HomeMy WebLinkAboutLaLonde Contractors Inc 06
)
7~
~
CONSTRUCTION CONTRACT
THIS AGREEMENT, made on the 10th day of May, 2006, by and between the CITY
OF OSHKOSH, party of the first part, hereinafter referred to as CITY, and LaLond,~
Contractors, Inc., 2929 S. Chase Ave., Milwaukee, WI 53207-0420, party of the second
part, hereinafter referred to as the CONTRACTOR,
WITNESSETH:
That the City and the Contractor, for the consideration hereinafter named, agree as
follows:
ARTICLE I. SCOPE OF WORK
The Contractor hereby agrees to furnish all of the materials and all of the equipment
and labor necessary, and to perform all of the work shown on the plans and described in
the specifications for the project entitled or described as follows:
for concrete sidewalk, Public Works Contract No. 06-05, pursuant to Resolution 06-164
adopted by the Common Council of the City of Oshkosh on the 9th day of May, 2006,
all in accordance and in strict compliance with the Contractor's proposal and the other
contract documents referred to in ARTICLE V of this contract.
ARTICLE II. TIME OF COMPLETION
The work to be performed under this contract shall be commenced and the work
completed within the time limits specified in the General Conditions and/or Contractor's
proposal.
ARTICLE III. PAYMENT
(a) The Contract Sum.
The City shall pay to the Contractor for the performance of the contract the sum of
$4,081,553.43, adjusted by any changes as provided in the General Conditions, or any
changes hereafter mutually agreed upon in writing by the parties hereto, provided,
however, in the event the proposal and contract documents are on a "Unit Price" basis, the
above mentioned figure is an estimated figure, and the City shall, in such cases, pay to
the Contractor for the performance of the contract the amounts determined for the total
number of each of the units of work as set forth in the Contractor's proposal; the number
of units therein contained is approximate only, and the final payment shall be made for thiS
actual number of units that are incorporated in or made necessary by the work covered
by the contract.
1
~
(b) Progress Payments.
In the event the time necessary to complete this Contract is such that progress payments
are required, they shall be made according to the provisions set forth in the General
Conditions.
ARTICLE IV. CONTRACTOR TO HOLD CITY HARMLESS
The Contractor covenants and agrees to protect and hold the City of Oshkosh
harmless against all actions, claims and demands of any kind or character whatsoever
which may in any way be caused by or result from the intentional or negligent acts of the
Contractor, his agents or assigns, his employees or his subcontractors related however
remotely to the performance of this Contract or be caused or result from any violation of
any law or administrative regulation, and shall indemnify or refund to the City all sums
including court costs, attorney fees and punitive damages which the City may be obliged
or adjudged to pay on any such claims or demands within thirty (30) days of the date of the
City's written demand for indemnification or refund.
ARTICLE V. COMPONENT PARTS OF THE CONTRACT
This contract consists of the following component parts, all of which are as fully a
part of this contract as if herein set out verbatim, or if not attached, as if hereto attached:
1. General Conditions
2. Advertisement for Bids
3. Instructions to Bidders
4. Specifications, including any addenda
5. Plans
6. Contractor's Proposal
7. This Instrument
I n the event that any provision in any of the above component parts of this contract
conflicts with any provision in any other of the component parts, the provision in the
component part first enumerated above shall govern over any other component part which
follows it numerically except as may be otherwise specifically stated.
IT IS HEREBY DECLARED, UNDERSTOOD AND AGREED that the word
"Contractor" wherever used in this contract means the party of the second part and
its/his/their legal representatives, successors and assigns. '
2
~
, ~
IN WITNESS WHEREOF, the City of Oshkosh, Wisconsin, has caused this contract
to be sealed with its corporate seal and to be subscribed to by its City Manager and City
Clerk and countersigned by the Comptroller of said City, and the party of the second part
hereunto set its, his or their hand and seal the day and year first above written.
I~l~
(Seal of Contractor
if a Corporation.)
~w~e~
/1
~ ~
-- if
By:
By:
(M~~rtY~~
~a
SECRETARY
(Specify Title)
CITY OF OSHKOSH
BY:~~
ichard A. Wollangk, City Manager
I hereby certify that the necess-
ary provisions have been made to
pay the liability which will accrue
under this contract.
~},Al) O.C~
City Comptroller
3
PERFORMANCE BOND
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable.
CONTRACTOR (Name and Address):
SURETY (Name and Principal Place of Business):
LaLonde Contractors, Inc.
2929 S. Chase Avenue
Milwaukee, WI 53207
Liberty Mutual Insurance Company
450 Plymouth Road
Plymouth Meeting, PA 19462
OWNER (Name and Address):
City of Oshkosh
PO Box 1130
Oshkosh, WI 54902
CONSTRUCTION CONTRACT
Date: 5-10-06
Amount: $4,081, 553.43
Description (Name and Location):
Public Works Contract 06-06
......,'"' /~
-/r
BOND -,
Date (Not earlier than Construction Contract Date): 5 -10 - 0 6
Amolmt: $4,081,553.43
Modifications to this Bond:
IXI None
D See other side
CONTRACT AS PRINCIPAL
Company: (Corporate Seal)
LaLonde Contractors, "~
Signature: ~ r:
SURETY
Company:
Liberty
(Corporate Seal)
Mutual Insuranc~ CO~I>an:z.
MkNxa. ~;iL)-
Signature:
~'/
Name and Title:
MARK LALONDE
VICE-PRESIDENT
NameandTitle:Debbra A. Hinkes,
Attorney-in-Fact
---?
-",,- ~-
~...~. I" '''-,,,
(FOR INFORMATION ONLY - Name, Address and Telephone)
AGENT or BROKER:
OWNER'S REPRESENTATIVE (Architect, Engineer or othm party):
Printed in cooperation with the American Institute of Architects (AlA) by the CNA Insurance Companies.
The language in this document conforms exactly to the language used in AlA Document A312 - Performance Bond - December 1984 edition.
1 Ihe Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner
for the performance of the Construction Contract, which is incorporated herein by reference.
2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except to participate
in conferences as provided in Subparagraph 3.1.
3 If there is no Owner Default, the Surety's obligation under this Bond shall arise after:
3.1 The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 below that the Owner is considering
declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later
than fifteen days after receipt of such notice to discuss methods of performing the Construction Contract. If the Owner, the Contractor and the
Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the
Owner's right, if any, subsequently to declare a Contractor Default; and
3.2 The Owner has declared a Contractor Default and formally terminated the Contractor's right to complete the contract. Such Contractor
Default shall not be declared earlier than twenty days after the Contractor and the Surety have received notice as provided in Subparagraph 3.1;
and
3.3 The Owner has agreed to pay the Balance of the Contract Price to the Surety in accordance with the terms of the Construction Contract or
to a contractor selected to perform the Construction Contract in accordance with the terms of the contract with the Owner.
4 When the Owner has satisfied the conditions of Paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following
actions:
4.1 Arrange for the Contractor, with consent of the Owner, to perform and complete the Construction Contract; or
4.2 Undertake to perform and complete the Construction Contract itself, through its agents or through independent contractors; or
4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and complletion of the
Construction Contract; arrange for a contract to be prepared for execution by the Owner and the contractor selected with the Owner's concurrence,
to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,
and pay to the Owner the amount of damages as described in Paragraph 6 in excess of the Balance of the Contract Price incurred by the Owner
resulting from the Contractor's default; or
4.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the
circumstances:
.1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is
determined, tender payment therefor to the Owner; or
.2 Deny liability in whole or in part and notify the Owner citing reasons therefor.
5 If the Surety does not proceed as provided in Paragraph 4 with reasonable promptness, the Surety shall be deemed to be in default on this Bond
fifteen days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond,
and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Subparagraph 4.4, and Owner
refuses the payment tendered or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to emforce and
remedy available to the Owner.
6 After the Owner has terminated the Contractor's right to complete the Construction Contract; and if the Surety elects to act under Sulbparagraph
4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction
Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. To the limit
of the amount of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs and damages of the
Construction Contract, the Surety is obligated without dulication for:
6.1 The responsibilities of the Contractor for correction of defective work and completion of the Construction Contract;
6.2 Additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act
of the Surety under Paragraph 4; and
6.3 Liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed
performance or non-performance of the Contractor.
7 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the
Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this bond
to any person or entity other than the Owner or its heirs, executors, administrators or successors.
8 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase
orders and other obligations.
9 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part
of the work is located and shall be instituted within two years after Contractor Default or within two years after the Contractor ceased working or within
two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void
or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable.
10 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page.
11 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be
performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming
to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond
and not as a common law bond.
12 DEFINITIONS
12.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Construction contract afte.r all proper
adjustments have been made, including allowance to the Contractor or any amounts received or to be received by the Owner in settlement of
insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the
Contractor under the Construction Contract.
12.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract
Documents and changes thereto.
12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the
terms of the Construction Contract.
12.4 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction
Contract or to perform and complete or comply with the other terms thereof.
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
PAYMENT BOND
Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable.
CONTRACTOR (Name and Address):
SURETY (Name and Principal Place of Business):
LaLonde Contractors, Inc.
2929 S. Chase Avenue
Milwaukee, WI 53207
Liberty Mutual Insurance Company
450 Plymouth Road
Plymouth Meeting, PA 19462
OWNER (Name and Address):
City of Oshkosh
PO Box 1130
Oshkosh, WI 54902
CONSTRUCTION CONTRACT
Date: 5-10-06
Amount:$4, 081,553.43
Description (Name and Location):
Public Works Contract 06-06
BOND
Date (Not earlier than Construction Contract Date): 5-10-06
Amount: $4,081,553.43
Modifications to this Bond:
ug None
D See other side
CONTRACTOR AS PRINCIPAL
Company:
LaLonde Contractors, Inc.
(Corporate Seal)
SURETY
Company: (Corporate Seal)
Liberty Mutual Insurance Company
Signature:
Signature:
Mb\R.Q. ~~
Name and Title:
Name and Title: Debbra A. HinkE~s ,
Attorney-in-Fact
(FOR INFORMATION ONLY - Name, Address and Telephone)
AGENT or BROKER:
OWNER'S REPRESENTATIVE (Architect, Engineer or other party):
Printed in cooperation with the American Institute of Architects (AlA) by the CNA Insurance Companies.
The language in this document conforms exactly to the language used in AlA Document A312 - Payment Bond - December 1984 Edition.
1 The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner
to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference.
2 With respect to the Owner, this obligation shall be null and void if the Contractor:
2.1 Promptly makes payment, directly or indirectly, for all sums due Claimants, and
2.2 Defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity whose claim, dernand, lien
or suit is for the payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, provided the Owner
has promptly notified the Contractor and the Surety (at the address described in Paragraph 12) of any claims, demands, liens or suits and
tendered defense of such claims, demands, liens or suits to the Contractor and the Surety, and provided there is no Owner Default.
3 With respect to Claimants, this obligation shall be null and void it the Contractor promptly makes payment, directly or indirectly, for all sums due.
4 The surety shall have no obligation to Claimants under this bond until:
4.1 Claimants who are employed by or have a direct contract with the Contractor have given notice to the Surety (at the address described in
Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy,
the amount of the claim.
4.2 Claimants who do not have a direct contract with the Contractor:
.1 Have furnished written notice to the Contractor and sent a copy, or notice thereof, to the Owner, within 90 days after having last
performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and
the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and
.2 Have either received a rejection in whole or in part from the Contractor, or not received within 30 days of furnishing the above notice any
communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly; and
.3 Not having been paid within the above 30 days, have sent a written notice to the Surety (at the address described in Pargraph 12) and
sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written
notice furnished to the Contractor.
5 If a notice required by paragraph 4 is given by the Owner to the Contractor or to the Surety, that is sufficient compliance.
6 When the Claimant has satisfied the conditions of Paragraph 4, the Surety shall promptly and at the Surety's expense take the followin!~ actions:
6.1 Send an answer to the Claimant, with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed
and the basis for challenging any amounts that are disputed.
6.2 Payor arrange for payment of any undisputed amounts.
7 The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in
good faith by the Surety.
8 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract
and to satisfy claims, it any, under any Construction Performance Bond. By the Contractor furnishing and the Owner accepting this Bond, they agree
that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the ContraGtor and the
Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work.
9 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract.
The Owner shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no ol)ligations to
make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond.
10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase
orders and other obligations.
11 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the
work or part of the work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Subparagraph
4.1 or Clause 4.2.3, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone
under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum
period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable.
12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. Actual receipt of
notice by Surety, the Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on
the signature page.
13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be
performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming
to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond
and not as a common law bond.
14 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor shall promptly furnish a copy of this Bond
or shall permit a copy to be made.
15 DEFINITIONS
15.1 Claimant: An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,
materials or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor,
materials or equipment" that part of water, gas power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction
Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and
all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished.
15.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract
Documents and changes thereto.
15.3 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction
Contract or to perform and complete or comply with the other terms thereof.
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
;.;c:.,:.:t..,'.,';C>C:;:".",,:: : .:: ..; ,::;i'::. ,';c .::i....:':, .:. :.:;':"::. -c,.'.;. :; :.,:.>:.:::.. .:,.; :'.'. .':. .'.' .. :.:c..<';,::; :.>,::.:...:.:<.:...::;.::::.::..;.. :. . ... <. '. :. :
.....:....:. ,i,j::t~;.~r~;t~ef~,n .s!ate~;';/.:;~i'.:W;t.IBE~':'tM(JtUAL i~~URANC'e:cbMPA~~;:::\E;'02 ,....' .'. . ;.;': ':. >{>
.......:....)..: ::..:; ; c; ,.." ::'..;:':'.. :':;.::. .' ..'SOSTONMAsSACHUSETTS ;'.F: .~'.:X.:..' :.;; ':,...:'.: .:'.'c:: ..:: '. ........;:.:..:.,~... .
. :.,' :::<? ':." .... ,,: .;::i:c . .:.......>:.i::'"- .. '... .... ... .': :.......; .ci;' cc).:":"":;.:.:
. ."'::.:::':..::::.::.::..:':.',.:. :::C..:: .'...:::'.: .:..::.."c'::.~..;.: .:,',..:: ::,. POWEROF~T'f'ORNEY : 'c'.:.. ';..~.:'::.. ..:.::..:i' ..:.'. .. '.:::<..:;.:. ...,... ;..
'. :;.....:..;?:::.:".:: '. '::.:.:'; . .': . .,;.........:. :..... .".C.:,.:..: .... .... .:.:.;:C.... . '. >>:..::.::::. ..:..:...... .. :;..... ". . '..,".> . .. ':.:. ..':
.. ......T ~NbYv'~L.L<PE~S~~S:~Y fl-l~~~~~~$~NT~/f th~F Ljb~i-ty.MutGJ( Insu~a~6~ /co~p~ri~(tAe;;bbhi'p~ny'i)~ .~ M~st~c~'U~~~s ~~6.ckfllsLr~~#~>/
..~company,pursuanttp and by authonty ofth~ By-Iawand Authpl')z~tl~nherell')after seHorth, doel3 hereby nanie,con~titute and appomt .', '.:.;
t~~\~E~~~1~;:t.ijirt~::rrj!:0~iftl;~;:~~:t::ji~:tr:f.~~ili~r:1;~~t:i~i~:r:mi~11~!1:rrt0:~~i
............. ...:}e;(1cl1 individuatl{if ther~ be;rno(e tharr ~ne ha,med; it~ t~uea~d laWf~t atto~y~in:facf tO~ke, Elxeci~te, :s~aj:. ~C~tiOW,ledge 'iiritf defixer, .tor anq <in ,its
< ?'>behalf as surety and as ItS act and deed, ~andalll:lngettaklngs, bonds, rei::ogOlzancesand othersurety obllgatlonstrt1he penal sum not exceeding.
...:.. '. THIRTYMILtION.AND00l100*~**~*~**, .*****~*:~.:...:,...';:.'. .' :..:.'...DOLLAR:S ($ 30jOOO,OOO.OO*****.:.....:......:> ) each, and the...'
> .i. ......exe.cutionof~uchD.iiaertakirigs.b(ji1ds,.reb6gn.izah~e~.ahd:othersuretY QblfgatiOns, inpG($uanee.j)f.. ttiesepresents'shaf! bea:s. .bindin~1 upb6th( .
........ ...:qompanyas if they haa Men. duly si9i:le9;by thepfesideritan~a11esteg by the secretary ofth~ Gorhl?any .in their own Proper perSOrts,~;:;,. ...... ..=
.......:. . . . ., ... '.' . , ' . , .' .....,.. .. .'.... . ,.. .. ...." '><0'::.;,;:":
0m~~~~I~~lilil~~
I. . <:~..< Any officer- of the Company authorized for that purpose in writing by tI:1e chairrharl6rtllepfesident, and subjectto such Iil11itatior1sas t,he .
1'.':.:. .. i;cbairman prthe preside.nt may prescribe, sh~llapp:oint :sqcn attorneys:in:-fact, as may be necessaiy toabt rnb~hi:llf of t~e Companylo:make! ....... i
.~....... .'. 'execute; seal, acknowledge 'and>deliver as 5uretyany'arid' all undertakings, bonds, recogniza:nce$and ptner ;sOrety obligations. Such .~
.iii ...... ..... ..... ..; : a~orri~ys-in-fa:ct~: subject to tlje 1!rpit~ti6ris's~t forth in t~elrrespecti\ie pow~rs ofa.ttorney,: shl:(U hay~ full power to ~irid lh~ pOfTipany by thei~ ...... g
o . .........slgna.tute ?lnc;l execution of any such. Instrum~nts .and to attach th.ereto these~lof the Company. . When. spexecutecfstlch tnstrulT)ents shall be. G
g. .. .......... .: as bind.irig. as if s.igned by the preSident and Eltlested by the ~e~r~tary. '. ':.. ',. :;.':; . ;;, ... .. . .. . ;. , . ,: "; ,..:.:;; ..5
"C .......<:........ '. ........ ;'..: ;;' .': ., : ' , · .... .; > .,.., ,....c:......:.; , .,.... .;. .'. .'... ..::.;.:::..:<:........ ., ." .. .. ..... ..:, .. :. .',':: .... .:.. .. ;...;:> ./~
I.~.:g ..By:itI.~fQIJo~ingin~t~prnel1ithecha!rniar16r Y,e ~resii:len(h~;aut~ori~edtheo~icer or oth~r6t1idi~lrrameid ther~ir!tCl a.ppoin(~ttorneys-!j,-fact:.:.:<i
&i O)>...:c..: ;.....:.......:....:. <,;.,..::::.::':::;..:. · .. : .' .. : :: :. :. :';..:':"':..<.::;..' ':> .', '.,.:....C : .. ,'.....:..:.. .:'. :: ; :; .. ;: " . ... .:' : :.., :. .,: :'.., .::. ....,..:.::.......X..:.:.. ~
.~ ~~I10g>:t;~g~;~J~/~~~i~I~~~e~~~~n~y~~r~%G~~;~:y ~:~~J~~a~j\6tt~c~~~i~:R~,~~1jhla~0~p~~~~...;#~~I~~:k~t:.c;e~~~~:;'~'I~d~:r:~a ...;.....~
"C !! .. .{'i '.. :dElliver as sl.iretyanY~~d),IIJindertakirigs, bonds, rec()!:Iniza:nce~ an(j <ither:sur~~P?ligatioris. . :... , :.: f..:~j!? .." /~i~?;; :: ..';.' :: ....:...:.; ~ C
0) 0)"::..':.:.; : .'. .: .... :. ' . . : ; ':.,>".:' . :.. '. · >.<. ....<:.." ... .'" , ..... .': .. :. :. , ..: .. , . .;:..>;>. .. .. ;.. {~:.;:" > : /./ , ".:..:::::.. :.. .,..:.. : ,....::.::::.. 0- '"
5 0) 'Tfi~tfh~ By~jclw'andtheAqthorjzati6n~s~tfofthab?y~~ritrG~(;~~ie$ thereof anciafen(w.iin full forc~ and eff~Ci. ...'0 .': :. . ';::::'lZ'i ~:: ~~
'0.2 <'. . " . . ; . . . .. '. . '. ; '. . ... ..- ,. '. .:.<;...';' .>:":.'" ........ '.. .; ..... . . . '. .: ... :. . ,. :"::'.:";:' ....:: ;.... i:
~ ~ IN WiTNESS WHEREOF, this Powe.~of Attorney has beerisubscribed by an authorized ,officer or o.ffL~J~lpf the Company and the''Core()rate se~t}8t 0. ~
= (ijL,ibew Mutuallnsurance Company has b~~n affixed thereto in Plymoqth f\J1.~e3.}eti?g, Pennsylvania this .7th:day of':... June ..,.... " '.,' ,= <:
J!::I ....2004';;::>..>;:. '.':: >.'.::.<: ......,. :.....:...::".:.:...:...;;..:....:... . ..:.... '" .:.<.:,;= '!J'. <C (t
....-; "C..:...'.~:.;:.... .>.,....;........ :.i.....:i../.. '. ..:.....> "., :.,.:<:.. '..<:::..... <. ....:>: .' . ::.:'..'.>' -0 ~
c '-'''' :..: .. ..... .......::: . .....: ','.: ....:. :::.:' '.. ,....
CIS :g ............;\.) \.. '. .'. . ...............,. i..' paER'T'Y:I\iIl)TUALI~$U.R~~CE POMP.ANY.. . '.. ... ...~ ~
.~::: ..............>~..~~ .y .. .,;.;.:.,. i'.:;';: · ;....... .:. ;..z::::....>;: r..> '.. ... :'.' .. .,: 3:: ~
0) 0 .............. ...C,: .:..::...).....:.......::.::,..:.. ......:, :..'..:...;.:~....:..~ .j.;:. ....~>~..~,/, ':.', ... .:. ;. .::;> 0 E
'00):...... .. ::;...:;::....:.::.':......::.. . '.; . .... :....:.:..: ...::...;;:.:. .....:. :.:.. :...sy~~.!2!L..;;'. ~~ ;...'.>:..:. ..,.:::... a... ~
c <<i . .' . '.: ;>; ..:. .> .. .,.'.< .::. .0 .: ..c......... 'W.: .:. .. . '. ...:.. GarnefW: Elliott Assistant Secr~tar\ry;.. ..... .;.:::.':.;. ..:,.....<:.;,>, th <:
or'::: COMMONWEALTH OF pgNNSYI..VAN(~'S~..~;.i\\'./:.~ ....... ,....X{J..> .. .c.. ". .:: '.. ,>;.:X': :;.......';:;: 5 c:
1: ~9n>tils7th: .. dkyof ;: J~ne..6,2()04, beifore..ri~.a~~t~&~~6!iS;per~oiiatIYCarrie.Ga~r1et w.Eiliot('torn~ ~i1?Viri?iiridaCklriOw1e8~e~ ~ ~
~'-' that he is an Assi.stant Secretary of 1,.iberty Mutuql Insurance Company; that he Knows the seal of saldcqrporation; and tti;3.tM e.xecuted the. apove :2'.;:
(j g:~~er~f/f\~or.n~yand: a~xed . corporate ~~~I.O~ L;b~~: ~~t~ail~s~r~n~e~?mp,~ny r.~r~t; ~it~ tse, aut~otity ~~!~t lh1 ~}r~c~i!~.~f.~~d:c~~o,r~~o~:; ~. ~
.~ ~ ~~sT~~~~~~tt~~H .0 supS~r!b~d:my~ame and ~~e.d: my notanaI~e~1 atPI~rno~th~eebn.~,:~~n.r~yl~~?I~,;?n;I~~~d~y:~nd.v~~r 5 ~
~ g .~~:;~:~.': ........... ...., . ., ...;E<...... . . ..........~..n.....~;;';.;:::i.:o::.; Ed
. ;.... .....:::.....:...::..:...: ....:...... .., ..'.:..:.:::........~........;:. ~...::..;:...:....;....:-.:.::.;....:.. .!::(t
-... ..............0:;:;:... :.':.... . ......:,... .., . y ....~ ... ......:.~..::.::. : .:....:..:. ......:..:. -ex
o ::I ..' >:. .:':.; ,.... ..'/'./7f: . . .: .,...:..: 'By" . 1./ . ,...: .. ... .:. ::; .:..... . ..' :.:: C I
Z (,) ...... :/.:... . ....:...::. . ....... ..... ' . .: ... /.. .. ..... ....., ...... .0<:
. 'i/?:?~" ...:. . ':W~:fj.r,". . .,'" '. Teresa PC\stella, Notary PUblic .. ... ....................i;, ............ :.j:......gr
..~: ~~;U~cfersig~~ci: ~ssi '. '. . ,.,'Y QfU~~rtYM~tu~11I1Su!~nce8~ii;p.~ny,~.heretiy~rtifYtha(111~6ri~rh~IPb~~ro~atto;A~y .~!,~hiCh..'thiltorkgOing -9
..: ;i~ ~ full, true an.d corre:t C?Py, 1~1n f~P fo.tqe (1nd ~ffe?t on th~~e .of ttl1S ~rtlfjpate; an~J dO fu~her c~rtlfY tl)~t. tt)eo~l(;er ,or offlclcaI 'Who; e)(e9.uted ,th~.: .
.:..; .s-ald pow~rofattorneYls a,n Assl~~nt Se~retary. speCially authortzedby.thec~a1rma~ Of tile pre.sldenttc>appomt att<lmeys-In~fact as pr?v~ded In A!ilsl~;'
X/XIII. SectIon 5 of the By-laws of Liberty Mutual Insurance Company. . . .. ... " . . / :;.' . ..;' ., ::. ,::.:;
jc '!~~;~~:{~'~~~~~ k ~~~~~~ &:,;~~a~T~;m~l.~~.;.;1~y~l~f~~~:~t~~~"~~i~~~~, ~ .J.~~~~.'
':<".\';V:O~SD th.~t the.faCSiTile 'or riieichani~any. reproduce~ si~nat~re ofariy,:assi~tarit ~ecretarY6f the ccimp~ny. whe.reyer appearing Dpori a '
................ :"iit '.' c~rtlflEld copy of any power of att"rney Issued by the. company In conl'le<.:tlon With ?urety~ol1<:i$, shall be. valid and bmdtn!;! upon thl~ c(jmpa.nr .........
..Y-:lf'./TE$TIM ~'iv f{EREO~1b~i h~Ie8;,t9~ubscribedmy7~f1'l~~Q~ affixed'the ?6tp~r~~.~~al 6~f ~h~tjai~26irib~nY, thi~ J. ~ tyJ ..... :,'.:d~Y'Of ...........
. ....:....;;.Il l.t .,cz..u!.JJ.l2.,.:..........~..:.;.0';.. .... .... .. ............... '<';..i' "}':;'.:'.";'.:.'.; ,,:. ,:<c'. .......:
. :"..":':."".:,..' .;. .'. .:.../. ....:. ';:::.:...::-::.:. .................:.i..:;:}... ',}:.?:. ..... ...::::~.:;. ...';>./J..i~i~;;,;i..i '.t :' ;:.:::',:;.X.
.::;.< ........:\ . .... ......... ... .... ...................;...........'.; :,2': ."'...:;.Z.' .c..".....:... ."; ., . /' "::",. . >.. ...:.... .::.. ...:. :.......
......,...:.:, .:........:..::.:. ;., ...:", :..C:. . .:. '<;'.. :'>co.: 's' ,;, -'. .1 .....//.::: '..' ::.... <:...:., c...:. :'.:.. ..
....::.::/.::....:.: .... . ::::..; ....: . ',..:. . . . Y II""".... ..... .> .. .'. ' . .
, .:..........::.:.; '0.: . 'c,'c ;,." "..""';. ';. . .... ."Davia M:c~~a~r:ety,..~ A:S;S~' tl'int Secretary ...::....;; ,:: :;.
.'. ..:.. ::>,::.,. ...i..... ..:> ~:;.. ': ::. ';'..:~" .':27':~voi' ..' .. "c': .'. ..... ...:.. .............. ........ ......... .........',
I. ... .: .~. ............. :.' .j):.::.:..,.: '... .f.\. C.;.:.:.. ;<'...:: .:..( .... ~':,,: .::< ...:'.'; ....'.': >.0..:'.'
I... ... ':...;.. .......:; .. :.:..... ...c.,. .... ,':..' ..::::.":':.; .. ....... ..../'. . : /'. ....:.....:.;:.... :. ..,':..::.:..::. :...:<. :,. ...:.......':....:;.::;::..::.: . .'. . . . ....<...::: .:"':..::..:.:
"
OS/26/2,006 FRI 14:21 FAX 414 744 1715 LALONDE CbNtRACTORS,INC
I'-"'~
aEel 5/26/2006 Time: 12:46 PM To. Wendy @ 14147441715
~002/003
pa'lG. 002-0.03
ACORDTM CERTIFICATE OF LIABILITY INSURANCE I DATE IIMMIDDIYYYYI
OS/2:/106
PRODUCER THIS CERTIFICATE IS ISSUED AS A MATrER OF INFORMA:TION
Security Insurance Svcs., Inc. ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATIE
HOLDER. THIS CERTIFICATE DOES NOTAMEND, EXTEND OR
P.O. Box 510925 ALTER THE COVERAGE AFFORDED BYTHE POLICIES BELOW.
New Berlin, WI 53151-0925
262 785-9490 INSURERS AFFORDING COVERAGE NA,IC~
INSURED INSURER A, General Casually Company
laLonde Contractors, Inc. INSURER B:
P.O. Box 0.70420 INSURER C:
Milwauk~e, WI 53207 INSURER D:
INSURERE:
Clienl#' 3801
LALOCON
COVERAGES
THE POLICIES OF INSURANCE LISTED BaoW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE poLlCYPER.lbbINDlc::ATED. NoTWITHSTJINOING
ANY REQUIREIVIENT, TERM OR CONDITION OF /'NY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
. MAY PERTAIN. THE INSURANCE AFFORDED BYTHE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BE.EN REDUCED BY F'AID CLAIMS.
LTR NSR TYPE O.F INSURANCE POL1CYNlIMBER PJ'k~~~:~\'Bg,Wf Pg~.fl;W~~ LIMITS
A ~NERAL LIABILITY CCI0421034 04/01106 D4/D 1/07 EACH OCCURRENCE $1.000.000
X COMNERCIAL GENERAL LIABILITY DAMAGE \9c~~~ ,_, 5100.000
I CLAIMS MADE ~ OCCUR NED EXF> (Any ene person) 55.00'0
PERSONAL & ADV INJURY $1 000,000
GENERAL AGGREGATE $2 000.000
,i..,..\ n'L AGGREr;lE ;~~ APr~f PER: PRODUCTS - CONPIOP A<3G $2 OllIO.OOO
POLICY X JEer LOC
A ~OMOBILE L1ABIUTY CBA042.1034 04/01106 04/01/07 COMBINED SINGLE LIMIT 51,DIlID,000
~ ANY AUTO lEa accidentl
- ALL OWNED AUTOS BODILY INJURY
(p... personl $
- SCHEDULED AUTOS
X. HIRED AUTOS BODILY INJURY
$
X. NON-OWNED AIITOS (Per accidenl)
- PROPERlY DAMAGE $
(P..- accid..ll)
==rGE L1ABIUTY AUTO ONLY. EA ACCIDENT 5
ANY AUTO OTHER THAN EAACC $
AUTO DNL Y: AGG $
A ~ESSlUMBREI.U\. L1ABIUTY CCU0421034 04/01/06 04/D1/07 EACH OCCURRENCE $5 000.000
OCCUR D CLAIMS MADE AGGREGATE $5.0110.000
5
==i DEDUCTIBLE $
RETENTION $ $
A WORKERS CONPENSATIDN AND CWC0421D34 04/01/06 D4/D1/D7 X I T~fj1f~~;, I IOJ~
EIIIPLOYERS'L1AB1UTY EL EACH ACCIDENT $500.000
fWY PROPRIETORIPARTNERlEXECUTIVE
OFFICERlMEMBER EXCLUDED1 E.L. DISEASE - EA EMPLOYEE $500,000
If yes, desai~urlder EL DISEASE -POLlCYLllI.lrT 5500,000
SPECIAL PROVISIONS below
OTHER
DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES I EXCLUSIONS ADDE:D BY ENDORSEMENT I SPECIAL PROVISIONS
job: Public Works Contract #06005
The City of Oshkosh is named additional insured for general liability with regard to work
perfonned by the named insured.
CERTIFICATE HOLDER
CANCELLATION
City of Oshkosh
P.O. Box 1130
Oshkosh,~ 54902
SHOULD ANY OF lliE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION
DATI; T1iEREOF, THE ISSUING INSUREOR WILL ENDEAVOR TO MAIL -3JL DAYSWRITlEN
NOTICE TO THE CERTIFICA.TE HOLDEI'I NANED TO THE LEFT, BUT FAILURE TO DO SO SHALL
IMPOSE NO CBLlGATION OR UABILITV OF ANY KIND UPON THE INSURER, IT!; AGENTS OR
ACORD 25 (20D1/08) 1 of 2
#S116377/M113640
ACORD CORF'ORATION 1988