HomeMy WebLinkAboutPW CNT 11-05 Carl Bowers & Sons Construction CONSTRUCTION CONTRACT
THIS AGREEMENT, made on the 27th day of April, 2011, by and between the CITY
OF OSHKOSH, party of the first part, hereinafter referred to as CITY, and CARL BOWERS
& SONS CONSTRUCTION, N1844 Maloney Rd, Kaukauna, WI 54130, party of the second
part, hereinafter referred to as the CONTRACTOR,
WITNESSETH:
That the City and the Contractor, for the consideration hereinafter named, agree as
follows:
ARTICLE I. SCOPE OF WORK
The Contractor hereby agrees to furnish all of the materials and all of the equipment
and labor necessary, and to perform all of the work shown on the plans and described in
the specifications for the project entitled or described as follows:
Public Works Contract No. 11 -05
for Concrete Paving & Utilities (South) and appurtenant work, for the Public Works
Department, pursuant to Resolution 11 -170 adopted by the Common Council of the City of
Oshkosh on the 26th day of April, 2011,
all in accordance and in strict compliance with the Contractor's proposal and the other
contract documents referred to in ARTICLE V of this contract.
ARTICLE II. TIME OF COMPLETION
The work to be performed under this contract shall be commenced and the work
completed within the time limits specified in the General Conditions and /or Contractor's
proposal.
ARTICLE III. PAYMENT
(a) The Contract Sum.
The City shall pay to the Contractor for the performance of the contract the sum of
$5,985,920.25, adjusted by any changes as provided in the General Conditions, or any
changes hereafter mutually agreed upon in writing by the parties hereto, provided,
however, in the event the proposal and contract documents are on a "Unit Price" basis, the
above mentioned figure is an estimated figure, and the City shall, in such cases, pay to the
Contractor for the performance of the contract the amounts determined for the total
number of each of the units of work as set forth in the Contractor's proposal; the number of
units therein contained is approximate only, and the final payment shall be made for the
actual number of units that are incorporated in or made necessary by the work covered by
the contract.
1
(b) Progress Payments.
In the event the time necessary to complete this Contract is such that progress payments
are required, they shall be made according to the provisions set forth in the General
Conditions.
ARTICLE IV. CONTRACTOR TO HOLD CITY HARMLESS
The Contractor covenants and agrees to protect and hold the City of Oshkosh
harmless against all actions, claims and demands of any kind or character whatsoever
which may in any way be caused by or result from the intentional or negligent acts of the
Contractor, his agents or assigns, his employees or his subcontractors related however
remotely to the performance of this Contract or be caused or result from any violation of
any law or administrative regulation, and shall indemnify or refund to the City all sums
including court costs, attorney fees and punitive damages which the City may be obliged or
adjudged to pay on any such claims or demands within thirty (30) days of the date of the
City's written demand for indemnification or refund.
ARTICLE V. INSURANCE
The Insurance required by the City of Oshkosh as specified in the City's
specifications, including addenda, or plans, or instructions, or advertisements, shall be
primary coverage and that any insurance or self insurance maintained by the City of
Oshkosh, its officers, council members, agents, employees or authorized volunteers will
not contribute to a loss. All insurance shall be based upon the occurrence of an event, and
not based on claims made. All insurance shall be in full force prior to commencing work
and remain in force until the entire job is completed and the length of time that is specified,
if any, in this contract, the specifications, whichever is longer.
ARTICLE VI. COMPONENT PARTS OF THE CONTRACT
This contract consists of the following component parts, all of which are as fully a
part of this contract as if herein set out verbatim, or if not attached, as if hereto attached:
1. This Instrument
2. The City's Approved Plans
3. Specifications, including any addenda
4. City of Oshkosh Standard Specifications
5. Instructions to Bidders
6. Advertisement for Bids
7. Contractor's Proposal
The contract documents are complementary; what is required by one is as binding
as if required by all. Before undertaking each part of the work, the Contractor shall
carefully study and compare the Contract Documents and check and verify all pertinent
figures and measurements required therein. Contractor shall promptly report in writing to
the Engineer any conflict, error, ambiguity or discrepancy which Contractor may discover
2
and shall obtain written clarification from the Engineer before proceeding with any work
affected thereby.
In the event that any provision in any of the above component parts of this contract
conflicts with any provision in any other of the component parts, the provision in the
component part first enumerated above shall govern over any other component part which
follows it numerically except as may be otherwise specifically stated.
IT IS HEREBY DECLARED, UNDERSTOOD AND AGREED that the word
"Contractor" wherever used in this contract means the party of the second part and
its /his /their legal representatives, successors and assigns.
IN WITNESS WHEREOF, the City of Oshkosh, Wisconsin, has caused this contract
to be sealed with its corporate seal and to be subscribed to by its City Manager and City
Clerk and countersigned by the Comptroller of said City, and the party of the second part
hereunto set its, his or their hand and seal the day and year first above written.
In the Presence of: CONTRACTOR
CARL BOWE & SONS CONSTRUCTION
By: C--- Y?) , )- 1 )-
\i t IQ, 1° i I N t,5 At
(Seal of Contractor (Specify Title)
if a Corporation.)
By:
. (Specify Title)
CITY OF OSHKOSH
By: /a1-
%� ±n ./', _ ' � � M rk A. Rohloff, City Manager
,F---.. ( itness)
7 ,
, 11 '
� r . �_,_ �►. ) And: , `, . t
IF . ( i ness) Pamela R. Ubrig, City Clem
_ 3
APPROVED: I hereby certify that the necessary
! , provisions have been made to pay
the liability which will accrue
1 , ` under this contract.
CI Attorn
C
a-- 1 74
ity Comptrollt
3
* Bond # 1215233
* *
* PERFORMANCE BOND
* * The American Institute of Architects,
AIA Document No. A312 (December, 1984 Edition)
* * * Any singular reference to Contractor, Surety, Owner or other
party shall be considered plural where applicable.
CONTRACTOR (Name and Address): OWNER (Name and Address):
Carl Bowers & Sons Construction Co Inc City of Oshkosh
N1844 Maloney Road 215 Church Avenue
Kaukauna, WI 54130 Oshkosh, WI 54903
CONSTRUCTION CONTRACT SURETY (Name and Principal Place of Business):
- Please Select From Below -
Date: April 26, 2011 Old Republic Insurance Company
133 Oakland Avenue
Amount: $5,985,920.25 Greensburg, PA 15601 -0789
Description (Name and Location):
Public Works Contract No. 11 -05 Concrete Paving & Utilities (South)
BOND
Date (Not earlier than Construction Contract Date): May 2, 2011
Amount: $5,985,920.25
Modifications to this Bond: EX None ❑ See Page 2
¢ � 4774;'7 ,
CONTRACTOR AS PRINCIPAL SURETY `
9
�
;;'V
Company: (Corporate Seal) Company: (Corporate -"'" .
Carl Bowers & Sons Const Co Inc ,)l� eA tchrt� t} w -
- Pleas l p l insurance Company
Signature: Signature: Michael L.iedt
Name and Title: Name and Title:
Attorney in Fact
(Any additional signatures appear on page 2.)
(FOR INFORMATION Only Name, Address and Telephone) OWNER'S REPRESENTATIVE (Architect, Engineer or other
AGENT or BROKER: - Please Select From Below - party): - Please Select From Below -
Agent
1 The Contractor and the Surety, jointly and severally, bind them- 3.3 The Owner has agreed to pay the Balance of the Contract Price
selves, their heirs, executors, administrators, successors and assigns to the Surety in accordance with the terms of the Construction
to the Owner for the performance of the Construction Contract, which Contract or to a contractor selected to perform the Construction
is incorporated herein by reference. Contract in accordance with the terms of the contract with the
2 If the Contractor performs the Construction Contract, the Surety and Owner.
the Contractor shall have no obligation under this Bond, except to par- 4 When the Owner has satisfied the conditions of Paragraph 3, the
ticipate in conferences as provided in Subparagraph 3.1. Surety shall promptly and at the Surety's expense take one of the
3 If there is no Owner Default/ the Surety's obligation under this Bond following actions:
shall arise after:
3.1 The Owner has notified the Contractor and the Surety at its 4.1 Arrange for the Contractor with consent of the Owner, to
address described in Paragraph 10 below that the Owner is con- perform and complete the Construction Contract; or
sidering declaring a Contractor Default and has requested and 4 Undertake to perform and complete the Construction Contract
attempted to arrange a conference with the Contractor and the itself, through its agents or through independent contractors; or
Surety to be held not later than fifteen days after receipt of such
notice to discuss methods of performing the Construction Contract. 4.3 Obtain bids or negotiated proposals from qualified contractors
If the Owner, the Contractor and the Surety agree, the Contractor acceptable to the Owner for a contract for performance and com-
shall be allowed a reasonable time to perform the Construction Con- pletion of the Construction Contract, arrange for a contract to be
tract. but such an agreement shall not waive the Owner's right, if prepared for execution by the Owner and the contractor selected
any, subsequently to declare a Contractor Default; and with the Owner's concurrence, to be secured with performance
3.2 The Owner has declared a Contractor Default and formally and payment bonds executed by a qualified surety equivalent to
terminated the Contractor's right to complete the contract. Such the bonds issued on the Construction Contract, and pay to the
Contractor Default shall not be declared earlier than twenty days Owner the amount of damages as described in Paragraph 6 in
after the Contractor and Surety have received notice as provided excess of the Balance of the Contract Price incurred by the Owner
in Subparagraph 3.1; and resulting from the Contractor's default; or
ORSC 22119 (10 -93) Page 1 of 2
- 4.4 Waive its right to perform and complete, arrange for completion, accrue on this Bond to any person or entity other than the Owner or
Or obtain a new contractor and with reasonable promptness under its heirs, executors, administrators or successors.
the circumstances: 8 The Surety hereby waives notice of any change, including changes
.1 After investigation, determine the amount for which it may of time, to the Construction Contract or to related subcontracts,
be liable to the Owner and, as soon as practicable after purchase orders and other obligations.
the amount is determined, tender payment therefor to the 9 Any proceeding, legal or equitable, under this Bond may be
Owner: or instituted in any court of competent jurisdiction in the location in which
.2 Deny liability in whole or in part and notify the Owner citing the work or part of the work is located and shall be instituted within
reasons therefor. two years after Contractor Default or within two years after the Con-
tractor ceased working or within two years after the Surety refuses
5 If the Surety does not proceed as provided in Paragraph 4 with
reasonable promptness, the Surety shall be deemed to be in default or fails to perform its obligations under this Bond, whichever occurs
first. If the provisions of this Paragraph are void or prohibited by law,
on this Bond fifteen days after receipt of an additional written notice the minimum period of limitation available to sureties as a defense
from the Owner to the Surety demanding that the Surety perform its in the jurisdiction of the suit shall be applicable.
Obligations under this Bond, and the Owner shall be entitled to enforce
any remedy available to the Owner. If the Surety proceeds as provided 10 Notice to the Surety, the Owner or the Contractor shall be mailed
in Subparagraph 4.4, and the Owner refuses the payment tendered or delivered to the address shown on the signature page.
or the Surety has denied liability, in whole or in part, without further 11 When this Bond has been furnished to comply with a statutory or
notice the Owner shall be entitled to enforce any remedy available other legal requirement in the location where the construction was
to the Owner. to be performed, any provision in this Bond conflicting with said statu-
6 After the Owner has terminated the Contractor's right to complete tory or legal requirement shall be deemed deleted herefrom and
the Construction Contract, and if the Surety elects to act under provisions conforming to such statutory or other legal requirement
Subparagraph 4.1, 4.2, or 4.3 above, then the responsibilities of the shall be deemed incorporated herein. The intent is that this Bond shall
Surety to the Owner shall not be greater than those of the Contractor be construed as a statutory bond and not as a common law bond.
under the Construction Contract, and the responsibilities of the Owner 12 DEFINITIONS
to the Surety shall not be greater than those of the Owner under the 12.1 Balance of the Contract Price The total amount payable by
Construction Contract. To the limit of the amount of this Bond, but the Owner to the Contractor under the Construction Contract after
subject to commitment by the Owner of the Balance of the Contract all proper adjustments have been made, including allowance to
Price to mitigation of costs and damages on the Construction the Contractor of any amounts received or to be received by the
Contract, the Surety is obligated without duplication for: Owner in settlement of insurance or other claims for damages to
6.1 The responsibilities of the Contractor for correction of defec- which the Contractor is entitled, reduced by all valid and proper
payments made to or on behalf of the Contractor under the
tive work and completion of the Construction Contract;
Construction Contract.
6.2 Additional legal design professional and delay costs resulting 12.2 Construction Contract: The agreement between the Owner
from the Contractor's Default, and resulting from the actions or and the Contractor identified on the signature page, including all
failure to act of the Surety under Paragraph 4; and Contract Documents and changes thereto.
6.3 Liquidated damages, or if no liquidated damages are speci- 12.3 Contractor Default: Failure of the Contractor, which has neither
fied in the Construction Contract. actual damages caused by been remedied nor waived, to perform or otherwise to comply with
delayed performance or non - performance of the Contractor. the terms of the Construction Contract.
7 The Surety shall not be liable to the Owner or others for obligations 12.4 Owner Default: Failure of the Owner, which has neither been
of the Contractor that are unrelated to the Construction Contract and remedied nor waived, to pay the Contractor as required by the
the Balance of the Contract Price shall not be reduced or set off on Construction Contract or to perform and complete or comply with
account of any such unrelated obligations. No right of action shall the other terms thereof.
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL (Corporate Seal) SURETY (Corporate Seal)
Company: Company: Please Select From Below -
Address: Address:
Name and Title: Name and Title:
Signature: Signature:
ORSC 22119 (10 -93) Page 2 of 2
* * * * Bond# 1215233
*
PAYMENT BOND
* 9t, * The American Institute of Architects, AIA Document No. A312
* * (December, 1984 Edition). Any singular reference to Contractor, Surety,
* * Owner or other party shall be considered plural where applicable.
CONTRACTOR (Name and Address): SURETY (Name and Pri ";ipal Place of Business):
Carl Bowers & Sons Construction Co Inc Old Reputlic Insurance Company
N1844 Maloney Road 133 Oakland Avenue
Kaukauna, WI 54130 Greensburg, PA 15601 -0789
OWNER (Name and Address):
City of Oshkosh
215 Church Avenue
Oshkosh, Wi 54903
CONSTRUCTION CONTRACT
Date: April 26, 2011
Amount: $5,985,920.25
Description (Name and Location): Public Works Contract No. 11 -05 Concrete Paving
& Utilities (South)
BOND 2011
Date (Not earlier than Construction Contract Date): May 2,
Amount: $5,985,920.25
Modifications to this Bond: 6 None ❑ See Page 2
' g
CONTRACTOR AS PRINCIPAL SURETY a o
Company: (Corporate Seal) Company: (Corpora,_ _al)
Carl Bowers & Sons Const Co Inc Old Republic Insurance Company
Signature: Signature:
Name and Title: Name and Title: Michael L. Tiedt
Attorney in Fact
(Any additional signatures appear on page 2.)
(FOR INFORMATION ONLY —Name, Address and Telephone) OWNER'S REPRESENTATIVE (Architect, Engineer or other
AGENT or BROKER: party):
Agent
1 The Contractor and the Surety, jointly and severally, bind them- 4.1 Claimants who are employed by or have a direct contract with the
selves, their heirs, executors, administrators, successors and assigns Contractor have given notice to the Surety (at the address described
to the Owner to pay for labor, materials and equipment furnished for in Paragraph 12) and sent a copy, or notice thereof, to the Owner,
use in the performance of the Construction Contract, which is incor- stating that a claim is being made under this Bond and, with sub -
porated herein by reference. stantial accuracy, the amount of the claim.
2 With respect to the Owner, this obligation shall be null and void if 4.2 Claimants who do not have a direct contract with the Contractor:
the Contractor: .1 Have furnished written notice to the Contractor and sent a copy.
2.1 Promptly makes payment, directly or indirectly, for all sums due or notice thereof, to the Owner, within 90 days after having last
Claimants, and performed labor or last furnished materials or equipment included
2.2 Defends, indemnifies and holds harmless the Owner from in the claim stating, with substantial accuracy, the amount of the
claims, demands, liens or suits by any person or entity whose claim and the name of the party to whom the materials were fur -
claim, demand, lien or suit is for the payment for labor, materials nished or supplied or for whom the labor was done or performed;
or equipment furnished for use in the performance of the Construc- and
tion Contract, provided the Owner has promptly notified the Con- .2 Have either received a rejection in whole or in part from the Con-
tractor and the Surety (at the address described in Paragraph 12) tractor, or not received within 30 days of furnishing the above notice
of any claims; demands, liens or suits and tendered defense of any communication from the Contractor by which the Contractor
such claims, demands, liens or suits to the Contractor and the has indicated the claim will be paid directly or indirectly; and
Surety, and provided there is no Owner Default. .3 Not having been paid within the above 30 days, have sent a
3 With respect to Claimants, this obligation shall be null and void if written notice to the Surety (at the address described in Paragraph
the Contractor promptly makes payment, directly or indirectly, for all 12) and sent a copy, or notice thereof, to the Owner, stating that
sums due. a claim is being made under this Bond and enclosing a copy of
4 The Surety shall have no obligation to Claimants under this Bond until: the previous written notice furnished to the Contractor,
ORIC 22114 (7 -93) Page 1 of 2
5 If a notice required by Paragraph 4 is given by the Owner to the Con- Paragraph are void or prohibited by law, the minimum period of limi-
tractor fir to the Surety, that is sufficient compliance. tation available to sureties as a defense in the jurisdiction of the suit
6 When the Claimant has satisfied the conditions of Paragraph 4, the shall be applicable.
Surety shall promptly and at the Surety's expense take the following 12 Notice to the Surety, the Owner or the Contractor shall be mailed
actions: or delivered to the address shown on the signature page. Actual
6,1 Send an answer to the Claimant, with a copy to the Owner, receipt of notice by Surety, the Owner or the Contractor, however
within 45 days after receipt of the claim, stating the amounts that accomplished, shall be sufficient compliance as of the date received
are undisputed and the basis for challenging any amounts that are at the address shown on the signature page.
disputed . 13 When this Bond has been furnished to comply with a statutory or
6.2 Pay or arrange for payment of any undisputed amounts. other legal requirement in the location where the construction was
7 The Surety's total obligation shall not exceed the amount of this to be performed. any provision in this Bond conflicting with said statu-
Bond, and the amount of this Bond shall be credited for any payments tory or legal requirement shall be deemed deleted herefrom and
made in good faith by the Surety. provisions conforming to such statutory or other legal requirement
8 Amounts owed by the Owner to the Contractor under the Construc- shall be deemed incorporated herein, The intent is that this Bond shall
tion Contract shall be used for the performance of the Construction be construed as a statutory bond and not as a common law bond.
Contract and to satisfy claims, if any, under any Construction Perfor- 14 Upon request by any person or entity appearing to be a potential
mance Bond. By the Contractor furnishing and the Owner accepting beneficiary of this Bond, the Contractor shall promptly furnish a copy
this Bond, they agree that all funds earned by the Contractor in the of this Bond or shall permit a copy to be made.
performance of the Construction Contract are dedicated to satisfy obli- 15 DEFINITIONS
gations of the Contractor and the Surety under this Bond, subject to 15.1 Claimant: An individual or entity having a direct contract with
the Owner's priority to use the funds for the completion of the work. the Contractor or with a subcontractor of the Contractor to furnish
9 The Surety shall not be liable to the Owner, Claimants or others for labor, materials or equipment for use in the performance of the
obligations of the Contractor that are unrelated to the Construction Contract. The intent of this Bond shall be to include without limi-
Contract. The Owner shall not be liable for payment of any costs or tation in the terms "labor, materials or equipment" that part of
expenses of any Claimant under this Bond, and shall have under this water, gas, power, light, heat, oil, gasoline, telephone service or
Bond no obligation to make payments to, give notices on behalf of, rental equipment used in the Construction Contract, architectural
or otherwise have obligations to Claimants under this Bond. and engineering services required for performance of the work of
10 The Surety hereby waives notice of any change, including changes the Contractor and the Contractor's subcontractors, and all other
of time, to the Construction Contract or to related subcontracts, pur- items for which a mechanic's lien may be asserted in the jurisdic-
chase orders and other obligations. tion where the labor, materials or equipment were furnished.
11 No suit or action shall be commenced by a Claimant under this 15.2 Construction Contract: The agreement between the Owner
Bond other than in a court of competent jurisdiction in the location and the Contractor identified on the signature page, including all
in which the work or part of the work is located or after the expiration Contract Documents and changes thereto.
of one year from the date (1) on which the Claimant gave the notice
required by Subparagraph 4.1 or Clause 4.2.3, or (2) on which the last 15.3 Owner Default: Failure of the Owner, which has neither been
labor or service was performed by anyone or the last materials or remedied nor waived, to pay the Contractor as required by the Con -
equipment were furnished by anyone under the Construction Con- struction Contract or to perform and complete or comply with the
tract, whichever of (1) or (2) first occurs. If the provisions of this other terms thereof.
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties, other than those appearing on the cover page.)
(Corporate Seal)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company:
Signature: Signature:
Name and Title: Name and Title:
Address: Address:
Page 2 of 2
05/10/2011 12:30 FAX 9203245057 SIA INSURANCE SERVICES 1j 001
ACCORD CERTIFICATE OF LIABILITY INSURANCE 5/10/2011 DD
L ess./ ......
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND.CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to
the terms and conditions of the policy, Certain policies may require an endorsement. A statement on this certificate does not Confer rights to the
certificate holder in lieu of such endorsement(s).
PRODUCER CONTACT SIA Insurance •
NAME:
SIA Insurance Services (a -2071 FAX
SIA 6920)3.24 -5057
999 West Main St. E-MAIL
SS:
P • O • Box 72
PRODUCER ID 3 :00002590
Waupun WI 53963 INSURERS) AFFORDING COVERAGE NAIL #
INSURED INSURER A ;Regent Insurance Company 24449
INSURER B !General Casualty, Co of WI 24414
Carl Bowers & Sons Construction Co. , Inc. INSURER C :
N1844 Maloney Road INSURER D:
INSURER E :
Kaukauna WI 54130 INSURER F :
COVERAGES CERTIFICATE NUMBER:CL114402134 REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INBR TYPE OF INSURANCE IAODLISUBRI LI POLICY EFF I POLICY asp LIMITb
LTR INSR II wen POLICY NUMBER (MMIOOIYYYTI IMMDI
IDYYYY) 1
GENERAL LABILITY EACH OCCURRENCE 5 1 , 000 , 000
..._ DAMAGE TO RENTED
X COMMERCIAL GENERAL LIABILITY PREMISES Ea occurrence) ence) 5 100 , 000
A J CLAIMS -MADE [ Xl OCCUR CCS0700591 4/1/2011 4/2/2012 ME0 EXP (Anyone person) $ 5,000
. ..... .... ... _ ....
PERSONAL B ADV INJURY $ 1,000,000
I GENERAL AGGREGATE $ 2,000,000
GE M:AGGR GATE LIMIT APPLIES PER PRODUCTS • COMP /OP AGO 5 2,000,000
r _. • I MF i POLICY I X 1 JFC LOC .5
1 AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT s 1,000,000
(Ea aeddent)
X ANY AUTO BODILY INJURY (Per person) 1
B ALL OWNED AUTOS ■ cBAO700590 4/2/2021 4/1/2012
__--•• BODILY INJURY (Per accident) $
SCHEDULED AUTOS PROPERTY DAMAGE $
HIRED AUTOS (Per accident)
NoN - OWNED AUTOS Uninsured motorist combined 5 500,000
Meeleal peymenls 5 10,000
E I X UMBRELLA LIAR OCCUR EACH OCCURRENCE S
X EXCESS u►
LB CLAIMS•MADE CCD07005E8 4/1/2011 4/1/2012 AGGREGATE 5
DEDUCTIBLE S
i RETENTION S 10 , 000 $
A WORKERS COMPENSATION I I T W ORY C ST LIM !
ATITS U- ((OTH-
AND EMPLOYERS' LIABILITY
PROPRIETOR/ PARTNERIEXECUTIVE N/A; E.L. EACH ACCIDENT $ 500,000
OFFICER /MEMBER EXCLUDED? ' I07005H9 4/1/2011 4/1/2012
(Mandatory ]n NH) I 1 EL. DISEASE • EA EMPLOYEE 5 500,000
If yes, describe under
DESCRIPTION OF OPERATIONS bellow E.L. DISEASE - POLICY LIMIT 5 500,000
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORP 1E1, Additional Remark"' Saheeul*. If mOre spa= Is raqulmd)
City of Oshkosh and its officers, council members, agents, employees and authorized volunteers are Addit -onal
Insureds, as required.by written contract,. to the General Liability, Umbrella and Auto Liability, with respect to work
performed by tyke xn'urod.
Project: Public Works Contract 11 -05
CERTIFICATE HOLDER CANCELLATION ,
SHOWW ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE
THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED 1N
ACCORDANCE WITH THE POLICY PROVISIONS.
CITY OF OSHKOSH
215 Church Ave AUTHORIZED REPRESENTATIVE
PO Sox 1130 •
Oshkosh, WI 54902 -1130
Daniel Zerateky /SARA
4CORD 25 (2009/09) di 1988 -2009 ACORD CORPORATION. All rights reserved.
N5025 pomp The ACORD name and logo are registered marks of ACORD