occupancy Single Family Notice First Final Other Introduction Following a complaint and an inspection,and investigation the violations listed below were noted. Item# g Code NEC 110 Compliance No Compliance Date 04/03/2002 IMMEDIATELY Description here is no connector where the cable enters the Air conditioner disconnect@@ Summarv Please make the re uired corrections and arran e for a reins ection within the next 30 da s. If ou have an q g p y y y questions I can e reached at(920)236-5051.ALL ELECTRICAL VIOLATIONS ARE REQUIRED TO BE CORRECTED BY A LICENSED ELECTRICIAN! DEFICIENCIES MUST BE CO D APPROVED BEFORE CONCEALMENT. CALL(920)236-5050 FOR INSPECTION. Signature Date � yG Z Page 3 of 3 Date: February 28, 2002 Subject: Construction work at 1522 Jackson Street, Oshkosh,WI List of Complaints/Demands (not in order of importance) ❑ Warranty and installation `specs' papers for all newly installed replacement window products ❑ Warranty and installation specs papers for(5) solar tubes ❑ Warranty papers for roofmg installation or materials ❑ As an enticement to sign contract with PW, he promised to substitute fiberglass (shake-look) shingles for eye appeal but did not follow through ❑ Names and phone numbers of all subcontractors used on work site o Leaking solar tube in kitchen ❑ Deadbolt lock on new front entry door fails to operate(misaligned?) ❑ Contract called for install of 6 solar tubes—verbal agreement made with PW to substitute purchase and installation of the 6`h solar tube in exchange for installation of new range outside eachaust vent ❑ Installation of solar tubes done after the mofing was complete,thereby putting at risk the integrity of roofing application ❑ Failure to install new fascia boazd around roof as per contract- stain marks already obvious around fascia ❑ Continued leaking from inside and outside corners of roof gutters especially at entry areas and front steps ❑ PW failed to comply with verbal promises about adjusting previously existing patio door a PW failed to post the required purple Oshkosh(city ordinance)building permit placard during entire process of work ❑ Center post of new front porch split open already ❑ Construction of left and right sides of front porch attachment to the house do not match