Loading...
HomeMy WebLinkAboutReinke, Hansche, Last, Inc./South Side Lighted Diamond T H E A M E R I C A N I N S T I T U T E O F A R C H I T E C T S ORO AIA Document B151 Abbreviated Form of Agreement Between Owner and Architect for Construction Projects of Limited Scope 1987 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION. AGREEMENT made as of the Fifth day of February in the year of Nineteen Hundred and Eighty Eight BETWEEN the Owner: (Name and address) City Of Oshkosh 215 Church Avenue Oshkosh, WI 54901 and the Architect: (Name and address) Reinke, Hansche, Last, Inc. 805 N. Main Street Oshkosh, WI 54901 For the following Project: (Include detailed description of Project, location, address and scope.) City of Oshkosh Parks Department New Comfort Station/Storage Building South Side Lighted Diamond Sawyer Avenue Oshkosh, WI RHL Project No. 788 The Owner and Architect agree as set forth below. Copyright 1974,1978,©1987 by The American Institute of Architects,1735 New York Avenue,N.W.,Washington,D.C.20006. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA° •©1957 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C.20006 B151-1987 1 TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT ARTICLE 1 2.4 CONSTRUCTION PHASE—ADMINISTRATION OF THE CONSTRUCTION CONTRACT ARCHITECT'S RESPONSIBILITIES 2.4.1 The Architect's responsibility to provide Basic Services 1.1 ARCHITECT'S SERVICES for the Construction Phase under this Agreement commences with the award of the Contract for Construction and terminates 1.1.1 The Architect's services consist of those services per- at the earlier of issuance to the Owner of the final Certificate for formed by the Architect,Architect's employees and Architect's Payment or 60 days after the date of Substantial Completion of consultants as enumerated in Articles 2 and 3 of this Agreement the Work, unless extended under the terms of Subparagraph and any other services included in Article 12. 10.2.3. 1.1.2 The Architect's services shall be performed as expedi 2.4.2 The Architect shall provide administration of the Con- tiously as is consistent with professional skill and care and the tract for Construction as set forth below and in the edition of orderly progress of the Work. AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. 1.1.3 The services covered by this Agreement are subject to the time limitations contained in Subparagraph 11.5.1. 2.4.3 Duties,responsibilities and limitations of authority of the Architect shall not be restricted, modified or extended without written agreement of the Owner and Architect with consent of the Contractor, which consent shall not be unreasonably withheld. 2.4.4 The Architect shall be a representative of and shall advise and consult with the Owner(1)during construction until final ARTICLE 2 payment to the Contractor is due and(2)as an Additional Ser- vice at the Owner's direction from time to time during the cor- SCOPE OF ARCHITECT'S BASIC SERVICES rection period described in the Contract for Construction. 2.1 DEFINITION 2.4.5 The Architect shall visit the site at intervals appropriate to the stage of construction or as otherwise agreed by the 2.1.1. The Architect's Basic Services consist of those described Owner and Architect in writing to become generally familiar under the three phases indentified below, any other services with the progress and quality of the Work completed and to identified in Article 12,and include normal structural,mechani- determine in general if the Work is being performed in a man- cal and electrical engineering services. ner indicating that the Work when completed will be in accor- dance with the Contract Documents. However, the Architect 2.2 DESIGN PHASE shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On 2.2.1 The Architect shall review with the Owner alternative the basis of on-site observations as an architect, the Architect approaches to design and construction of the Project. shall keep the Owner informed of the progress and quality of the Work, and shall endeavor to guard the Owner against 2.2.2 Based on the mutually agreed-upon program, schedule defects and deficiencies in the Work. (More extensive site and construction budget requirements, the Architect shall representation may be agreed to as an Additional Service, as prepare, for approval by the Owner, Design Documents con- described in Paragraph 3.2.) sisting of drawings and other documents appropriate for the Project,and shall submit to the Owner a preliminary estimate of 2.4.6 The Architect shall not have control over or charge of Construction Cost. and shall not be responsible for construction means,methods, techniques, sequences or procedures,or for safety precautions 2.3 CONSTRUCTION DOCUMENTS PHASE and programs in connection with the Work, since these are solely the Contractor's responsibility under the Contract for 2.3.1 Based on the approved Design Documents,the Architect Construction. The Architect shall not be responsible for the shall prepare, for approval by the Owner, Construction Docu- Contractor's schedules or failure to carry out the Work in ments consisting of Drawings and Specifications setting forth in accordance with the Contract Documents. The Architect shall detail the requirements for the construction of the Project and not have control over or charge of acts or omissions of the shall advise the Owner of any adjustments to previous Contractor, Subcontractors,or their agents or employees,or of preliminary estimates of Construction Cost. any other persons performing portions of the Work. 2.3.2 The Architect shall assist the Owner in connection with 2.4.7 The Architect shall at all times have access to the Work the Owner's responsibility for filing documents required for wherever it is in preparation or progress. the approval of governmental authorities having jurisdiction over the Project. 2.4.8 Based on the Architect's observations and evaluations of the Contractor's Applications for Payment, the Architect shall 2.3.3 Unless provided in Article 12, the Architect, following review and certify the amounts due the Contractor. the Owner's approval of the Construction Documents and of the latest preliminary estimate of Construction Cost,shall assist 2.4.9 The Architect's certification for payment shall constitute the Owner in obtaining bids or negotiated proposals and assist a representation to the Owner, based on the Architect's obser- in awarding and preparing contracts for construction. vations at the site as provided in Subparagraph 2.4.5 and on the AIA DOCUMENT B151 •ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA® •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON, D.C. 20006 B151-1987 2 • data comprising the Contractor's Application for Payment,that they shall be paid for by the Owner as provided in this Agree- the Work has progressed to the point indicated and that,to the ment. Such Additional Services shall include, in addition to best of the Architect's knowledge, information and belief, those described in Paragraphs 3.2 and 3.3, budget analysis, quality of the Work is in accordance with the Contract Docu- financial feasibility studies,' planning surveys, environmental ments. The issuance of a Certificate for Payment shall not be a studies, measured drawings of existing conditions, coordina- representation that the Architect has (1) made exhaustive or tion of separate contractors or independent consultants, coor- continuous on-site inspections to check the quality or quantity dination of construction or project managers, detailed Con- of the Work,(2)reviewed construction means,methods, tech- struction Cost estimates,quantity surveys,interior design,plan- niques, sequences or procedures,(3)reviewed copies of requi- ping of tenant or rental spaces, inventories of materials or sitions received from Subcontractors and material suppliers and equipment,preparation of record drawings,and any other ser- other data requested by the Owner to substantiate the Contrac- vices not otherwise included in this Agreement under Basic Ser- tor's right to payment or(4)ascertained how or for what pur- vices or not customarily furnished in accordance with generally pose the Contractor has used money previously paid on accepted architectural practice. account of the Contract Sum. 3.2 If more extensive representation at the site than is 2.4.10 The Architect shall have authority to reject Work which described in Subparagraph 2.4.5 is required, such additional does not conform to the Contract Documents and will have project representation shall be provided and paid for as set authority to require additional inspection or testing of the forth in Articles 11 and 12. Work whenever, in the Architect's reasonable opinion, it is necessary or advisable for the implementation of the intent of 3.3 As an Additional Service in connection with Change the Contract Documents. Orders and Construction Change Directives, the Architect shall prepare Drawings,Specifications and other documentation and 2.4.11 The Architect shall review and approve or take other data, evaluate Contractor's proposals, and provide any other appropriate action upon Contractor's submittals such as Shop services made necessary by such Change Orders and Construc- Drawings, Product Data and Samples, but only for the limited tion Change Directives. purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect's action shall be taken with such reasonable promptness as to cause no delay. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component.When professional certification of performance characteristics of materials, systems or equip- ARTICLE 4 ment is required by the Contract Documents, the Architect shall be entitled to rely upon such certification to establish that OWNER'S RESPONSIBILITIES the materials,systems or equipment will meet the performance criteria required by the Contract Documents. 4.1 The Owner shall provide full information,including a pro- gram The Architect shall prepare Change Orders and Con- gram which shall set forth the Owner's objectives, schedule, constraints, budget with reasonable contingencies,and criteria. struction Change Directives, with supporting documentation and data if authorized or confirmed in writing by the Owner as 4.2 The Owner shall furnish surveys describing physical char- provided in Paragraphs 3.1 and 3.3, for the Owner's approval acteristics, legal limitations and utility locations for the site of and execution in accordance with the Contract Documents, the Project, a written legal description of the site and the ser- and may authorize minor changes in the Work not involving an vices of geotechnical engineers or other consultants when such adjustment in the Contract Sum or an extension of the Contract services are requested by the Architect. Time which are not inconsistent with the intent of the Contract Documents. 4.3 The Owner shall furnish structural, mechanical, chemical, air and water pollution tests, tests for hazardous materials, and 2.4.13 The Architect shall conduct inspections to determine other laboratory and environmental tests, inspections and the dates of Substantial Completion and final completion and reports required by law or the Contract Documents. shall issue a final Certificate for Payment. 4.4 The Owner shall furnish all legal,accounting and insurance 2.4.14 The Architect shall interpret and decide matters con- counseling services as may be necessary at any time for the cerning performance of the Owner and Contractor under the Project, including auditing services the Owner may require to requirements of the Contract Documents on written request of verify the Contractor's Applications for Payment or to ascertain either the Owner or Contractor. The Architect's response to how or for what purposes the Contractor has used the money such requests shall be made with reasonable promptness and paid by the Owner. within any time limits agreed upon. When making such inter- pretations and initial decisions, the Architect shall endeavor to 4.5 The foregoing services, information, surveys and reports secure faithful performance by both Owner and Contractor, shall be furnished at the Owner's expense, and the Architect shall not show partiality to either, and shall not be liable for shall be entitled to rely upon the accuracy and completeness results of interpretations or decisions so rendered in good faith. thereof. 4.6 Prompt written notice shall be given by the Owner to the Architect if the Owner becomes aware of any fault or defect in ARTICLE 3 the Project or nonconformance with the Contract Documents. ADDITIONAL SERVICES 4.7 The proposed language of certificates or certifications requested of the Architect or Architect's consultants shall he 3.1 Additional Services shall be provided if authorized or con- submitted to the Architect for review and approval at least 14 firmed in writing by the Owner or if included in Article 12,and days prior to execution. A1A DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•ALA° •01987 3 B151-1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON, D .20006 ARTICLE 5 ARTICLE 6 CONSTRUCTION COST USE OF ARCHITECT'S DRAWINGS, SPECIFICATIONS AND OTHER DOCUMENTS 5.1 DEFINITION 6.1 The Drawings, Specifications and other documents pre- 5.1.1 The Construction Cost shall be the total cost or esti- pared by the Architect for this Project are instruments of the mated cost to the Owner of all elements of the Project designed Architect's service for use solely with respect to this Project, or specified by the Architect. and the Architect shall be deemed the author of these docu- 5.1.2 The Construction Cost shall include the cost at current ments and shall retain all common law, statutory and other market rates of labor and materials furnished by the Owner and reserved rights, including the copyright. The Owner shall be equipment designed, specified, selected or specially provided permitted to retain copies, including reproducible copies, of for by the Architect, plus a reasonable allowance for the Con- the Architect's Drawings, Specifications and other documents tractor's overhead and profit. In addition, a reasonable allow- for information and reference in connection with the Owner's ance for contingencies shall be included for market conditions use and occupancy of the Project. The Architect's Drawings, at the time of bidding and for changes in the Work during Specifications or other documents shall not be used by the construction. Owner or others on other projects,for additions to this Project or for completion of this Project by others,unless the Architect 5.1.3 Construction Cost does not include the compensation of is adjudged to be in default under this Agreement, except by the Architect and Architect's consultants, the costs of the land, agreement in writing and with appropriate compensation to the rights-of-way, financing or other costs which are the respon- Architect. sibility of the Owner as provided in Article 4. 6.2 Submission or distribution of documents to meet official 5.2 RESPONSIBILITY FOR CONSTRUCTION COST regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in deroga- 5.2.1 It is recognized that neither the Architect nor the Owner tion of the Architect's reserved rights. has control over the cost of labor,materials or equipment,over the Contractor's methods of determining bid prices, or over competitive bidding,market or negotiating conditions.Accord- ingly, the Architect cannot and does not warrant or represent ARTICLE 7 that bids or negotiated prices will not vary from any estimate of ARBITRATION Construction Cost or evaluation prepared or agreed to by the Architect. 7.1 Claims, disputes or other matters in question between the 5.2.2 No fixed limit of Construction Cost shall be established parties to this Agreement arising out of or relating to this Agree- as a condition of this Agreement by the furnishing,proposal or ment or breach thereof shall be subject to and decided by arbi- establishment of a Project budget, unless a fixed limit has been tration in accordance with the Construction Industry Arbitra- agreed upon in writing and signed by the parties hereto. Fixed tion Rules of the American Arbitration Association currently in limits, if any, shall be increased in the amount of an increase in effect unless the parties mutually agree otherwise. No arbitra- the Contract Sum occurring after execution of the Contract for tion arising out of or relating to this Agreement shall include,by Construction. consolidation, joinder or in any other manner, an additional 5.2.3 Any Project budget or fixed limit of Construction Cost person or entity not a party to this Agreement,except by writ- ten consent containing a specific reference to this Agreement may be adjusted to reflect changes in the general level of prices signed by the Owner,Architect,and any other person or entity in the construction industry between the date of submission of sought to be joined. Consent to arbitration involving an addi- the Construction Documents to the Owner and the date on tional person or entity shall not constitute consent to arbitra- which proposals are sought. tion of any claim, dispute or other matter in question not 5.2.4 If a fixed limit of Construction Cost is exceeded by the described in the written consent. The foregoing agreement to lowest bona fide bid or negotiated proposal, the Owner shall: arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by the parties to this Agree- .1 give written approval of an increase in such fixed ment shall be specifically enforceable in accordance with appli- limit; cable law in any court having jurisdiction thereof. .2 authorize rebidding or renegotiating of the Project 7.2 In no event shall the demand for arbitration be made after within a reasonable time; the date when institution of legal or equitable proceedings .3 if the Project is abandoned, terminate in accordance based on such claim,dispute or other matter in question would with Paragraph 8.3; or be barred by the applicable statutes of limitations. .4 cooperate in revising the Project scope and quality as required to reduce the Construction Cost. 7.3 The award rendered by the arbitrator or arbitrators shall be final,and judgment may be entered upon it in accordance with 5.2.4 If the Owner chooses to proceed under Clause 5.2.4.4, applicable law in any court having jurisdiction thereof. the Architect, without additional charge, shall modify the Con- tract Documents as necessary to comply with the fixed limit,if established as a condition of this Agreement. The modification ARTICLE 8 of Contract Documents shall he the limit of the Architect's responsibility arising out of the establishment of a fixed limit. TERMINATION, SUSPENSION OR ABANDONMENT The Architect shall he entitled to compensation in accordance with this Agreement for all services performed whether or not 8.1 This Agreement may be terminated by either party upon the Construction Phase is commenced. not less than seven days' written notice should the other party AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE, N.W.,WASHINGTON, D.C. 20006 B151-1987 4 fail substantially to perform in accordance with the terms of this ditions of the Contract for Construction,current as of the date Agreement through no fault of the party initiating the ter- of this Agreement. The Owner and Architect each shall require mination. similar waivers from their contractors, consultants and agents. 8.2 If the Project is suspended by the Owner for more than 30 9.5 The Owner and Architect, respectively, bind themselves, consecutive days, the Architect shall be compensated for ser- their partners, successors, assigns and legal representatives to vices performed prior to notice of such suspension. When the the other party to this Agreement and to the partners, suc- Project is resumed,the Architect's compensation shall be equit- cessors, assigns and legal representatives of such other party ably adjusted to provide for expenses incurred in the interrup- with respect to all covenants of this Agreement.Neither Owner tion and resumption of the Architect's services. nor Architect shall assign this Agreement without the written 8.3 This Agreement may be terminated by the Owner upon consent of the other. not less than seven days' written notice to the Architect in the 9.6 This Agreement represents the entire and integrated agree- event that the Project is permanently abandoned. If the Project ment between the Owner and Architect and supersedes all is abandoned by the Owner for more than 90 consecutive days, prior negotiations, representations or agreements, either writ- the Architect may terminate this Agreement by giving written ten or oral. This Agreement may be amended only by written notice. instrument signed by both Owner and Architect. 8.4 Failure of the Owner to make payments to the Architect in 9.7 Nothing contained in this Agreement shall create a contrac- accordance with this Agreement shall be considered substantial tual relationship with or a cause of action in favor of a third nonperformance and cause for termination. party against either the Owner or Architect. 8.5 If the Owner fails to make payment when due the Archi- 9.8 The Architect and Architect's consultants shall have no tect for services and expenses, the Architect may, upon seven responsibility for the discovery,presence,handling,removal or days'written notice to the Owner,suspend performance of ser- disposal of or exposure of persons to hazardous materials in vices under this Agreement. Unless payment in full is received any form at the Project site, including but not limited to by the Architect within seven days of the date of the notice,the asbestos,asbestos products,polychlorinated biphenyl(PCB)or suspension shall take effect without further notice.In the event other toxic substances. of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. 8.6 In the event of termination not the fault of the Architect, the Architect shall be compensated for services performed prior ARTICLE 10 to termination, together with Reimbursable Expenses then due and all Termination Expenses. PAYMENTS TO THE ARCHITECT 8.7 Termination Expenses are in addition to compensation for 10.1 DIRECT PERSONNEL EXPENSE Basic and Additional Services, and include expenses which are directly attributable to termination. 10.1.1 Direct Personnel Expense is defined as the direct salaries of the Architect's personnel engaged on the Project and the portion of the cost of their mandatory and customary con- tributions and benefits related thereto, such as employment taxes and other statutory employee benefits, insurance, sick ARTICLE 9 leave, holidays, vacations, pensions and similar contributions MISCELLANEOUS PROVISIONS and benefits. 10.2 REIMBURSABLE EXPENSES 9.1 Unless otherwise provided, this Agreement shall be gov- erned by the law of the principal place of business of the 10.2.1 Reimbursable Expenses include expenses incurred by Architect. the Architect in the interest of the Project for: 9.2 Terms in this Agreement shall have the same meaning as .1 expense of transportation and living expenses in con those in AIA Document A201, General Conditions of the Con- nection with out-of-town travel authorized by the tract for Construction,current as of the date of this Agreement. Owner; .2 long-distance communications; 9.3 Causes of action between the parties to this Agreement .3 fees paid for securing approval of authorities having pertaining to acts or failures to act shall be deemed to have jurisdiction over the Project; accrued and the applicable statutes of limitations shall cotn- mence to run not later than either the date of Substantial Com- .4 reproductions; pletion for acts or failures to act occurring prior to Substantial .5 postage and handling of Drawings and Specifications; Completion, or the date of issuance of the final Certificate for .6 expense of overtime work requiring higher than regu- Payment for acts or failures to act occurring after Substantial lar rates, if authorized by the Owner; Completion. .7 renderings and models requested by the Owner; 9.4 The Owner and Architect waive all rights against each .8 expense of additional insurance coverage or limits, other and against the contractors, consultants, agents and including professional liability insurance, requested employees of the other for damages, but only to the extent by the Owner in excess of that normally carried by covered by property insurance during construction, except the Architect and Architect's consultants; and such rights as they may have to the proceeds of such insurance .9 expense of computer-aided design and drafting equip- as set forth in the edition of AIA Document A201,General Con- ment time when used in connection with the Project. AIA DOCUMENT B151 •ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA° •©1987 5 B151-1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON, D.C. 20006 10.3 PAYMENTS ON ACCOUNT OF BASIC SERVICES forth in Subparagraph 11.2.2,based on(1)the lowest bona fide bid or negotiated proposal, or(2)if no such bid or proposal is 10.3.1 An initial payment as set forth in Paragraph 11.1 is the received,the most recent preliminary estimate of Construction minimum payment under this Agreement. Cost or detailed estimate of Construction Cost for such por- 10.3.2 Subsequent payments for Basic Services shall be made [ions of the Project. monthly and, where applicable, shall be in proportion to ser 10.4 PAYMENTS ON ACCOUNT OF ADDITIONAL vices performed within each phase of service. SERVICES AND REIMBURSABLE EXPENSES 10.3.3 If and to the extent that the time initially established in Subparagraph 11.5.1 of this Agreement is exceeded or ex- 10.4.1 Payments on account of the Architect's Additional Ser- tended through no fault of the Architect,compensation for any vices and for Reimbursable Expenses shall be made monthly services rendered during the additional period of time shall be upon presentation of the Architect's statement of services computed in the manner set forth in Subparagraph 11.3.2. rendered or expenses incurred. 10.3.4 When compensation is based on a percentage of Con- 10.5 PAYMENTS WITHHELD struction Cost and any portions of the Project are deleted or otherwise not constructed,compensation for those portions of 10.5.1 No deductions shall be made from the Architect's corn- the Project shall be payable to the extent services are per- pensation on account of sums withheld from payments to formed on those portions, in accordance with the schedule set contractors. ARTICLE 11 BASIS OF COMPENSATION The Owner shall compensate the Architect as follows: None Required 11.1 AN INITIAL PAYMENT OF Dollars OA- shall be made upon execution of this Agreement and credited to the Owner's account at final payment. 11.2 BASIC COMPENSATION 11.2.1 FOR BASIC SERVICES,as described in Article 2, and any other services included in Article 12 as part of Basic Services,Basic Compensation shall be computed as follows: (Insert basis of compensation,including stipulated sums,multiples or percentages,and identify phases to which particular methods of compensation apply,if necessary.) Basic Compensation will be invoiced at the Direct Personnel Expense for employees times a multiplier of three (3) with a maximum not to exceed Six Thousand Five Hundred Dollars ( $6 , 500 . 00) for services through bidding. 11.2.2 Where compensation is based on a stipulated sum or percentage of Construction Cost,progress payments for Basic Services in each phase shall total the following percentages of the total Basic Compensation payable: (Insert additional phases as appropriate.) N/A Design Phase: percent( %) Construction Documents Phase: percent( %) Construction Phase: percent( %) Total Basic Compensation: one hundred percent(100%) AIA DOCUMENT B151 •ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA® •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON, D.C. 20006 8151-1987 6 11.3 COMPENSATION FOR ADDITIONAL SERVICES 11.3.1 FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES, as described in Paragraph 3.2, compensation shall be computed as follows: Three (3) times Direct Personnel Expense. 11.3.2 FOR ADDITIONAL SERVICES OF THE ARCHITECT provided under Article 3 or identified in Article 12,compensation shall be computed as follows: (Insert basis of compensation, including rates and/or multiples of Direct Personnel Expense for Principals and employees, and identify Principals and classify employees, if required. Identify specific services to which particular methods of compensation apply. if necessary.) Three (3) times Direct Personnel Expense. 11.3.3 FOR ADDITIONAL SERVICES OF CONSULTANTS,including additional structural,mechanical and electrical engineering ser- vices and those provided under Article 3 or identified in Article 12 as part of Additional Services,a multiple of fifteen percent ( 1 . 15 )times the amounts billed to the Architect for such services. (Identify specific types of consultants in Article 12, if required.) 11.4 REIMBURSABLE EXPENSES 11.4.1 FOR REIMBURSABLE EXPENSES,as described in Paragraph 10.2,and any other items included in Article 12 as Reimbursable Expenses, a multiple of fifteen percent ( 1 . 15 )times the expenses incurred by the Architect, the Architect's employees and consultants in the interest of the Project. 11.5 ADDITIONAL PROVISIONS 11.5.1 IF THE BASIC SERVICES covered by this Agreement have not been completed within twelve ( 12 )months of the date hereof,through no fault of the Architect,extension of the Architect's services beyond that time shall be compensated as provided in Subparagraphs 10.3.3 and 11.3.2. 11.5.2 Payments are due and payable thirty (30) days from the date of the Architect's invoice.Amounts unpaid thirty (30) days after invoice date shall bear interest from the date payment is due at the rate entered below, or in the absence thereof, at the legal rate prevailing from time to time at the principal place of business of the Architect. (Insert any rate of interest agreed upon.) (Usury laws and requirements under the Federal Truth in Lending Act,similar state and local consumer credit laws and other regulations at the Owner's and Archi- tect's principal places of business, the location of the Project and elsewhere may affect the validity of this provision. Specific legal advice should he obtained with respect to deletions or modifications, and also regarding requirements such as written disclosures or waivers.) 11.5.3 The rates and multiples set forth for Additional Services shall be annually adjusted in accordance with normal salary review practices of the Architect. AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•ALA® •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C.20006 B151-1987 7 ARTICLE 12 OTHER CONDITIONS OR SERVICES (Insert descriptions of other services, identify Additional Services included within Basic Compensation and modifications to the payment and compensation terms included in this Agreement.) 12 . 1 Bidding Phase City of Oshkosh will provide all services during bidding. The City will provide all construction documents to bidders, printed from originals furnished by Reinke, Hansche, Last, Inc. City of Oshkosh will distribute all plans and receive bids. APPROVED , C o r , s . t t ! 2(� 0 1 OSHKOSH,WISCONSIN 1 �-c3CJl1.-'Cc��l�V�=��"^ This Agreement entered into as of the day and year first written above. OWNER C ' ty of Os::: AR: Rein , Hansche, Last, Inc . W' e" . P. Prue 9o:ha C. SFr as (Signature) ' (Si: ■ture) Ronald D. Hansche (Printed name and title) (Printed name and title) AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA® •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C.20006 8151-1987 8 1 H E A M E R I C A N I N S T I T U T E O F A R C H I T E C T S LIfrA v:114 AIA Document B151 Abbreviated Form of Agreement Between Owner and Architect for Construction Projects of Limited Scope 1987 EDITION THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES; CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION. AGREEMENT made as of the Fifth day of February in the year of Nineteen Hundred and Eighty Eight BETWEEN the Owner: (Name and address) City 'of Oshkosh 215 Church Avenue Oshkosh, WI 54901 and the Architect: (Name and address) Reinke, Hansche, Last, Inc. 805 N. Main Street Oshkosh, WI 54901 For the following Project: (Include detailed description of Project, location, address and scope.) City of Oshkosh Parks Department New Comfort Station Fugleburg Park (South Side Bathing Beach) South Main Street Oshkosh, WI RHL Project No. 688 The Owner and Architect agree as set forth below. Copyright 1974, 1978,©1987 by The American Institute of Architects, 1735 New York Avenue,N.W.,Washington,D.C.20006. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will be subject to legal prosecution. AIA DOCUMENT B151 •ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•ADO' •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C. 20006 B151-1987 1 TERMS AND CONDITIONS OF AGREEMENT BETWEEN OWNER AND ARCHITECT ARTICLE 1 2.4 CONSTRUCTION PHASE—ADMINISTRATION OF THE CONSTRUCTION CONTRACT ARCHITECT'S RESPONSIBILITIES 2.4.1 The Architect's responsibility to provide Basic Services 1.1 ARCHITECT'S SERVICES for the Construction Phase under this Agreement commences with the award of the Contract for Construction and terminates 1.1.1 The Architect's services consist of those services per- Payment the earlier of issuance to the Owner of the final Certificate for formed by the Architect,Architect's employees and Architect's Payment or 60 days after the date of Substantial Completion of consultants as enumerated in Articles 2 and 3 of this Agreement the Work, unless extended under the terms of Subparagraph and any other services included in Article 12. 10.2.3. 1.1.2 The Architect's services shall be performed as expedi- 2.4.2 The Architect shall provide administration of the Con- tiously as is consistent with professional skill and care and the tract for Construction as set forth below and in the edition of orderly progress of the Work. AIA Document A201, General Conditions of the Contract for Construction, current as of the date of this Agreement. 1.1.3 The services covered by this Agreement are subject to the time limitations contained in Subparagraph 11.5.1. 2.4.3 Duties,responsibilities and limitations of authority of the Architect shall not be restricted,modified or extended without written agreement of the Owner and Architect with consent of the Contractor, which consent shall not be unreasonably withheld. 2.4.4 The Architect shall be a representative of and shall advise and consult with the Owner(1)during construction until final ARTICLE 2 payment to the Contractor is due and(2)as an Additional Ser- vice at the Owner's direction from time to time during the cor- SCOPE OF ARCHITECT'S BASIC SERVICES rection period described in the Contract for Construction. 2.1 DEFINITION 2.4.5 The Architect shall visit the site at intervals appropriate to the stage of construction or as otherwise agreed by the 2.1.1. The Architect's Basic Services consist of those described Owner and Architect in writing to become generally familiar under the three phases indentified below, any other services with the progress and quality of the Work completed and to identified in Article 12,and include normal structural,mechani determine in general if the Work is being performed in a man cal and electrical engineering services. ner indicating that the Work when completed will be in accor- dance with the Contract Documents. However, the Architect 2.2 DESIGN PHASE shall not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. On 2.2.1 The Architect shall review with the Owner alternative the basis of on-site observations as an architect, the Architect approaches to design and construction of the Project. shall keep the Owner informed of the progress and quality of the Work, and shall endeavor to guard the Owner against 2.2.2 Based on the mutually agreed-upon program, schedule defects and deficiencies in the Work. (More extensive site and construction budget requirements, the Architect shall representation may be agreed to as an Additional Service, as prepare, for approval by the Owner, Design Documents con- described in Paragraph 3.2.) sisting of drawings and other documents appropriate for the Project,and shall submit to the Owner a preliminary estimate of 2.4.6 The Architect shall not have control over or charge of Construction Cost. and shall not be responsible for construction means, methods, techniques, sequences or procedures,or for safety precautions 2.3 CONSTRUCTION DOCUMENTS PHASE and programs in connection with the Work, since these are solely the Contractor's responsibility under the Contract for 2.3.1 Based on the approved Design Documents,the Architect Construction. The Architect shall not be responsible for the shall prepare, for approval by the Owner, Construction Docu- Contractor's schedules or failure to carry out the Work in ments consisting of Drawings and Specifications setting forth in accordance with the Contract Documents. The Architect shall detail the requirements for the construction of the Project and not have control over or charge of acts or omissions of the shall advise the Owner of any adjustments to previous Contractor,Subcontractors,or their agents or employees,or of preliminary estimates of Construction Cost. any other persons performing portions of the Work. 2.3.2 The Architect shall assist the Owner in connection with 2.4.7 The Architect shall at all times have access to the Work the Owner's responsibility for filing documents required for wherever it is in preparation or progress. the approval of governmental authorities having jurisdiction over the Project. 2.4.8 Based on the Architect's observations and evaluations of the Contractor's Applications for Payment, the Architect shall 2.3.3 Unless provided in Article 12, the Architect, following review and certify the amounts due the Contractor. the Owner's approval of the Construction Documents and of the latest preliminary estimate of Construction Cost,shall assist 2.4.9 The Architect's certification for payment shall constitute the Owner in obtaining bids or negotiated proposals and assist a representation to the Owner, based on the Architect's obser- in awarding and preparing contracts for construction. vations at the site as provided in Subparagraph 2.4.5 and on the AIA DOCUMENT B151 •ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA® •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C. 20006 B151-1987 2 data comprising the Contractor's Application for Payment,that they shall be paid for by the Owner as provided in this Agree- the Work has progressed to the point indicated and that,to the ment. Such Additional Services shall include, in addition to best of the Architect's knowledge, information and belief, those described in Paragraphs 3.2 and 3.3, budget analysis, quality of the Work is in accordance with the Contract Docu- financial feasibility studies; planning surveys, environmental ments. The issuance of a Certificate for Payment shall not be a studies, measured drawings of existing conditions, coordina- representation that the Architect has (1) made exhaustive or tion of separate contractors or independent consultants, coor- continuous on-site inspections to check the quality or quantity dination of construction or project managers, detailed Con- of the Work,(2)reviewed construction means,methods, tech- struction Cost estimates,quantity surveys,interior design,plan- niques,sequences or procedures,(3)reviewed copies of requi- ping of tenant or rental spaces, inventories of materials or sitions received from Subcontractors and material suppliers and equipment,preparation of record drawings,and any other ser- other data requested by the Owner to substantiate the Contrac- vices not otherwise included in this Agreement under Basic Ser- tor's right to payment or(4)ascertained how or for what pur- vices or not customarily furnished in accordance with generally pose the Contractor has used money previously paid on accepted architectural practice. account of the Contract Sum. 3.2 If more extensive representation at the site than is 2.4.10 The Architect shall have authority to reject Work which described in Subparagraph 2.4.5 is required, such additional does not conform to the Contract Documents and will have project representation shall be provided and paid for as set authority to require additional inspection or testing of the forth in Articles 11 and 12. Work whenever, in the Architect's reasonable opinion, it is 3.3 As an Additional Service in connection with Change necessary or advisable for the implementation of the intent of Orders and Construction Change Directives,the Architect shall the Contract Documents. prepare Drawings, Specifications and other documentation and 2.4.11 The Architect shall review and approve or take other data, evaluate Contractor's proposals, and provide any other appropriate action upon Contractor's submittals such as Shop services made necessary by such Change Orders and Construe- Drawings, Product Data and Samples, but only for the limited tion Change Directives. purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect's action shall be taken with such reasonable promptness as to cause no delay. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component.When professional certification of performance characteristics of materials, systems or equip- ARTICLE 4 ment is required by the Contract Documents, the Architect shall be entitled to rely upon such certification to establish that OWNER'S RESPONSIBILITIES the materials,systems or equipment will meet the performance criteria required by the Contract Documents. 4.1 The Owner shall provide full information, including a pro- gram which shall set forth the Owner's objectives, schedule, 2.4.12 The Architect shall prepare Change Orders and Con- constraints, budget with reasonable contingencies,and criteria. struction Change Directives, with supporting documentation and data if authorized or confirmed in writing by the Owner as 4.2 The Owner shall furnish surveys describing physical char- provided in Paragraphs 3.1 and 3.3, for the Owner's approval acteristics, legal limitations and utility locations for the site of and execution in accordance with the Contract Documents, the Project, a written legal description of the site and the ser- and may authorize minor changes in the Work not involving an vices of geotechnical engineers or other consultants when such adjustment in the Contract Sum or an extension of the Contract services are requested by the Architect. Time which are not inconsistent with the intent of the Contract Documents. 4.3 The Owner shall furnish structural, mechanical, chemical, air and water pollution tests, tests for hazardous materials, and 2.4.13 The Architect shall conduct inspections to determine other laboratory and environmental tests, inspections and the dates of Substantial Completion and final completion and reports required by law or the Contract Documents. shall issue a final Certificate for Payment. 4.4 The Owner shall furnish all legal,accounting and insurance 2.4.14 The Architect shall interpret and decide matters con- counseling services as may be necessary at any time for the cerning performance of the Owner and Contractor under the Project, including auditing services the Owner may require to requirements of the Contract Documents on written request of verify the Contractor's Applications for Payment or to ascertain either the Owner or Contractor. The Architect's response to how or for what purposes the Contractor has used the money such requests shall be made with reasonable promptness and paid by the Owner. within any time limits agreed upon. When making such inter- pretations and initial decisions, the Architect shall endeavor to 4.5 The foregoing services, information, surveys and reports secure faithful performance by both Owner and Contractor, shall be furnished at the Owner's expense, and the Architect shall not show partiality to either, and shall not be liable for shall be entitled to rely upon the accuracy and completeness results of interpretations or decisions so rendered in good faith. thereof. 4.6 Prompt written notice shall be given by the Owner to the Architect if the Owner becomes aware of any fault or defect in ARTICLE 3 the Project or nonconformance with the Contract Documents. ADDITIONAL SERVICES 4.7 The proposed language of certificates or certifications requested of the Architect or Architect's consultants shall be 3.1 Additional Services shall be provided if authorized or con- submitted to the Architect for review and approval at least 14 firmed in writing by the Owner or if included in Article 12,and days prior to execution. AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA° •©1987 3 B151-1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON, D.C. 20006 ARTICLE 5 ARTICLE 6 CONSTRUCTION COST USE OF ARCHITECT'S DRAWINGS, SPECIFICATIONS AND OTHER DOCUMENTS 5.1 DEFINITION 6.1 The Drawings, Specifications and other documents pre- 5.1.1 The Construction Cost shall be the total cost or esti- pared by the Architect for this Project are instruments of the mated cost to the Owner of all elements of the Project designed Architect's service for use solely with respect to this Project, or specified by the Architect. and the Architect shall be deemed the author of these docu- 5.1.2 The Construction Cost shall include the cost at current ments and shall retain all common law, statutory and other market rates of labor and materials furnished by the Owner and reserved rights, including the copyright. The Owner shall be equipment designed, specified, selected or specially provided permitted to retain copies, including reproducible copies, of for by the Architect, plus a reasonable allowance for the Con- the Architect's Drawings, Specifications and other documents tractor's overhead and profit. In addition, a reasonable allow- for information and reference in connection with the Owner's ance for contingencies shall be included for market conditions use and occupancy of the Project. The Architect's Drawings, at the time of bidding and for changes in the Work during Specifications or other documents shall not be used by the construction. Owner or others on other projects,for additions to this Project or for completion of this Project by others,unless the Architect 5.1.3 Construction Cost does not include the compensation of is adjudged to be in default under this Agreement, except by the Architect and Architect's consultants, the costs of the land, agreement in writing and with appropriate compensation to the rights-of-way, financing or other costs which are the respon- Architect. sibility of the Owner as provided in Article 4. 6.2 Submission or distribution of documents to meet official 5.2 RESPONSIBILITY FOR CONSTRUCTION COST regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in deroga- 5.2.1 It is recognized that neither the Architect nor the Owner tion of the Architect's reserved rights. has control over the cost of labor,materials or equipment,over the Contractor's methods of determining bid prices, or over competitive bidding,market or negotiating conditions.Accord- ingly, the Architect cannot and does not warrant or represent ARTICLE 7 that bids or negotiated prices will not vary from any estimate of ARBITRATION Construction Cost or evaluation prepared or agreed to by the Architect. 7.1 Claims, disputes or other matters in question between the 5.2.2 No fixed limit of Construction Cost shall be established parties to this Agreement arising out of or relating to this Agree- as a condition of this Agreement by the furnishing,proposal or ment or breach thereof shall be subject to and decided by arbi- establishment of a Project budget, unless a fixed limit has been tration in accordance with the Construction Industry Arbitra- agreed upon in writing and signed by the parties hereto. Fixed tion Rules of the American Arbitration Association currently in limits,if any, shall be increased in the amount of an increase in effect unless the parties mutually agree otherwise. No arbitra- the Contract Sum occurring after execution of the Contract for tion arising out of or relating to this Agreement shall include,by Construction. consolidation, joinder or in any other manner, an additional person or entity not a party to this Agreement, except by writ- 5.2.3 Any Project budget or fixed limit of Construction Cost ten consent containing a specific reference to this Agreement may be adjusted to reflect changes in the general level of prices signed by the Owner,Architect,and any other person or entity in the construction industry between the date of submission of sought to he joined. Consent to arbitration involving an addi- the Construction Documents to the Owner and the date on tional person or entity shall not constitute consent to arbitra- which proposals are sought. tion of any claim, dispute or other matter in question not 5.2.4 If a fixed limit of Construction Cost is exceeded by the described in the written consent. The foregoing agreement to lowest bona fide hid or negotiated proposal, the Owner shall: arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by the parties to this Agree- .1 give written approval of an increase in such fixed ment shall be specifically enforceable in accordance with appli- limit; cable law in any court having jurisdiction thereof. .2 authorize rebidding or renegotiating of the Project 7.2 In no event shall the demand for arbitration he made after within a reasonable time; the date when institution of legal or equitable proceedings .3 if the Project is abandoned, terminate in accordance based on such claim,dispute or other matter in question would with Paragraph 8.3; or be barred by the applicable statutes of limitations. .4 cooperate in revising the Project scope and quality as required to reduce the Construction Cost. 7.3 The award rendered by the arbitrator or arbitrators shall be final,and judgment may be entered upon it in accordance with 5.2.4 If the Owner chooses to proceed under Clause 9.2.4.4, applicable law in any court having jurisdiction thereof. the Architect, without additional charge, shall modify the Con- tract Documents as necessary to comply with the fixed limit,if established as a condition of this Agreement. The modification ARTICLE 8 of Contract Documents shall be the limit of the Architect's responsibility arising out of the establishment of a fixed limit. TERMINATION, SUSPENSION OR ABANDONMENT The Architect shall he entitled to compensation in accordance with this Agreement for all services performed whether or not 8.1 This Agreement may be terminated by either party upon the Construction Phase is commenced. not less than seven days' written notice should the other party AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA° •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON, D.C. 20006 B151-1987 4 10.3 PAYMENTS ON ACCOUNT OF BASIC SERVICES forth in Subparagraph 11.2.2,based on(1)the lowest bona fide bid or negotiated proposal, or(2)if no such bid or proposal is 10.3.1 An initial payment as set forth in Paragraph 11.1 is the received,the most recent preliminary estimate of Construction minimum payment under this Agreement. Cost or detailed estimate of Construction Cost for such por- 10.3.2 Subsequent payments for Basic Services shall be made tions of the Project. monthly and, where applicable, shall be in proportion to ser- 10.4 PAYMENTS ON ACCOUNT OF ADDITIONAL vices performed within each phase of service. SERVICES AND REIMBURSABLE EXPENSES 10.3.3 If and to the extent that the time initially established in Subparagraph 11.5.1 of this Agreement is exceeded or ex- 10.4.1 Payments on account of the Architect's Additional Ser- tended through no fault of the Architect,compensation for any vices and for Reimbursable Expenses shall be made monthly services rendered during the additional period of time shall be upon presentation of the Architect's statement of services computed in the manner set forth in Subparagraph 11.3.2. rendered or expenses incurred. 10.3.4 When compensation is based on a percentage of Con- 10.5 PAYMENTS WITHHELD struction Cost and any portions of the Project are deleted or otherwise not constructed,compensation for those portions of 10.5.1 No deductions shall be made from the Architect's com- the Project shall be payable to the extent services are per- pensation on account of sums withheld from payments to formed on those portions,in accordance with the schedule set contractors. ARTICLE 11 BASIS OF COMPENSATION The Owner shall compensate the Architect as follows: 11.1 AN INITIAL PAYMENT OF None Required Dollars($ shall be made upon execution of this Agreement and credited to the Owner's account at final payment. 11.2 BASIC COMPENSATION 11.2.1 FOR BASIC SERVICES, as described in Article 2,and any other services included in Article 12 as part of Basic Services, Basic Compensation shall be computed as follows: (Insert basis of compensation,including stipulated sums,multiples or percentages,and identify phases to which particular methods of compensation apply,if necessary.) Basic Compensation will be invoiced at the Direct Personnel Expenses for employees times a multiplier of three (3) with a maximum not to exceed Four Thousand Dollars ($4 , 000 . 00) for services through bidding. 11.2.2 Where compensation is based on a stipulated sum or percentage of Construction Cost,progress payments for Basic Services in each phase shall total the following percentages of the total Basic Compensation payable: (Insert additional phases as appropriate.) NAP, Design Phase: percent( %) Construction Documents Phase: percent( %) Construction Phase: percent( %) Total Basic Compensation: one hundred percent(100%) AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA° •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON, D.C. 20006 B151-1987 6 11.3 COMPENSATION FOR ADDITIONAL SERVICES 11.3.1 FOR PROJECT REPRESENTATION BEYOND BASIC SERVICES, as described in Paragraph 3.2, compensation shall be computed as follows: Three (3) times Direct Personnel Expense. 11.3.2 FOR ADDITIONAL SERVICES OF THE ARCHITECT provided under Article 3 or identified in Article 12,compensation shall be computed as follows: (Insert basis of compensation, including rates and/or multiples of Direct Personnel Expense for Principals and employees, and identify Principals and classify employees, if required. Identify specific services to which particular methods of compensation apply, if necessary.) Three (3) times Direct Personnel Expense. 11.3.3 FOR ADDITIONAL SERVICES OF CONSULTANTS,including additional structural,mechanical and electrical engineering ser- vices and those provided under Article 3 or identified in Article 12 as part of Additional Services,a multiple of fifteen percent ( 1 . 15 ) times the amounts billed to the Architect for such services. (Identify specific types of consultants in Article 12, if required.) 11.4 REIMBURSABLE EXPENSES 11.4.1 FOR REIMBURSABLE EXPENSES,as described in Paragraph 10.2,and any other items included in Article 12 as Reimbursable Expenses, a multiple of fifteen percent ( 1 . 15 )times the expenses incurred by the Architect, the Architect's employees and consultants in the interest of the Project. 11.5 ADDITIONAL PROVISIONS 11.5.1 IF THE BASIC SERVICES covered by this Agreement have not been completed within Twelve ( 12 )months of the date hereof,through no fault of the Architect,extension of the Architect's services beyond that time shall be compensated as provided in Subparagraphs 10.3.3 and 11.3.2. 11.5.2 Payments are due and payable thirty (3 0) days from the date of the Architect's invoice.Amounts unpaid thirty (3 0) days after invoice date shall bear interest from the date payment is due at the rate entered below, or in the absence thereof, at the legal rate prevailing from time to time at the principal place of business of the Architect. (Insert any rate of interest agreed upon.) (Usury laws and requirements under the Federal Truth in Lending Act,similar state and local consumer credit laws and other regulations at the Owner's and Archi- tect's principal places of business, the location of the Project and elsewhere may affect the validity of this provision. Specific legal advice should be obtained with respect to deletions or modifications, and also regarding requirements such as written disclosures or waivers.) 11.5.3 The rates and multiples set forth for Additional Services shall be annually adjusted in accordance with normal salary review practices of the Architect. AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AIA® •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C.20006 B151-1987 7 ARTICLE 12 OTHER CONDITIONS OR SERVICES (Insert descriptions of other services, identify Additional Services included within Basic Compensation and modifications to the payment and compensation terms included in this Agreement.) 12 . 1 Bidding Phase City of Oshkosh will provide all services during bidding. The City will provide all construction documents to bidders , printed from originals furnished by Reinke, Hansche, Last, Inc. City of Oshkosh will distribute all plans and receive bids. ' APPS : CITY 4170 NEY OSHMOSM L;iSCot:iIN a ;t pTrOiler This Agreement entered into as of the thy and year first written above. OWNER C ty Of O kosh AR APP, Rein e, Hansche, Last, Inc. ky,7;vzit)(1,Ar, /1.a.,!?) fra.,alf 15117/11/41,s (Ignature) 1 lam D. Frueh DonnaerWgrtature) City Manager City Clerk Ronald D. Hansche (Printed name and title) (Printed name and title) AIA DOCUMENT B151•ABBREVIATED OWNER-ARCHITECT AGREEMENT•THIRD EDITION•AlA® •©1987 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YORK AVENUE,N.W.,WASHINGTON,D.C.20006 B151-1987 8