Loading...
HomeMy WebLinkAboutAECOM/Melvin Ave Pump Station I -- DEPARTMENT OF PUBLIC WORKS 215 Church Avenue _ P.O. Box 1130 Oshkosh, Wisconsin 54903 -1130 ` Ph. (920) 236 -5065 — APR 9 jI Fax (920) 236 -5068 Of Of ri ON THE WATER March 23, 2010 CITY C Lt. L' Steve Peterson AECOM Technical Services 4135 Technology Parkway Sheboygan, WI 53083 RE: Melvin Avenue Pump Station Construction Related Services Dear Mr. Peterson, Enclosed please find a signed copy of the Construction Related Services Contract for the Melvin Avenue Pump Station (City of Oshkosh Contract 10 -09) project. A copy of the City of Oshkosh Purchase Order (PO Number must appear on all invoices) has previously been faxed to your attention. If you need another copy sent to you, please let us know, and we will forward. If you have any questions, please do not hesitate to contact us. Sincerely, James Rabe, P.E., CPESC Civil Engineer II Encl.: Signed Contract cc: David Patek, P.E., Director of Public Works (w /o Encl.) Steve Gohde, P.E., Assistant Director of Public Works (w /o Encl.) Peter Gulbronson, P.E., CDT, Civil Engineer II (w /o Encl.) Laura Gray, Civil Engineer I (w /o Encl.) File Po U bo Ci fy dere< (w/ori91nc Lynn lorensch C;1 A-H v ( w /copq I:\Engineering110 -09 Melvin Avenue Storm Water Pump Page 1 of 1 Station\Project_ Information \Construction_Admin\AECOM CRS Contract LOT 03- 23- 10.doc CONSULTING AGREEMENT AND AUTHORIZATION TO PROCEED This Agreement between AECOM Technical Services, Inc., a California corporation, ( "ATS ") with offices at 4135 Technology Parkway, Sheboygan, WI 53083 and City of Oshkosh ( "CLIENT "), with offices at 215 Church Ave., Oshkosh, WI 54903. 1. AECOM Technical Services agrees to perform the services described in Attachment A, Scope of Services. 2. CLIENT authorizes AECOM Technical Services to perform these SERVICES for the following project and location: Melvin Avenue Storm Water Pump Station Construction Related Services 3. AECOM Technical Services is willing to perform the SERVICES in exchange for the following fee: CLIENT will pay on a time and material basis not to exceed the sum of $ 230,545.00. Upon reaching the limit, AECOM Technical Services will stop performing unless CLIENT authorizes further work in writing. 4. Billing: AECOM Technical Services will submit invoices to CLIENT monthly. CLIENT recognizes that timely payment is a material part of this Agreement. Each invoice is due and payable within thirty (30) calendar days of the date of the invoice. CLIENT will pay an additional charge of one and one -half percent per month not to exceed the maximum rate allowed by law for any payment received by AECOM Technical Services more than thirty (30) calendar days from the date of the invoice. CLIENT will pay when due that portion of invoice, if any, not in dispute. If CLIENT fails to pay any undisputed invoiced amounts within thirty (30) calendar days of the date of the invoice, AECOM Technical Services may suspend its performance or terminate this Agreement without incurring any liability to CLIENT and without waiving any other claim against CLIENT. 5. Special Provisions: X NONE _ ATTACHMENT CLIENT confirms reading this document in full (including the terms 1 through 23 on the following pages). This Agreement when executed by AECOM Technical Services is an offer to perform the services, open for acceptance within 30 days. This Agreement becomes effective on the date CLIENT signs below. CLIENT AECOM Techn'caI Services, Inc. 7 fl , By: --- 1D' ��� By: �:l a ..t .e'bi' Mark A. 'ohloff, City Ma . • - Name: Steven L. Peterson, P.E. By: UMW . i g . � itle: Vice President Pame R. Ubrig, City C,erk I D)te: March 3, 2010 By III/ . -!�.i } :,. =" \ Lynn ' Lorenson, City Attorney By: J 2 j c s7 7 , Peggy A. Steeno, Director of Finance Date: 3 - JO - 7..b/0 I hereby certify that the necessary provisions have been made to pay the liability which will accrue under this contract. 20100301 CRS Conssf w -City requirements.docx A=COM Page 1 of 12 AECOM General Conditions of Service — City of Oshkosh April, 2009 These General Conditions of Service, including any Supplemental Conditions of Service which are or may become applicable to the services described in AECOM's Proposal, are incorporated by reference into the foregoing Proposal and shall also be incorporated by reference into any Agreement under which services are to be performed by AECOM for the Client. No agreement or understanding, oral or written, which in any way modifies or waives these General Conditions of Service, shall be binding on AECOM (whether contained in the Client's purchase forms or otherwise) unless hereafter made in writing and executed by AECOM's authorized representative. Section 1: Scope of Work a. The scope of work and the time schedules defined in the Proposal are based on the information provided by the Client and shall be subject to the provisions of this agreement. If this information is incomplete or inaccurate, or if site conditions are encountered which materially vary from those indicated by the Client, or if the Client directs AECOM to change the original scope of work established by the Proposal, a written amendment to the Agreement equitably adjusting the costs, performance time, and/or terms and conditions thereunder, shall be executed by the Client and AECOM as soon as practicable. AECOM, at its discretion, may suspend performance of its services until such an Amendment has been executed and, if such an Amendment is not agreed to within a reasonable time, AECOM may terminate this Agreement. In the event this Agreement is terminated pursuant to this Section, the Client shall pay AECOM for all services performed prior to termination and termination expenses as set forth in Section 15c of these General Conditions of Service. Section 2: Billings and Payments a. Payments for services and reimbursable expenses will be made on the basis set forth in the attached proposal. AECOM shall periodically submit invoices for services performed and expenses incurred and not previously billed. Payment is due upon receipt. For all amounts unpaid after 30 days from the invoice date, as set forth on AECOM's invoice form, the Client agrees to pay a finance charge of one and one -half percent (1 -1/2 %) per month, eighteen percent (18 %) annually. The fees described in this agreement may be adjusted annually on the anniversary date of the effective date of this agreement. b. The Client shall provide AECOM with a clear written statement within fifteen (15) days after receipt of the invoice of any objections to the invoice or any portion or element thereof. Failure to provide such a written statement shall constitute a waiver of any such objections and acceptance of the invoice as submitted. c. The Client's obligation to pay for the services performed by AECOM under this Agreement shall not be reduced or in any way impaired by or because of the Client's inability to obtain financing, zoning, approval of governmental or regulatory agencies, or any other cause, reason, or contingency. No deduction shall be made from any invoice on account of penalty or liquidated damages nor will any other sums be withheld or set off from payments to AECOM. Client further agrees to pay AECOM any and all expenses incurred in recovering any delinquent amounts due, including, but not limited to reasonable attorney's fees, arbitration, or other dispute resolution costs, and all court costs. d. If any subpoena or court order is served upon AECOM and/or any of its staff, subconsultants or subcontractors requiring presentation of documents or the appearance of AECOM's staff, subconsultants or subcontractors at a trial, deposition, or for other discovery purposes arising out of AECOM's services performed under this Agreement, Client will pay AECOM's fees (if any) applicable to AECOM's compliance with the subpoena or court order. Fees will be based on actual units used at the standard rates in effect at time of service upon AECOM of the subpoena or court order. Billings shall include time and expenses incurred gathering, organizing, duplicating documents, preparing to give testimony, travel, and testifying in deposition or trial. Section 3: Right of Access a. If services to be provided under this Agreement require the agents, employees, or contractors of AECOM to enter onto the Project site, Client shall provide right -of -access to the site to AECOM, its employees, agents and contractors, to conduct the planned field observations or services. b. If the scope of services includes, or is amended to include, the performance of exploratory borings or test pit excavations, Client will furnish to AECOM all diagrams, and other information in its possession or reasonably attainable by Client indicating the location and boundaries of the site and subsurface structures (pipes, tanks, cables, sewers, other utilities, etc.) in such detail as to permit identifying, in the field, boring /test pit locations which will avoid interferences with any subsurface structures. AECOM will utilize "Diggers Hotline" to locate and mark public utilities. Client shall indemnify and hold AECOM harmless from liability on account of damages to subsurface structures or injury or loss arising from damage to subsurface structures, the locations of which are not indicated or are incorrectly indicated by Diggers Hotline or the information provided by the Client. c. AECOM reserves the right to deviate a reasonable distance from prescribed or selected exploratory boring or test pit locations. d. AECOM shall take reasonable precautions to minimize damage to the site due to its operations, but AECOM has not included in its fee, and is not responsible for, the cost of restoration for any damage resulting from its operations. At the Client's request and for additional fee, AECOM will, to the extent reasonably practicable, restore the site to conditions substantially similar to those existing prior to AECOM's operations. Section 4: Safety a. It is understood and agreed that, with respect to Project site health and safety, AECOM is responsible solely for the safe performance by its field personnel of their activities in performance of the required services. It is expressly agreed that AECOM's professional services hereunder do not involve any responsibility for the protection and safety of persons on and about the Project nor is AECOM to review the adequacy of job safety on the Project. It is further understood and agreed, and not in limitation of the foregoing, that AECOM shall not be in charge of, and shall have no control or responsibility over any aspect of the erection, construction or use of any scaffolds, 20100301 CRS Conssf w - City requirements.docx A_COM Page 2 of 12 hoists, cranes, stays, ladders, supports, or other similar mechanical contrivances or safety devices as defined and interpreted under any structural work act or other statute, regulation, or ordinance relating in any way to Project safety. b. Unless otherwise specifically provided in this Agreement, Client shall provide, at its expense, facilities and labor necessary to afford AECOM field personnel access to sampling, testing, or observation locations in conformance with federal, state, and local laws, ordinances, and regulations specifically, including, but not limited to regulations set forth in OSHA 29 CFR 1926. c. If, in AECOM's opinion, its field personnel are unable to access required locations and perform the required services in conformance with federal, state, and local laws, ordinances and regulations due to Project site conditions or operations of other parties present on the Project site, AECOM may, at its discretion, suspend its services until such conditions or operations are brought into conformance with applicable laws, ordinances and regulations. If, within a reasonable time, operations or conditions are not in conformance with applicable laws, ordinances, and regulations, AECOM may, at its discretion, terminate this Agreement. In the event that the Agreement is terminated pursuant to this Section, the Client shall pay AECOM for services and termination expenses as set forth in Section 15 of this Agreement. d. Current regulations promulgated by the Occupational Safety and Health Administration (OSHA) require that a "competent person" conduct inspections of excavations and review any supporting system if workers are to enter the excavations. See OSHA 29 CFR Part 1926 (Subpart P). Under the scope of work incorporated in this Agreement, AECOM does not provide and has not assumed any duties of inspection and /or monitoring of excavations required of the "competent person" under OSHA 29 CFR Part 1926 (Subpart P). AECOM has neither been assigned nor assumed the authority required of the "competent person" under OSHA 29 CFR Part 1926 (Subpart P). Section 5: Samples a. Unless otherwise specifically provided in this Agreement or amendments thereto, AECOM reserves the right to discard samples immediately after testing. Upon request, the samples will be shipped (shipping charges collected) or stored at the rate indicated in the fee schedule attached. Section 6: Reports and Ownership of Documents a. AECOM shall furnish up to six (6) copies of each report to Client. Additional copies shall be furnished at the rates specified in the fee schedule. With the exception of AECOM reports to Client, all documents, including original boring logs, field data, field notes, laboratory test data, calculations, and estimates are and remain the property of AECOM. Client agrees that all reports and other work product furnished to the Client not paid for in full will be returned upon demand and will not be used for any purpose, including, but not limited to design, construction, permits, or licensing. Section 7: Standard of Care a. AECOM represents that it will perform its services under this Agreement in conformance with the care and skill ordinarily exercised by reputable members of the professional engineering community practicing under similar conditions at the same time in the same or similar locality. b. NO OTHER WARRANTY OF ANY KIND, EXPRESSED OR IMPLIED, AT COMMON LAW OR CREATED BY STATUTE, IS EXTENDED, MADE, OR INTENDED BY THE RENDITION OF CONSULTING SERVICES OR BY FURNISHING ORAL OR WRITTEN REPORTS OF THE FINDINGS MADE. c. Any exploration, testing, surveys, and analysis associated with the work will be performed by AECOM for the Client's sole use to fulfill the purpose of this Agreement and AECOM is not responsible for interpretation by others of the information developed. The Client recognizes that subsurface conditions beneath the Project site may vary from those encountered in borings, surveys, or explorations and the information and recommendations developed by AECOM are based solely on the information available. d. AECOM is not responsible for supervising, directing, controlling, or otherwise being in charge of the construction activities at the Project site; or supervising, directing, controlling or otherwise being in charge of the actual work of the contractor, its subcontractors, or other materialmen or service providers not engaged by AECOM. Section 8: Hazardous Substances a. Upon entering into this Agreement, the Client shall notify AECOM of all such hazardous substances which it knows or which it reasonably suspects are or may be present at or contiguous to the Project site or which may otherwise affect the services to be provided. Thereafter, such notification to AECOM shall be required as soon as practicable after the Client discovers either the presence of hazardous substances which were not previously disclosed, increased concentrations of previously disclosed hazardous substances, or facts or information which cause the Client to reasonably suspect the presence of any such hazardous substances. Hazardous substances shall include, but not be limited to, any substance which poses or may pose a present or potential hazard to human health or the environment whether contained in a product, material, by- product, waste, or sample and whether it exists in a solid, liquid, semi- solid, or gaseous form. b. If all or any part of the scope of work is to be performed in the general vicinity of a facility or in an area where asbestos, dust, fumes, gas, noise, vibrations, or other particulate or nonparticulate matter is in the atmosphere where it raises a potential health hazard or nuisance to those working in the area of such conditions, Client shall immediately notify AECOM of such conditions, potential health hazard, or nuisance which it knows, should know, or reasonably suspects exists and, thereafter, AECOM is authorized by the Client to take all reasonable measures AECOM deems necessary to protect its employees against such possible health hazards or nuisance. The reasonable direct cost of such measures shall be borne by the Client. c. Following any disclosure as set forth in the preceding paragraphs, or if any hazardous substances or conditions are discovered or reasonably suspected by AECOM after its services are undertaken, AECOM may, at its discretion, suspend its services until reasonable measures have been taken at the Client's expense to protect AECOM's employees from such hazardous substances or conditions. Whether or not AECOM suspends its services in whole or in part, the Client and AECOM agree that the scope of services, terms, and conditions, schedule, and the estimated fee or budget shall be adjusted in accordance with the disclosed information or condition, or 20100301 CRS Conssf w - City requirements.docx A=COM Page 3 of 12 AECOM may, at its discretion, terminate the Agreement. In the event that this Agreement is terminated pursuant to this Section, the Client shall pay AECOM for all services rendered prior to termination and all termination expenses as set forth in Section 15 of these General Conditions of Service. d. In the event that services under this Agreement may involve or relate to hazardous substances, or constituents, including hazardous waste (as defined by federal, state, or local statutes, regulations or ordinances), whether or not involvement or relationship was contemplated at the time this Agreement was made or when services by AECOM began under this Agreement, the following conditions shall also be incorporated into the Agreement and be made applicable thereto: d.1. In the event that samples collected by or received by AECOM on behalf of the Client contain hazardous substances or constituents, including hazardous waste, AECOM will, after completion of testing and, at Client's expense, (1) return such samples to Client, or (2) upon written request and using a manifest signed by the Client as generator, release such samples to a carrier selected by the Client to be transported to a location selected by the Client for final disposal. The Client agrees to pay all costs associated with the storage, transport, and disposal of samples. The Client recognizes and agrees that AECOM is acting as a bailee and at no time assumes title to said samples or substances. d.2. All laboratory and field equipment contaminated in performing services under this Agreement which cannot be reasonably decontaminated shall become the property and responsibility of the Client. All such equipment shall be delivered to the Client or disposed of in a manner similar to that indicated for hazardous samples above. The Client agrees to pay the fair market value of any such equipment which cannot reasonably be decontaminated and all other costs associated with the storage, transport, and disposal of such equipment. Section 9: Construction Monitoring Services a. "Construction Monitoring Services" is defined as services, furnished by AECOM to the Client, which are performed for the purpose of evaluating and/or documenting general conformance of construction operations or completed work with Project specifications, plans, and /or specific reports of the Project. Such services may include taking of tests or collecting samples of natural or manmade materials at various locations on a project site, and making visual observations related to earthwork, foundations, and/or materials. If the services to be provided by AECOM under this agreement include or are amended to include Construction Monitoring Services, the provisions of this Section 9 shall be an integral part of this agreement and applicable thereto. b. The presence of AECOM field personnel will be for the purpose of providing the client with a professional service based on observations and testing of the work which is performed by a contractor, subcontractor, or other materialmen or service provider. Such services will only be those specifically requested by the Client and agreed to by AECOM. Discrepancies between construction operations or completed work and project requirements which are noted by AECOM field personnel will be referred to the Client, or the Client's representative, as designated prior to AECOM's involvement in the project. c. It is understood and agreed by the Client that the observation and testing of natural and /or man -made materials by AECOM in no way implies a guarantee or warranty of the work of the contractor, subcontractor, or other materialmen or service providers, and the services rendered by AECOM will in no way excuse such contractor, subcontractor, or other materialmen or service providers from liability in the event of subsequently discovered defects, omissions, errors or other deficiencies in their work. The presence or absence of AECOM on the Project site will not affect any obligation of any contractor, subcontractor, or other materialmen or service providers to perform in accordance with the specifications and plans of the Project. The Client further understands that AECOM is not a quality assurance representative for any contractor, subcontractor, or other materialman or service provider on the Project. d. The Client agrees to supply AECOM with specifications, plans, and other necessary material for the Project pertinent to providing its services. e. Due to the nature of its services, observing and field testing the work of contractors, subcontractors, or materialmen or service providers on the Project, AECOM cannot always be responsible for the schedule or length of time its field personnel remain on the Project site. The time AECOM's field personnel spend on the Project site is dependent upon the schedule of the contractor, subcontractor or materialman, or service provider whose work they are observing and/or testing. AECOM shall make reasonable effort to utilize its time on the Project site judiciously, but the Client understands and agrees that any delays, cancellations, rescheduling, overtime or other construction activities that may alter the anticipated number of hours and the anticipated costs of AECOM on the Project site and that are beyond the control of AECOM field personnel are legitimate and chargeable time and will be invoiced at the rates designated in the attached fee schedules. f. Part-time work is defined as Construction Monitoring Services provided by AECOM where its field personnel are on the Project less than five (5) working days per week or less than forty (40) hours per week, or both. It is agreed that the Client will furnish AECOM with a minimum of one working day's notice, or twenty -four (24) hours notice, whichever is greater, on any part-time work of AECOM if field personnel are requested. AECOM shall make reasonable effort to provide field personnel on all projects, but reserves the right to schedule its field personnel as it deems appropriate, including the scheduling of different field personnel from day to day on any given part-time project of AECOM. The Client agrees to inform AECOM of the anticipated services required by AECOM field personnel on any day, including but not restricted to the kind and number of tests to be required and the anticipated amount of time the field personnel will be required on the Project site. g. All field personnel charges will be made on a portal -to -portal basis. Mileage to and from the Project site will be billed at the rate designated in the attached fee schedules as will any office engineering time needed to review, evaluate or analyze the field data. All calls made by the Client or the Client's representative to cancel requested part-time AECOM field personnel must be received by AECOM in time for AECOM to notify field personnel before they leave for the Project site. AECOM will make reasonable effort to contact its field personnel as quickly as possible, but reserves the right to bill the Client for time incurred in the event AECOM received a cancellation call too late for it to intercept the field personnel enroute to the Project site. Section 10: Opinions of Cost a. AECOM's opinions of probable total Project costs and Project construction costs, if any, provided as part of the services under this Agreement are made on the basis of AECOM's knowledge, experience, and qualifications and represent AECOM's judgment as an 20100301 CRS Conssf w - City requirements.docx A=COM Page 4 of 12 experienced and qualified professional engineer, familiar with the construction industry; but AECOM cannot and does not guarantee that proposals, bids, or actual total Project costs or Project construction costs will not vary from opinions of probable cost provided by AECOM. Section 11: Shop Drawings a. In the event that the scope of services includes review and approval of Shop Drawings or other data which contractor(s) are required to submit, AECOM's review and approval will be only for conformance with the design concept of the Project and for compliance with the information given in the Project plans and specifications and shall not extend to means, methods, techniques, sequences, or procedures of construction, or to safety precautions or programs incident thereto. b. AECOM's review and approval of Shop Drawings or other data shall not relieve the contractor(s) from responsibility for any variation from the requirements of the plans and specifications unless the contractor(s) has, in writing, called AECOM's attention to each such variation at the time of submission and AECOM has given written approval of each such variation by a specific written notation incorporated into or accompanying the Shop Drawing or other data. Approval by AECOM will not relieve the contractor(s) from responsibility for errors or omissions in the Shop Drawings or other data. c. AECOM will accept Shop Drawings or other data submittals only from the contractor(s) required by the Project contract documents to furnish the Shop Drawings or data. AECOM will reasonably promptly review and approve, or take other appropriate action in regard to, Shop Drawings or data properly submitted to AECOM. Section 12: Allocation of Risk a. IN NO EVENT SHALL AECOM BE LIABLE, WHETHER IN CONTRACT, TORT, OR OTHERWISE, FOR CLIENTS LOSS OF PROFITS, DELAY DAMAGES, OR FOR ANY SPECIAL, INCIDENTAL, OR CONSEQUENTIAL LOSS OR DAMAGE OF ANY NATURE ARISING AT ANYTIME OR FROM ANY CAUSE WHATSOEVER. NOTWITHSTANDING ANY OTHER PROVISION OF THIS AGREEMENT, AECOM'S LIABILITY HEREUNDER SHALL BE LIMITED TO $50,000.00 OR THE FEE PAID TO AECOM, WHICHEVER IS GREATER. b. Subject to any limitations contained in Sec. 893.80 and any similar statute, of the Wisconsin Statutes, the City further agrees to hold AECOM harmless from any and all liability, including claims, demands, losses, costs, damages, and expenses of every kind and description (including death), or damages to person or property arising out of reuse of the documents without consent where such liability is founded upon or grows out of the acts or omission of any of the officers, employees or agents of the City of Oshkosh while acting within the scope of their employment. c. Under no circumstances shall AECOM be liable for extra work or other consequences due to changed conditions or for costs related to failure of the construction contractor or materialmen or service providers to install work in accordance with the plans and specifications. d. Notwithstanding any other provision of this Agreement, it is further agreed that to the fullest extent permitted by law the Client shall indemnify and hold harmless AECOM and its employees, agents, contractors and consultants from and against all claims, damages, losses and expenses, direct and indirect, or consequential damages, including but not limited to attorneys' fees and all Court, arbitration or other dispute resolution costs, arising out of, resulting from, or related to the presence and /or involvement of hazardous substances, including hazardous waste, at the Project site or contained in samples collected by or received by AECOM from the Project site. The indemnification set forth in this paragraph 12.e. extends to claims against AECOM which arise out of, are related to, or are based upon, the dispersal, discharge, escape, release, spillage or saturation of smoke, vapors, soot, fumes, acids, alkalis, toxic chemicals, liquids, gases or any other material, irritant, contaminant or pollution in or into the atmosphere, or on, onto, upon, in or into the surface or subsurface (a) soil, (b) water or watercourses, (c) objects, or (d) any tangible or intangible matter, whether such event or circumstances is sudden or not. Nothing in this Paragraph 12.e. is intended to indemnify, or shall be construed as indemnifying, AECOM with respect to claims, losses, expenses or damages to the extent caused by AECOM's own negligent acts or omissions. Section 13: Liability Insurance a. AECOM shall abide by the document entitled 'INSURANCE REQUIREMENTS FOR "PROFESSIONAL LIABILITY" PROVIDERS FOR CITY OF OSHKOSH' (a copy of which is attached). In the event the City requires specific inclusions of coverage in addition to that obtained by AECOM, or increased limits of liability in AECOM's liability policies, the cost of such inclusions or increased limits shall be borne by the City. The City agrees to provide liability protection for its officers, employees and agents while acting within the scope of their employment. Subject to any limitations contained in Sec. 893.80 and any similar statute, of the Wisconsin Statutes, the City further agrees to hold AECOM harmless from any and all liability, including claims, demands, losses, costs, damages, and expenses of every kind and description (including death), or damages to person or property arising out of or in connection with or occurring during the course of this agreement where such liability is founded upon or grows out of the acts or omission of any of the officers, employees or agents of the City of Oshkosh while acting within the scope of their employment. Section 14: Dispute Resolution a. All claims, disputes, controversies or matters in question arising out of, or relating to this Agreement or any breach thereof, including but not limited to disputes arising out of alleged design defects, breaches of contract, errors, omissions, or acts of professional negligence, (collectively "disputes ") shall be submitted to mediation before and as a condition precedent to any other remedy. Upon written request by either party to this Agreement for mediation of any dispute, Client and AECOM shall select by mutual agreement a neutral mediator. Such selection shall be made within ten (10) calendar days of the date of receipt by the other party of the written request for mediation. In the event of failure to reach such agreement or in any instance when the selected mediator is unable or unwilling to serve and a replacement mediator cannot be agreed upon by Client and AECOM within ten (10) calendar days, a mediator shall be chosen as specified in the Construction Industry Mediation Rules of the American Arbitration Association then in effect. b. Notwithstanding any other provisions of this Section 14, in no event shall a demand for mediation be made more than two (2) years from the date the party making demand knew or should have known of the dispute or six (6) years from the date of substantial completion of AECOM's participation in the Project, whichever date shall occur earlier. c. All mediation or arbitration shall take place in the City of Oshkosh, Wisconsin, unless Client and AECOM agree otherwise. The fees of 20100301 CRS Conssf w - City requirements.docx A COM Page 5 of 12 the mediator or arbitrator(s) and the costs of transcription and other costs incurred by the mediator or arbitrator(s) shall be apportioned equally between the parties. Section 15: Termination a. This Agreement may be terminated by either party upon at least seven (7) days written notice in the event of substantial failure by the other party to perform in accordance with the terms hereof through no fault of the terminating party. Such termination shall not be effective if that substantial failure has been remedied before expiration of the period specified in the written notice. The only exceptions to this seven -day written notice condition are AECOM's rights to terminate this Agreement as set forth in Sections 1, 4 and 8 of the Agreement. b. In addition, AECOM may terminate this Agreement if the Client suspends AECOM's services for more than sixty (60) consecutive days through no fault of AECOM. c. If this Agreement is terminated, AECOM shall be paid for services performed prior to the termination date set forth in the notice plus termination expenses. Termination expenses shall include personnel and equipment rescheduling and re- assignment adjustments and all other related costs incurred directly attributable to termination. Section 16: Employment a. Client agrees that, prior to the completion of AECOM's services on the Project, Client and its officers, agents or employees shall neither (1) offer employment to AECOM's employees, (2) advise AECOM's employees of employment opportunities with Client, Client's parent or affiliate organization(s), if any, nor (3) inquire into employment satisfaction of AECOM's employees. Section 17: Independent Contractor a. The relationship between the Client and AECOM created under this Agreement is that of principal and independent contractor. Neither the terms of this Agreement nor the performance thereof is intended to directly or indirectly benefit any person or entity not a party hereto and no such person or entity is intended to be or shall be construed as being, a third -party beneficiary of this Agreement unless specified by name herein or in an Amendment hereto, executed by AECOM's authorized representative. Section 18: Severability a. In the event that any provision herein shall be deemed invalid or unenforceable, the other provisions hereof shall remain in full force and effect, and binding upon the parties hereto. Section 19: Section Headings a. The heading or title of a section is provided for convenience and information and shall not serve to alter or affect the provisions included herein. Section 20: Survival a. All obligations arising prior to the termination of this Agreement and all provisions of this Agreement allocating responsibility or liability between the Client and AECOM shall survive the completion of services and the termination of this Agreement. Section 21: Assigns a. Neither the Client nor AECOM may delegate, assign, sublet or transfer its duties, responsibilities or interests in this Agreement without the written consent of the other party. Section 22: Choice Of Law a. This Agreement shall be governed by the law of the State of Wisconsin. Section 23: Written Notice a. Written notice shall be deemed to have been duly served if delivered in person to the individual or a member of the firm or entity or to an officer of the corporation for which it was intended, or if delivered at or sent by registered or certified mail to the last business address known to the party giving notice. 20100301 CRS Conssf w - City requirements.docx A=COM Page 6 of 12 ATTACHMENT A SCOPE OF SERVICES City of Oshkosh, Wisconsin Melvin Avenue Storm Water Pump Station Construction Related Services PART I AECOM RESPONSIBILITIES A. PROJECT DESCRIPTION The project consists of construction related services described herein, provided by AECOM Technical Services, Inc. (AECOM) for the City of Oshkosh, Wisconsin (CLIENT). The project is for construction of the Melvin Avenue Storm Water Pump Station to be shown and described in bidding documents prepared by AECOM under City Contract 10 -09. The scope of SERVICES is based on the following: 1. Seven month duration from notice to proceed to contractor to final completion. B. SCOPE OF SERVICES SERVICES to be provided for the project are as follows: 1. Contract Administration SERVICES a. Provide a construction administrator, who will visit the construction site at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the work outlined in the construction contract. AECOM shall keep the CLIENT informed of the progress of the work, shall endeavor to guard the CLIENT against defects and deficiencies in the work of the contractor, and reject work found not in conformance with the contract documents. b. Conduct a preconstruction conference with representatives of the contractor, AECOM, CLIENT, and affected utilities. 1) Develop pre- construction conference agenda. 2) Identify and notify participants 3) Conduct meeting. 4) Prepare and distribute minutes. c. Provide construction contract administration, clarifications, and interpretations of the contract documents, and coordination of AECOM's SERVICES. d. Prepare contract change orders for CLIENT execution or field orders for adjustments not requiring extra time or money. e. Process monthly applications for payment submitted by the contractor and forward to the CLIENT for execution with recommendations for approval and payment. f. Supply the CLIENT with a copy of communications issued by AECOM to the contractor. g. Perform a field observation of the completed contract before recommending final payment as set forth in the application from the contractor. 20100301 CRS Conssf w -City requirements.docx r COM �� Page 7of12 h. Provide continuing coordination with the Department of Natural Resources (DNR) to assist the CLIENT in complying with regulatory requirements. 2. Construction Observation SERVICES a. Provide observation of the work by the contractor during the construction period by a resident project representative. The Resident Project Representative (RPR) will, under the general guidance of the construction administrator, observe the construction work for general conformance to the contract documents and will advise the project engineer of any noted defects. b. The SERVICES to be provided by the construction administrator and/or resident project representative are as follows: 1) Review contractor's progress schedule, schedule of submittals/ submissions, and schedule of values prepared by contractor, and consult with CLIENT concerning their appropriateness. 2) Construction administrator will lead weekly progress meetings. The resident project representative will attend weekly foreman's meetings, and other job conferences as required and in consultation with CLIENT. 3) Serve as the liaison with CLIENT and contractor, and assist them in understanding the intent of the contract documents. 4) Monitor receipt of submittals and samples from contractor, and notify CLIENT of their availability for examination. 5) Conduct site observations of the work in progress, determine if the work is generally proceeding in accordance with the contract documents, and that completed work appears to conform to the contract documents. 6) Verify that material and other tests, as well as equipment and system start ups are conducted and operating and maintenance instructions as required by contract documents are provided. 7) Transmit to contractor, AECOM's clarifications and interpretations of the contract documents. 8) Maintain correspondence files, reports of job conferences, shop drawings and sample submissions, reproductions or original contract documents including all addenda, change orders, field orders, additional drawings issued subsequent to the execution of the contract, AECOM's clarifications and interpretations of the contract documents, progress reports, and other project - related documents. 9) Keep reports for the construction contract recording hours on the job site; weather conditions when on the job site; data relative to questions of extras or deductions; list of visiting officials, representatives of manufacturers, fabricators, suppliers, and distributors; daily activities; decisions; observations in general; and specific observations in more detail as in the case of observing test procedures. 10) Record names, addresses, and telephone numbers of the general contractor, subcontractors, and major suppliers of materials and equipment. 20100301 CRS Conssf w -City requirements.docx _ =COM Page 8 of 12 11) Direct visiting personnel representing the public or agencies having jurisdiction over the project to the CLIENT's representative who will be responsible for such visits. 12) Prepare necessary field modifications and change orders in accordance with instructions of the CLIENT and ENGINEER. Field modifications are conditions that require no adjustment on the contract cost or time of completion. Change orders require modification of cost and/or time of completion. 13) Furnish OWNER and ENGINEER with monthly reports of progress of the work and the Contractor's compliance with the approved progress schedule. Attend monthly progress meetings at the jobsite with OWNER to discuss progress of work. Keep OWNER and ENGINEER informed of any expected delays in progress schedule. 14) Report to OWNER and ENGINEER whenever RPR believes that any work is unsatisfactory, faulty, or defective or does not conform to the Contract Documents, and advise OWNER and ENGINEER when RPR believes work should be corrected or rejected. 15) Where applicable, witness field testing of the facilities furnished under the contract to assist in determining conformance with the contract documents. 16) Furnish CLIENT with reports of the progress of the work and contractor's compliance with the approved progress schedule. Keep CLIENT informed of any expected delays. 17) Consult with CLIENT in advance of scheduled major tests, inspections, or initiation of important phases of the work. 18) Notwithstanding that it is the contractor's sole responsibility for job site safety, AECOM will report immediately to CLIENT the occurrence of any accident. 19) Review applications for payment with the contractor for compliance with the established procedure for their submission, and forward with recommendations to CLIENT noting particularly relation to the schedule of values, work completed, and materials and equipment delivered at the site but not incorporated in the work. 20) Before AECOM issues the "Certificate of Substantial Completion," submit to the contractor a list of observed items requiring completion or correction. 21) Conduct a final inspection in the company of CLIENT and contractor, and prepare a final list of items to be completed or corrected. 3. Engineering Support - Shop Drawing Reviews and Field Questions a. Shop Drawing /Submittal Review 1) Administration and Management 20100301 CRS Conssf w -City requirements.docx _ AMOM Page 9 of 12 a) Establish project files with a separate file for each specification section which requires a submittal. b) Establish a shop drawing submittal log subdivided by specification section. c) Prepare a shop drawing routing (control) list identifying design personnel that will be providing the technical review. Provide CLIENT with a copy of the submittal. d) Prepare a shop drawing transmittal form for the contractor's use. e) Prepare a listing of anticipated submittals required for the project. f) Log and route each shop drawing as submitted. Track each submittal by tabulating receipt date, return date, and review status. Provide CLIENT a summary of submittal review status via e-mail once per month through project duration. g) Review designer's technical review comments on each submittal. h) Prepare reviewed submittals for distribution to contractor, CLIENT, and RPR. 2) Perform Designer Technical Reviews. The design disciplines (process, electrical, instrumentation, HVAC, plumbing, structural, architecture, and civil) will review shop drawings and provide the following SERVICES: a) Review shop drawings for conformance with the intent of the contract documents. Evaluate shop drawing substitution requests for materials and equipment the contractor considers to be an "or equal" product. CLIENT's shop drawing review will be concurrent with the designer's review. b) State the submittal's exceptions and deficiencies determined during the review process. c) Determine the status of the submittal. ( "Approved ", "Approved as Noted ", "Not Approved ", "Revise and Resubmit "). b. Designer Technical Input 1) Answer design interpretation and clarification requests from the CLIENT, contractor, and RPR. All responses to be documented by either e-mail or memo to the RPR. 2) Provide technical input into contract change orders and field modifications. c. Designer Site Visits 1) Conduct site visits by appropriate design discipline personnel at appropriate stages of construction to review the quality of the work and to determine, in general, whether the work conforms to the contract documents. 20100301 CRS Conssf w -City requirements.docx _ A=COM Page 10 of 12 a) For the purposes of this Agreement, 10 mandays of site visits are included. 2) Attend meetings with contractor to resolve disputes on the acceptability of proposed equipment and /or modifications required thereto. 4. Testing Laboratory SERVICES a. Perform testing for work specified in the following sections: 1) Section 02315 — Structure Excavation and Backfilling. 2) Section 02316 — Trenching, Backfilling, and Compacting. 3) Section 02740 — Asphalt Concrete Paving. 4) Section 03300 — Cast -in -Place Concrete. 5) Section 04810 — Unit Masonry. 5. Record Drawings a. Receive "as- built" markup drawings prepared by contractor. The as -built markup drawings submitted to AECOM shall be in accordance with the contract documents. b. Prepare record drawings based on contractor's as -built markup drawings. c. Provide two sets of 11 by 17 draft prints of record drawings to CLIENT for review. Incorporate CLIENT comments into record drawings. d. Provide CLIENT with one set of 11 by 17 paper prints, one set of 22 by 34 full size final record drawings, and one combined PDF of the drawings. C. ASSUMPTIONS In preparing this Agreement, the following assumptions were made: 1. The RPR will be on -site for 45 hours per week from April 1, 2010, through August 31, 2010. 2. The RPR will be part-time on -site as required after the substantial completion until the final completion of October 31, 2010 and we have estimated 20 hours per week for this effort. 3. The RPR is budgeted for 1,113 hours from April 1, 2010 through October, 31, 2010. If these times periods and efforts per week are exceeded to meet the Contractor schedule and /or changes to the schedule, additional contract SERVICES can be provided by amendment to the contract. 4. Testing Laboratory SERVICES — AECOM has included an estimate of $28,600 for these services based on our experience for similar contracts. However, the Contractor may differ in the testing laboratory services and any changes will be addressed via an amendment. 20100301 CRS Conssf w -City requirements.docx _ A=OM Page 11 of 12 PART 1I CLIENT'S RESPONSIBILITIES CLIENT shall do the following in a timely manner so as not to delay the SERVICES of the AECOM: A. CLIENT's PROJECT MANAGER (PM) Provide CLIENT's PM for the project, who shall have the authority to transmit instructions, receive information, interpret and define CLIENT's policies, and make decisions with respect to AECOM's SERVICES under this Agreement. The SERVICES to be provided by the CLIENT's PM are as follows: 1. Review the progress schedule, schedule of shop drawing submissions, and schedule of values prepared by contractor and consult with AECOM concerning their acceptability. 2. Attend and participate in the preconstruction conference. 3. Attend and participate in progress meetings to discuss construction progress and areas of concern. B. OTHER CLIENT RESPONSIBILITIES 1. Provide such legal, accounting and insurance services as may be required for the project. 2. Before commencement of the work, require that the Contractor submit written evidence that he has obtained the specified insurance coverage for the entire project which is the subject of the construction contract. Such insurance shall include the CLIENT and AECOM as additional named insureds. Provide copy of written evidence to AECOM. 3. Provide survey services to establish a base line and reference elevation to be used by the contractor during the construction of the facilities. 20100301 CRS Conssf w -City requirements.docx _ A=COM Page 12 of 12